02-0305_AVIATION ENV SERVICES_Construction ContractCONSTRUCTION CONTRACT
THIS CONTRACT is made and entered into, to be effective, this 5 day of
N1 .(/, 2002, by and between the CAPISTRANO VALLEY WATER DISTRICT,
hereinafter referred to as "District," and Aviation Env . Services , hereinafter
referred to as "Contractor."
City and Contractor mutually agree as follows:
Section 1. General Conditions.
Contractor certifies and agrees that all the terms, conditions and obligations of
the Contract Documents as hereinafter defined, the location of the job site, and the
conditions under which the work is to be performed have been thoroughly reviewed, and
enters into this Contract based upon Contractor's investigation of all such matters and is
in no way relying upon any opinions or representations of District.. It is agreed that this
Contract represents the entire agreement between the parties. It is further agreed that
the Contract Documents including the Notice Inviting Bids, Special Instructions to
Bidders, If any, and Contractor`s Proposal, are incorporated in this Contract by
reference, with the same force and effect as if the same were set forth at length herein,
and that Contractor and its subcontractors, If any, will be and are bound by any and all
of said Contract Documents insofar as they relate in any part or in any way, directly or
indirectly, to the work covered by this Contract.
"Project" as used herein defines the entire scope of the work covered by all the
Contract Documents. Anything mentioned in the Specifications and not indicated in the
Plans, or indicated in the Plans and not mentioned in the Specifications, shall be of like
effect as if indicated and mentioned in both. In case of discrepancy in the Plans, or
Specifications, the matter shall be immediately submitted to Districts Engineer, without
whose decision Contractor shall not adjust said discrepancy save only at Contractor's
own risk and expense. The decision of the Engineer shall be final.
CAPISTRANO VALLEY WATER DISTRICT AGREEMENT
RECYCLED WATER PIPELINE - FOUR OAKS &1
ATTACHMENT 3
Section 2. Materials and Labor.
Contractor shall furnish, under the conditions expressed in the Plans and
Specifications, at Contractor's own expense, all labor and materials necessary, except
such as are mentioned in the Specifications to be furnished by the District, to construct
and complete the Project, in good workmanlike and substantial order. If Contractor fails
to pay for labor or materials when due, District may settle such claims by making
demand upon the surety to this Contract. In the event of the failure or refusal of the
surety to satisfy said claims, District may settle them directly and deduct the amount of
payments from the Contract price and any amounts due to Contractor. In the event
District receives a stop notice from any laborer or material supplier alleging non-
payment by Contractor, District shall be entitled to deduct all of its costs and expenses
incurred relating thereto, including but not limited to administrative and legal fees.
Section 3. Description of Proiect.
The Project is described as: RECYCLED WATER PIPELINE — FOUR OAKS as
delineated in the Plans and Specifications prepared by Teledine Engineering, Inc.,
dated December, 2001. Work to include: the construction of approximately 1,000 linear
feet of 8 -inch non-domestic waterline, meters, and valves, and all appurtenant work.
Section 4. Plans and Specifications.
The work to be done is shown in a set of detailed Plans and Specifications entitled:
RECYCLED WATER PIPELINE — FOUR OAKS
CAPISTRANO VALLEY WATER DISTRICT AGREEMENT
RECYCLED WATER PIPELINE - FOUR OAKS B'2
Said Plans and Specifications and any revisions, amendments or addenda
thereto are attached hereto and incorporated herein as part of this Contract and referred
to by reference.
Section 5. Time of Commencement and Completion.
Contractor agrees to commence the Project within ten (10) calendar days from
the date set forth in the "Notice to Proceed" sent by District and shall diligently
/Vin
prosecute the work to completion within Twenly (90) calendar days from the date of the
"Notice to Proceed" issued by the District excluding delays caused or authorized by the
District as set forth in Sections 7, 8 and 9 hereof.
Section 6. Time is of the Essence.
