1995-0919_SJC HOUSING INVESTORS, L.P._Owner Participation AgreementOWNER PARTICIPATION AGREEMENT
Between
SAN JUAN CAPISTRANO REDEVELOPMENT AGENCY
and
SAN JUAN CAPISTRANO HOUSING INVESTORS, L.P.
SJCOPA.KB
091995
TABLE OF CONTENTS
ARTICLE 1. DEFINITIONS ................................... 2
ARTICLE 2. PERMITTED USE AND DEVELOPMENT OF THE PROPERTY ....
8
ARTICLE 3. FINANCING THE PROJECT ..........................
15
ARTICLE 4. RESTRICTED UNITS AND TAX CREDIT PROGRAM .........
23
ARTICLE 5. CONDITIONS OF DEVELOPER OBLIGATIONS .............
25
ARTICLE 6. INSURANCE; INDEMNIFICATION .............. I ......
25
ARTICLE 7. INSPECTION ...................................
28
ARTICLE 8. FORCED DELAY; EXTENSION OF TIME . I ...............
28
ARTICLE 9. REPRESENTATIONS AND WARRANTIES ................
28
ARTICLE 10. MORTGAGEE PROTECTION .........................
29
ARTICLE 11. CERTIFICATE OF COMPLETION ......................
33
ARTICLE 12. DISCRIMINATION ................................
33
ARTICLE 13. [PURPOSELY LEFT BLANK] .........................
34
ARTICLE 14. DEFAULTS, REMEDIES, AND TERMINATION .............
34
ARTICLE 15. INDEMNIFICATION ...............................
36
ARTICLE 16. EFFECT OF COVENANTS ..........................
36
ARTICLE 17. TERM; RECORDATION; BINDING EFFECT ...............
36
ARTICLE 18. GENERAL PROVISIONS ............................
36
Exhibits
A. Agency Note
B. Agency Deed of Trust
C. Agency Assignment of Leases
D. Project Budget
E. Legal Description of Property
F. Restrictive Covenants
G. Schedule of Performance
H. Promissory Note - Seller Financing Loan
I. Agency Loan Funding Schedule
J. Fannie Mae Subordination Agreement
K. Certificate of Completion
SJCOPA.KB
091995
OWNER PARTICIPATION AGREEMENT
THIS OWNER PARTICIPATION AGREEMENT ("Agreement") is entered into as
of this 19th day of , 1995 ("Effective Date"), by and between the
SAN JUAN CAPISTRANO REDEVELOPMENT AGENCY, a public body ("Agency") and
SAN JUAN CAPISTRANO HOUSING INVESTORS, L.P., a California limited partnership
("Developer"), pertaining to that certain real property ("Property") in the City of San
Juan Capistrano, County of Orange, State of California as more particularly described
herein.
RECITALS
A. The Agency is a public body, corporate and politic, exercising
governmental functions and powers and organized and existing under the Community
Redevelopment Law of the State of California (Health and Safety Code Section
33000, et seg.).
B. Agency has established the San Juan Capistrano Central Redevelopment
Project Area subject to and as set forth in the Redevelopment Plan adopted by
Ordinance No. 488 of the City Council of the City of San Juan Capistrano, amended
by Ordinance Nos. 509, 547 and 582.
C. Developer is the owner of the Property, or has the right to acquire
ownership of the Property pursuant to an option agreement.
D. Pursuant to Ordinance No. 766, Developer has applied for and the City
of San Juan Capistrano ("City") has determined to issue a Density Bonus Permit
("Density Bonus Permit") to Developer, which Density Bonus Permit grants a density
bonus and other concessions or incentives to Developer for the development of the
Property.
E. The Agency desires to meet its affordable housing requirements pursuant
to the California Community Redevelopment Law (Health and Safety Code Section
33000, et sea.) by assisting in the development of an affordable rental housing
project ("Project") on the Property.
F. By approving and executing this Agreement, the Agency finds that the
Project is of direct benefit to the redevelopment area under the jurisdiction of the
Agency.
G. The obligations of Developer under this Agreement, in addition to the
provisions hereof, are expressly conditioned upon and subject to: (i) the issuance of
the Density Bonus Permit to Developer pursuant to the application by Developer or on
terms and conditions otherwise approved in writing by Developer, and (ii) the
SJCOPA.KB
091995
acquisition of fee title to the Property by Developer pursuant to the option agreement
held by Developer or such terms and conditions otherwise agreed in writing by
Developer.