Time is of the essence of this Contract. As required by the Contract Documents,
Contractor shall prepare and obtain approval of all shop drawings, details and samples,
and do all other things necessary and incidental to the prosecution of Contractor's work
in conformance With an approved construction progress schedule. Contractor shall
coordinate the work covered by this Contract with that of all other Contractors,
subcontractors and of the District, in a manner that will facilitate the efficient completion
of the entire work in accordance with Section 5 herein. District shall have complete
control of the premises on which the work is to be performed and shall have the right to
decide the time or order in which the various portions of the work shall be installed or
the priority of the work of other subcontractors, and, in general, all matters representing
the timely and orderly conduct of the work of Contractor on the premises.
Section 7. Excusable Delays.
Contractor shall be excused for any delay in the prosecution or completion of the
Project caused by acts of God; inclement weather which exceeds the number of
calendar days estimated by the District and set forth in Section 5 hereof; damages
CAPISTRANO VALLEY WATER DISTRICT AGREEMENT
RECYCLED WATER PIPELINE - FOUR OAKS B3
caused by fire or other casualty for which Contractor is not responsible; any act, neglect
or default of District; failure of District to make timely payments to Contractor; late
delivery of materials required by this Contract to be furnished by District; combined
action of the workers in no way caused by or resulting from default or collusion on the
part of Contractor; a lockout by District; or any other delays unforeseen by Contractor
and beyond Contractor's reasonable control.
District shall extend the time fixed in Section 5 for completion of the Project by
the number of days Contractor has thus been delayed, provided that Contractor
presents a written request to District for such time extension within fifteen (15) days of
the commencement of such delay and District finds that the delay is justified. Districts
decision will be conclusive on the parties to this Contract. Failure to file such request
within the time allowed shall be deemed a waiver of the claim by Contractor.
No claims by Contractor for additional compensation or damages for delays will
be allowed unless Contractor satisfies District that such delays were unavoidable and
not the result of any action or inaction of Contractor and that Contractor took all
available measures to mitigate such damages. Extensions of time and extra
compensation as a result of incurring undisclosed utilities will be determined in
accordance with Section C -9(f) of the General Provisions. The District's decision will be
conclusive on all parties to this Contract.
Section S. Extra Work.
The Contract price includes compensation for all work performed by Contractor,
unless Contractor obtains a written change order signed by a designated representative
of District specifying the exact nature of the extra work and the amount of extra
compensation to be paid all as more particularly set forth in Section 9 -hereof.
District shall extend the time fixed in Section 5 for completion of the Project by
the number of days reasonably required for Contractor to perform the extra work, as
determined by District's Engineer. The decision of the Engineer shall be final.
CAPISTRANO VALLEY WATER DISTRICT AGREEMENyT
RECYCLED WATER PIPELINE - FOUR OAKS B-0
Section 9. Changes in Proiect.
A. District may at any time, without notice to any surety, by written order
designated or indicated to be a change order, make any change in the work within the
general scope of the Contract, including but not limited to changes:
1) in the Specifications (including drawings and designs);
2) in the time, method or manner of performance of the work;
3) in the District -furnished facilities, equipment, materials, services or
site; or
4) directing acceleration in the performance of the work.
B. A change order shall also be any other written order (including direction,
instruction, interpretation or determination) from the District which causes
any change, provided Contractor gives the District written notice stating
the date, circumstances and source of the order and that Contractor
regards the order as a change order.
C. Except as provided in this Section 9, no order, statement or conduct of the
District or its representatives shall be treated as a change under this Section 9 or entitle
Contractor to an equitable adjustment.
D. If any change under this Section 9 causes an increase or decrease in
Contractor's actual, direct cost or the time required to perform any part of the work
under this Contract, whether or not changed by any order, the District shall make an
equitable adjustment and modify the Contract in writing. Except for claims based on
defective specifications, no claim for any change under paragraph (B) above shall be
allowed for any costs incurred more than twenty (20) days before the Contractor gives
written notice as required in paragraph (B). In the case of defective specifications for
which the District is responsible, the equitable adjustment shall include any increased
direct cost Contractor reasonably incurred in attempting to comply with those defective
specifications.
CAPISTRANO VALLEY WATER DISTRICT AGREEMENT
RECYCLED WATER PIPELINE - FOUR OAKS &5
IE. If Contractor intends to assert a claim for an equitable adjustment under this
Section 9, it must, within
thirty
(30)
days after
receipt of a written change
1
' order under paragraph
(A) or
the
furnishing
of a written notice under
paragraph (B), submit a written statement to the District setting forth the
general nature and monetary extent of such claim. The District may extend
the thirty (30) day period. Contractor may include the statement of claim in
the notice under paragraph (B) of this Section 9.
F. No claim by Contractor for an equitable adjustment shall be allowed if
made after final payment under this Agreement.
G. Contractor hereby agrees to make any and all changes, furnish the
materials and perform the work that District may require without nullifying this Contract.
Contractor shall adhere strictly to the Plans_ and Specifications unless a- change
therefrom is authorized in writing by the District. Under no condition shall Contractor
make any changes to the Project, either in additions or deductions, without the written
order of the District and the District shall not pay for any extra charges made by
Contractor that, have not been agreed upon in advance in writing by the District.
Contractor shall submit immediately to the District written copies of its firm's cost or
credit proposal for change in the work. Disputed work shall be performed as ordered in
writing by the District and the proper cost or credit breakdowns therefore shall be
submitted without delay by Contractor to District.
Section 10. Liquidated Damages for Delay.
The parties agree that if the total work called for under this Contract, in all parts
and requirements, is not completed within the time specified in Section 5 plus the
allowance made for delays or extensions authorized under Sections 7, 8 and 9, the
District will sustain damage which would be extremely difficult and impracticable to
ascertain. The parties therefore agree that Contractor will pay to District the sum of
CAPISTRANO VALLEY WATER DISTRICT AGREEMENT
RECYCLED WATER PIPELINE - FOUR OAKS B$
$100.00 per day, as liquidated damages, and not as a penalty, for each and every
calendar day during which completion of the Project is so delayed.
Contractor agrees to pay such liquidated damages and further agrees that
District may offset the amount of liquidated damages from any monies due or that may
become due Contractor under this Contract.
Section 11. Contract Price and Method of Payment.
District agrees to pay and Contractor agrees to accept as full consideration for
the faithful performance of this Contract, subject to any subsequent additions or
deductions as provided in approved change orders, the sum of 63,666 Dollars and
81 cents ($ 63,666.81 ) as itemized on the attached Exhibit "A."
Within thirty (30) days from the commencement of work, there shall be paid to
the Contractor a sum equal to ninety percent (90%) of the value of the actual work
completed plus a like percentage of the value of material suitably stored at the worksite,
treatment plant or approved storage yards subject to or under the control of the District,
since the commencement of the work as determined by the District. Thereafter, on a
schedule issued by the District at the commencement of the job which shows a
minimum of one payment made to the Contractor per month for each successive month
as the work progresses and the request for payment due dates from the Contractor to
meet the payment schedule, the Contractor shall be paid such sum as will bring the total
payments received since the commencement of the work up to ninety percent (90%) of
the value of the work completed since the commencement of work as determined by the
District, less all previous payments, provided that the Contractor submits the request for
payment prior to the end of the day required to meet the payment schedule. The
District will retain ten percent (10%) of the amount of each such progress estimate and
material cost until the Final Payment.
Payments shall be made on demands drawn in the manner required by law,
accompanied by a certificate signed by the Districrs Engineer, stating that the work for
CAPISTRANO VALLEY WATER DISTRICT AGREEMENT
RECYCLED WATER PIPELINE - FOUR OAKS &7
which payment is demanded has been performed in accordance with the terms of the
Contract, and that the amount stated in the certificate is due under the terms of the
Contract. Partial payments on the Contract price shall not be considered as an
acceptance of any part of the work.
Section 12. Substitution of Securities in Lieu of Retention of Funds.