COVENANTS
Based upon the foregoing Recitals and for good and valuable consideration,
receipt and sufficiency of which is acknowledged by the parties, Agency and
Developer hereby agree as follows:
ARTICLE 1. DEFINITIONS
The following terms as used in this Agreement shall have the meanings given
unless expressly provided to the contrary:
1.1 "Affordable Rent" means the lesser of rents permissible pursuant to the
Low -Income Housing Tax Credit Program or affordable rent as defined in California
Health and Safety Code Section 50053 as exists on the Effective Date or as hereafter
amended. As of the Effective Date, Affordable Rent pursuant to Section 50053 shall
not exceed (a) the product of 30 percent times 60 percent of the area median income
adjusted for family size appropriate for the unit, with respect to Qualified Lower
Income Households whose gross incomes do not exceed 60 percent of the area
median income adjusted for family size, and (b) the product of 30 percent times 50
percent of the area median income adjusted for family size appropriate for the unit,
with respect to Very Low Income Households whose gross incomes do not exceed 50
percent of the area median income adjusted for family size.
1.2 "Agency" means the San Juan Capistrano Redevelopment Agency, a
public body, corporate and politic, having its offices in San Juan Capistrano,
California. The term "Agency" as used herein also includes any assignee of, or
successor to, the rights, powers, and responsibilities of the San Juan Capistrano
Redevelopment Agency.
1.3 "Agency Loan" shall mean the loan described in Paragraph 3.8 of this
Agreement.
1.4 "Agency Note" means the nonrecourse promissory note evidencing the
Agency Loan which note shall be in a form identical to Exhibit A attached hereto and
incorporated herein by reference.
1.5 "Agency Security Documents" means the deed of trust and assignment
of leases securing the Agency Note which shall be in forms identical to Exhibits B and
C attached hereto and incorporated herein by reference.
SJCOPA.KB
091995
K
1.6 "Bridge Loan" means the loan obtained by Developer from K&B, which
Developer anticipates that it will have to obtain to pay the portion of Developer's
Project Cost. The Bridge Loan shall be secured by a Lien on the Project.
1.7 "Capital Improvement Loan" means any Loan made to finance capital
improvements to the Project after the Certificate of Completion has been issued which
Loan or Loans may be secured by a Lien on the Project.
1.8 "Certificate of Completion" means the Certificate of Completion provided
for in Article 11 hereof.
1.9 "City" means the City of San Juan Capistrano, a California general law
municipal corporation, and its successors and assigns having jurisdiction.
1.10 "Construction Loan" means a loan or loans obtained by Developer in
accordance with Paragraph 3.4 herein from an institutional lender or other lender
making such loans the normal course of its business to finance a part of the
Developer's Project Cost which loan or loans shall be secured by a first Lien on the
Project.
1.11 "Debt Service" means the total of the payments actually made by
Developer during the applicable calendar year or partial calendar year in question for
the payment or repayment by Developer of (i) the First Mortgage Financing and (ii)
subject to the limitations set forth in Paragraph 3.7 hereof, any Loan refinancing the
First Mortgage Financing. Debt Service, Gross Income, Negative Cash Flow, Net
Proceeds, Operating Expenses and Rent shall for the purposes of this Agreement be
determined on a cash basis.
1.12 "Developer" means San Juan Capistrano Housing Investors, L.P., a
California limited partnership, its successors, assigns, transferees, or other persons
or entities acquiring title to or an ownership interest in the Property or Project.
1.13 "Developer Loan" means the loan obtained by Developer from K&B to
facilitate refinancing of the Construction Loan and the Bridge Loan. The Developer
Loan shall be secured by a Lien on the Project.
1.14 "Effective Date" is set forth in the opening paragraph on Page 1 of this
Agreement.
1.15 "First Mortgage Financing" means any of the following: (i) the
Construction Loan; (ii) the Permanent Loan; or (iii) any Loan refinancing any
Permanent Loan.
1.16 "Gross Income" means all revenues or income collected by the
Developer, or its successor or assign from the Project. Gross Income shall be
SJCOPA.KB
091995
3
determined on a cash basis during any pertinent or applicable period, but shall not
include security deposits until and unless such security deposits have been forfeited
by tenants. Gross Income shall not, except for loss of rent insurance proceeds which
shall be included, include insurance or condemnation proceeds, or the proceeds from
any sale or refinancing of the Project or any part thereof, provided however insurance
proceeds and payments from any reserve funds established pursuant to Section 1.26
hereof for a casualty loss to the extent that said proceeds are expended on any item
that would qualify as a repair or maintenance item pursuant to the definition of
Operating Expenses shall be included in Project Income.
1.17 "K&B" means Kaufman and Broad Multi -Housing Group, Inc. or any
affiliate thereof.
1.18 "Lender" means any Mortgagee.
1.19 "Lien" means any security instrument encumbering the Project or any
part thereof securing any Loan.
1.20 "Loan" means any loan made by a Mortgagee secured by a Lien.
1.21 "Low -Income Housing Tax Credit Program" shall have the meaning
ascribed in Paragraph 4.1 of this Agreement.
1.22 "Mortgagee" means a mortgagee of a mortgage or a beneficiary under
a deed of trust encumbering title to the Project, or any part thereof.
1.23 "Negative Cash Flow" means for any period the amount by which (i)
Operating Expenses and (ii) Debt Service for such period exceeds the Gross Income
for said period.
1.24 "Negative Cash Flow Loan" means any Loan made to fund Negative Cash
Flow secured by a Lien on the Project.
1.25 "Net Cash Flow" means for any calendar year or partial calendar year the
amount of Gross Income for such period less Operating Expenses and Debt Service
for such period.
1.26 "Net Proceeds" means the proceeds of any Loan secured by the Project,
less the repayment of any Loan made prior in time to said Loan and less any fees or
charges paid out of the gross proceeds related to such Loan, including without
limitation reasonable and customary broker's commissions and fees, Loan commitment
fees or other charges assessed by the Lender for making the Loan, normal closing
costs, title insurance premiums, and attorney's fees.
SJCOPA. KB
091995
H
1.27 "Operating Expenses" means for any calendar year or partial calendar
year the sum of the following expenses incurred and actually paid during such period:
(i) all expenses actually and reasonably incurred by Developer in owning, operating,
maintaining, repairing, and replacing the Project (excluding payment of insurance
proceeds and any costs or expenses paid or reimbursed by third parties), including
without limitation taxes, insurance, and improvement expenses for the Project,
accounting and legal fees, leasing commissions, advertising expenses, supplies,
license and permit fees, capital expenditures (to the extent such expenses exceed
reserves), utility charges and such other matters and in such amounts as Developer
in its reasonable discretion deems reasonable, (ii) such reserves as Developer or any
Mortgagee may require to be set aside for the Project (but excluding the payment of
funds from the reserve once set aside), (iii) a property management fee which shall
not exceed six percent (6%) of Gross Income; (iv) expenses of all on-site employees,
which employees shall be employees of the Project and not the property manager; and
(v) Twenty -Five Thousand Dollars ($25,000) per year to be paid as designated by the
general partner of Developer as an administration fee, and Ten Thousand Dollars
( $10,000) per year to be paid to K & B as an asset management fee, and with such
fees permitted to increase commencing with the second full calendar year after the
issuance of the Certificate of Completion by a percentage not to exceed the
authorized percentage increase in the maximum rents for the Restricted Units in the
Project. Developer shall be deemed to be required to pay Operating Expense for
materials and services upon receipt thereof, and to the extent services are not billed
on a monthly basis, the bill for such services shall be prorated over the period during
which such services were received. Real estate taxes and insurance premiums shall
be prorated on a monthly basis based on the latest information available. If the actual
cost of real estate taxes or insurance premiums are different from the information
used to make such prorations, then an adjustment in the next month's Operating
Expenses shall be made based upon the correct information. Operating Expenses shall
not include: (i) payments made from insurance proceeds for any loss to the Project,
or (ii) depreciation of buildings or improvements, or (iii) funds expended from reserves
to the extent such reserves have already been included as an Operating Expense.
Developer shall count an Operating Expense only one time in one category and under
no circumstances shall an Operating Expense be counted more than once.
1.28 "Party" means any party to this Agreement.
1.29 "Permanent Loan" means any loan, the Net Proceeds of which are used
in part to pay any Construction Loan or any previous Permanent Loan.
1.30 "Project" means the Property and the proposed development of the
Property with an up to one hundred twelve (112) unit apartment project in
conformance with the Final Plans provided for in Paragraph 2.1e.
1.31 "Project Approvals" means the Density Bonus Permit, site specific plans,
maps, permits and other entitlements, discretionary or ministerial, required by the City
SJCOPA.KB
091995
�i
or other governmental entity in connection with the development of the Project on the
Property.
1.32 "Project Budget" means the budget attached as Exhibit D and
incorporated herein by reference to this Agreement which identifies the parties'
estimates as of the Effective Date of the Project Cost, the categories or components
of Project Costs (the "Categories") and the sources and uses of funds applicable
thereto, provided however that the Project Budget is Parties' best estimate of Project
Cost based upon the information available to them as of the Effective Date. There is
no assurance that the actual Project Cost will be limited to the Project Budget and
there is a possibility for substantial increases in costs from those shown on the Project
Budget.