Pursuant to Public Contract Code Section 22300 et seq., the Contractor will be
entitled to post approved securities with the District or an approved financial institution
in order to have the District release funds retained by the District to insure performance
of the Contract. Contractor shall be required to execute an addendum to this Contract
together with escrow instructions and any other documents in order to effect this
substitution....
Section 13. Completion.
Within ten (10) days after the contract completion date of the Project, Contractor
shall file with the Districts, Engineer its affidavit stating that all' workers and persoos.
employed, all firms supplying materials, and all subcontractors upon the Project have
been paid in full, and that there ate no claims outstanding against the Project for either
labor or material, except those certain items, if any, to be set forth in an affidavit
covering disputed claims, or items in connection with. Stop Notices which have been
filed under the provisions of the statutes of the State of California. District may require
affidavits or certificates of payment and/or releases from any subcontractor, laborer or
material supplier.
Section 14. Contractor's Employees' Compensation,
A. Davis -Bacon Act:
Contractor will pay and will require all subcontractors to pay all employees on
said Project a salary or wage at least equal to the prevailing rate of per diem wages as
determined by the Secretary of Labor in accordance with the Davis -Bacon Act for each
craft or type of worker needed to perform the Contract.
CAPISTRANO VALLEY WATER DISTRICT AGREEMENT
RECYCLED WATER PIPELINE - FOUR OAKS 8-8
I
V
The provisions of the Davis -Bacon Act shall apply only if the Contract is in
excess of Two Thousand Dollars ($2,000.00) or when twenty-five percent (25%) or
more of the Contract is funded by federal assistance. If the aforesaid conditions are
met, a copy of the provisions of the Davis -Bacon Act to be complied with are
incorporated herein as a part of this Contract and referred to by reference.
B. General Prevailing Rate:
District has ascertained from the State of California Director of Industrial
Relations the general prevailing rate of per diem wages and the general prevailing rate
for legal holiday and overtime work in the locality in which the work is to be performed
for each craft or type of work needed to execute this Contract, and copies of the same
are on file in the Office of the Engineer of District. The Contractor agrees that not less
than said prevailing rates shall be paid to workers employed on this public works
contract as required by Labor Code Section 1774 of the State of California.
C. Forfeiture For Violation:
Contractor shall, as a penalty to the District, forfeit Fifty Dollars ($50.00) for each
calendar day or portion thereof for each worker paid (either by the Contractor or any
subcontractor under it) less than, the prevailing rate of per diem wages as set by- the
Director of Industrial Relations, in accordance with Sections 1770-1780 of the California
Labor Code for the work provided for in this Contract, all in accordance with Section
1775 of the Labor Code of the State of California.
D. Travel and Subsistence Pay:
Section 1773.8 of the Labor Code of the State of California, regarding, the
payment of travel and subsistence payments, is applicable to this Contract and
Contractor shall comply therewith.
E. Apprentices:
CAPISTRANO VALLEY WATER DISTRICT
RECYCLED WATER PIPELINE - FOUR OAKS
AGREEMENT
&9
Section 1777.5, 1777.6 and 1777.7 of the Labor Code of the State of California,
regarding the employment of apprentices, is applicable to this Contract and the
Contractor shall comply therewith if the prime contract involves Thirty Thousand Dollars
($30,000.00) or more or twenty (20) working days, or more; or if contracts of specialty
Contractors not bidding for work through the general or prime Contractor are Two
Thousand Dollars ($2,000.00) or more or five (5) working days or more.
F. Workday:
In the performance of this Contract, not more than eight (8) hours shall constitute
a day's work, and Contractor shall not require more than eight (8) hours of labor in a day
from any person employed by him hereunder except as provided in paragraph (f})
above. Contractor shall conform to Article 3, Chapter 1, Part 7 (Sections 1810 at s
of the Labor Code of the State of California and shall forfeit to the District as a perwklty,
the sum of Twenty-five Dollars ($25.00) for each worker employed in the execution of
this Contract by Contractor or any subcontractor for eactrcalendar day during which any
worker is required or permitted to labor more than eight (8) hours in any one calendar
day and forty (40) hours in any one week in violation of said Article. Contractor stlall
keep an accurate record showing the name and actual hours worked each calendar day
and each calendar week by each worker employed by Contractor in connection with, the
Project.
G. Record of Wages; Inspection:
Contractor agrees to maintain accurate payroll records showing the name,
address, social security number, work classification, straight -time and overtime hours
worked each day and week, and the actual per diem wages paid to each journeyman,
apprentice, worker or other employee employed by it in connection with the Project and
CAPISTRANO VALLEY WATER DISTRICT AGREEMENT
RECYCLED WATER PIPELINE - FOUR OAKS B-10
agrees to require that each of its subcontractors does the same. All payroll records
shall be certified as accurate by the applicable Contractor or subcontractor or its agent
having authority over such matters. Contractor further agrees that its payroll records
and those of its subcontractors shall be available to the employee or employee's
I
representative, the Division of Labor Standards Enforcement, and the Division of
4 Apprenticeship Standards and shall comply with all of the provisions of Labor Code
Section 1776, in general.
Section 15. Surety Bond> .
Contractor shall, before entering upon the performance of this Contract, furnish
bonds approved by the District Counsel — one in the amount of one hundred percent
(100%) of the Contract price bid, to guarantee the faithful performance of the work, and
the other in the amount of one hundred percent (100%) of the Contract price bid to
guarantee payment of all claims for labor and materials furnished. This Contract shall
not become effective until such bonds are supplied to and approved by the District.
Section 16. Insurance.
A. Contractor is also aware of the provisions of Section 3700 of the Labor
Code which requires every employer to be insured against liability for
Workers' Compensation or undertake self-insurance in accordance with
the provisions of that Code and will comply with such provisions before
commencing the performance of the. work of this Contract.
B. Contractor and all subcontractors will carry workers' compensation
insurance for the protection of its employees during the progress of the
work. The insurer shall waive its rights of subrogation against District, its
1 CAPISTRANO VALLEY WATER DISTRICT AGREEMENT
RECYCLED WATER PIPELINE - FOUR OAKS &11
i
officers, agents and employees and shall issue a certificate to the policy
evidencing same.
C. Contractor shall at all times carry, on all operations hereunder, bodily
injury, including death, and property damage liability insurance, including automotive
operations, bodily injury and property damage coverage. All insurance coverage shall
be in amounts specified by District in the Insurance Requirements and shall be
evidenced by the issuance of a certificate in a form prescribed by the District and shall
be underwritten by insurance companies satisfactory to District for all operations,
subcontract work, contractual obligations, product or completed operations, all owned
vehicles and non -owned vehicles. Said insurance coverage obtained by the Contractor,
excepting workers' compensation coverage, shall name the District, its Directors,
Officers, Agents, Employees, Engineers, and Consultants for this contract, and all public
agencies from whom permits will be obtained and their Directors, Officers, Agents and
Employees, as determined by the District, as additional insureds on said policies.
C. Before Contractor performs any work at, or prepares or delivers materials
to, the site of construction, Contractor shall furnish certificates of
insurance evidencing the foregoing insurance coverages and such
certificates shall provide the name and policy number of each carrier and
policy and that the insurance is in force and will not be canceled without
thirty (30) days' written notice to District.
Contractor shall maintain all of the foregoing insurance coverages in force until
1 the work under this Contract is fully completed. The requirement for carrying the
foregoing insurance shall not derogate from the provisions for indemnification of District
by Contractor under Section 17 of this Contract. Notwithstanding nor'diminishing the
obligations of Contractor with respect to the foregoing, Contractor shall subscribe for
CAPISTRANO VALLEY WATER DISTRICT AGREEMENT
RECYCLED WATER PIPELINE - FOUR OAKS &t2
Section 18. Stop Notice Administration.
District reserves the right to charge Contractor for District's actual administrative
} time (including attorney's time) to administer and process stop notices filed by
Contractor's subcontractors, materialmen, or any other claimant or lienholder.
Section 19. Termination.
A. This Contract may be terminated in whole or in part in writing by either
party in the event of substantial failure by the other party to fulfill its obligations under
jthis Contract through no fault of the terminating party, provided that no termination may
be effected unless the other party is given: (1) not less than ten (10) calendar days'
written notice (delivered by certified mail, return receipt requested) of intent to terminate,
and (2) an opportunity for consultation with the terminating party prior to termination.
1 B. This Contract may be terminated in whole or in part in writing by the
District for its convenience, provided that the Contractor is given (1) not less than ten
(10) calendar days' written notice (delivered by certified mail, return receipt requested)
of intent to terminate, and (2) an opportunity for consultation with the terminating party
prior to termination.
D. If termination for default or convenience is effected by the District, an
equitable adjustment in the price provided for in this Contract shall be
made, but (1) no amount shall be allowed for anticipated profit on
unperformed services or other work, and (2) any payment due to the
Contractor at the time of termination may be adjusted to cover any
additional costs to the District because of the Contractor's default. If
termination for default is effected by the Contractor, the equitable
adjustment shall include a reasonable profit for services or other work
performed, but no adjustment will be allowed for anticipated profits. The
equitable adjustment for any termination shall provide for payment to the
Contractor for services rendered and expenses incurred prior to the
termination, in addition to termination settlement costs reasonably incurred
CAPISTRANO VALLEY WATER DISTRICT AGREEMENT
RECYCLED WATER PIPELINE - FOUR OAKS B-14
by the Contractor relating to commitments which had become firm prior to
the termination.
D. Upon receipt of a termination action under paragraphs (A) or (B) above,
the Contractor shall (1) promptly discontinue all affected work (unless the notice directs
otherwise), and (2) deliver or otherwise make available to the District all data, drawings,
specifications, reports, estimates, summaries and such other information and materials
as may have been accumulated by the Contractor in performing this Contract whether
completed or in process.
E. Upon termination under paragraphs (A) or (B) above, the District may take
over the work and may award another party an agreement to complete the work under
this Contract.
Contractor agrees to perform all work under this Contract in accordance with the
District's designs, drawings and specifications. The Contractor guarantees for a period
of at least one (1) year from the date of substantial completion of the work that the
completed work is free from all defects due to faulty materials, equipment or
workmanship and that he shall promptly make whatever adjustments or correctiorks
which may be necessary to cure any defects, including repairs of any damage to other
parts of the system resulting from such defects. The District shall promptly give notice
to the Contractor of observed defects. In the event that the Contractor fails to make
adjustments, repairs, corrections or other work made necessary by such defects, the
District may do so and charge the Contractor the cost incurred. The performance bond
shall remain in full force and effect through the guarantee period.
The Contractor's obligations under this clause are in addition to the Contractoes
other express or implied assurances under this Contract or state law and in no way
I
diminish any other rights that the District may have against the Contractor for faulty
materials, equipment or work.
CAPISTRANO VALLEY WATER DISTRICT AGREEMENT
RECYCLED WATER PIPELINE - FOUR OAKS &15
Section 20. Assignment.
No assignment by the Contractor of this Contract or any part hereof, or of funds
to be received hereunder, will be recognized by the District unless such assignment has
had prior written approval and consent of the District and the surety.
Section 21. Attorneys' Fees.
If any action at law or in equity is necessary to enforce or interpretthe terms of
this Contract, the prevailing party shall be entitled to reasonable attorneys' fees, costs
and necessary disbursements in addition to any other relief to which it may be, entitled.
If any action is brought against the Contractor or any subcontractor to enforce a Stop
Notice or Notice to Withhold, which names the District as a party to said action, the
District shall be entitled to reasonable attorneys' fees, costs and necessary
disbursements arising out of the defense of such action by the District. The District
shall be entitled to deduct its costs for any Stop Notice filed, whether court action is
involved or not.
Section 22. Resolution of Disputes.
The District and the Contractor shall comply with the revisions of California Public
Contracts Code Section 20104, et seg., regarding resolution of construction claims for
any claims which arise between the Contractor and the District.
Section 23. Notices.
Any notice required or permitted under this Contract may be given by ordinary
mail at the address set forth below. Any party whose address changes shall notify the
l
I other party in writing.
To District: Capistrano Valley Water District
32400 Paseo Adelanto
San Juan Capistrano, CA 92675
CAPISTRANO VALLEY WATER DISTRICT AGREEMENT
RECYCLED WATER PIPELINE - FOUR OAKS &16
Attn: Director of Public Works
i
To Contractor: contact Andy Galbraith
Company name Aviation Environmental Services
addreSS15330 Cholame Road, Suite B
city, State, Zip Victorville, Ca. 92392
I
IN WITNESS WHEREOF, the parties hereto have executed this Construction
Contract as
of the date first hereinabove written.
IVY,
C�A`PrISTRA 1O j%OLLEY WATER DISTRICT
Diane Bathgate,- Chairman of the Board
0
FORM:
John R. Shaw, City Counsel
"Contract "
y: David Whitman
CAPISTRANO VALLEY WATER DISTRICT AGREEMENT
&1
RECYCLED WATER PIPELINE - FOUR OAKS -
I
BID SCHEDULE
RECYCLED WATER PIPELINE — FOUR OAKS
CIP NO. 0576
Item
Description
Estimated
Unit
Unit
Amount
No.
Quantity
Price
1
8" PVC Water Mainw/Street Repair
960
LF
$ 32.20
$30,912.00
2
90 Deg. Bends w/Thrust Blocks
3
EA
$7 2 7 , 5 0
2,182.50
$
3
Cut in Tee
1
EA
$3 497.50
$3,49 .50
4
Protect in Place
1
LS
2,200.00
,200.00
200.00
$2,
5
80 R.W. Gate Valve
1
EA
$1,928,75
$1,928.75
6
Repair Landscape & Irrigation
1
LS
200.00
$4., inn _ n0
7
Driveway Access
4
EA
$ 7nn no
$
8
1" Meter & Backflow Device
1
EA
$ 1,525.00
$ 0
g
1" PVC Water Line
150
LF
$ 10.53
$1 579.50
10
2" Water Meter
1
EA
$ 1 A71 99
$1 R71 2S
11
Remove EX. Backflow Device
1
EA
500.00
500.00
$
$
12
Traffic Control
1
LS
$2,200.00
$2,200.00
13
Vacuum Relief Valve
1
EA
4 , 2 7 0.31
4 , 2 7 0.31
Assembly$
$
14
Mobilization.
1
LS
$ 4, 000.00
$4,000.00
CeZePY111lgLEI :I
IUNIT PRICE BID SCHEDULE
09U-30Iun1 zu BID FORMS - PAGE 2
2
o.�..e., a, om
ATTACHMENT A
TOTAL OF ALL ITEMS OF THE BID SCHEDULE:
$ 63,666.81
(Price In figures)
Sixty Three Thousand, Six Hundred Sixty Six and Eighty nna P.S
(Price in words)
QUANTITIES OF WORK:
The quantities of work or material in the unit price items of the Bid Schedule are
supplied only to give an indication of the general scope of the Work. The Capistrano
valley Water District does not expressly nor by implication agree that the actual
amounts of work or material will correspond herewith, and reserves the right after
award to increase or decrease the quantity of any unit price bid item, by an amount up
to 25 percent of increase or decrease, without a change in the unit prices, and shall
have the right to delete any bid item in its entirety, and receive full credit in the
amount in the Bid Schedule for the deleted item of Work.
Aviation Environmental Services
Name of Bidder or Firm
UNIT PRICE BID SCHEDULE
BID FORMS - PAGE)( 3
0.,..er D. 3001