1.33 "Project Cost(s)" means the sum of Developer's total cost to acquire the
Property and construct the Project, including but not limited to, all of the following:
(i) the total cost of market studies, consulting fees, soils tests, closing costs and
attorneys' fees related to the -acquisition of the Property and the economic feasibility
of constructing and operating the Project; (ii) the cost of obtaining the Bridge Loan,
the Developer Loan, the Construction Loan and the Permanent Loan to finance the
Project Cost, including but not limited to, reasonable and customary loan brokerage
fees, finder's fees, loan commitment fees, points, closing costs, attorneys' fees, title
insurance premiums and interest on all such financing through the funding of the
Permanent Loan; (iii) appraisal fees, architectural fees, engineering fees, attorney's
fees and other consulting fees and costs; (iv) the cost of fees and permits payable to
any governmental agency having jurisdiction relating to the construction and operation
of the Project; (v) on site and off site construction costs, including general contractor
fees at 10% of the total construction cost for off-site and on-site improvements, base
construction, exterior common area and customary indirect costs, including without
limitation, trailer, temporary utilities, insurance and on-site supervision; (vi) costs of
construction supervision; (vii) credit enhancement fees; (viii) developer fees of One
Million Eight Thousand and No/100 Dollars ($1,008,000) payable to K&B; (ix) all costs
incurred by Developer in constructing the Project which are not identified in the
Categories, but which qualify as Eligible Basis under Section 42(d)(1) of the Internal
Revenue Code of 1986 as amended; (x) all fees and expenses in obtaining an
allocation of Tax Credits for the Project; (xi) reserves for the operation of the Project
in such amounts as Developer or as a Lender may require; (xii) the amount of any
Negative Cash Flow until Project Stabilization; and (xiii) such amounts properly
expended in any Category not accounted for hereinabove.
1.34 "Project Stabilization" means the first date on which Gross Income equals
or exceeds the total of: (i) Operating Expenses, and (ii) Debt Service, for six (6)
consecutive calendar months.
SJCOPA.KB
091995
A
1.35 "Property" is the subject real property located in the City of San Juan
Capistrano, County of Orange, State of California, and more particularly described in
Exhibit E attached hereto and incorporated herein by reference.
1.36 "Qualified Lower Income Households" means households whose gross
annual income does not exceed 60 percent of the area median income, adjusted for
family size in accordance with adjustment factors adopted by the United States
Department of Housing and Urban Development pursuant to Section 8 of the United
States Housing Act of 1937 as amended. Qualified Lower Income Households satisfy
the income eligibility criteria for Lower Income Households within the meaning of
California Health and Safety Code Section 50079.5.
1.37 "Redevelopment Plan" means the Redevelopment Plan for the San Juan
Capistrano Central Redevelopment Project Area adopted by Ordinance No. 488,
amended by Ordinance Nos. 509, 547 and 582.
1.38 "Regulatory Agreement" means any regulatory agreement required by 4
California Code of Regulations § 10340(c) as required for Developer to obtain the Tax
Credits.
1.39 "Restricted Units" means the 92 one bedroom units in the Project.
1.40 "Restrictive Covenants" means the agreement referred to in Paragraph
4.2 of this Agreement regarding the Restricted Units, which Restrictive Covenants
shall be in the form of the Restrictive Covenants Affecting Real Property as set forth
in Exhibit F attached hereto.
1.41 "Senior Citizen" means a person 62 years of age or older.
1.42 "Schedule of Performance" means that certain Schedule of Performance
attached hereto as Exhibit G and incorporated herein by reference.
1.43 "Seller Financing Loan" means the portion of the purchase price for the
Property payable by Developer to the seller of the Property pursuant to a purchase
promissory note secured by a deed of trust on the Property and other instruments
encumbering the Property as a second priority lien after the First Mortgage Financing.
The principal amount of the Seller Financing Loan is anticipated to be in the amount
of $500,000, earning interest at the rate of eight percent (8%) per annum, and to be
payable from fifty percent (50°x6) of the Net Cash Flow after deduction of Debt
Service and to the extent not theretofore paid the Seller Financing Loan shall be all
due and payable fifteen (15) years after the making of the loan by the Seller. A copy
of the promissory note evidencing the Seller Financing Loan is attached hereto as
Exhibit H and incorporated herein by reference.
SJCOPA.KB
091995
7
1.44 "Tax Credits" means low-income housing tax credits allowable to the
Developer with respect to the Project under Section 42 of the Internal Revenue Code
of 1986, as amended.
1.45 "Tax Credit Sale Proceeds" means the total net proceeds to be obtained
by Developer from the sale of limited partnership interests in Developer to persons
who will qualify as limited partners of Developer for Internal Revenue Code Section
42 tax credits, less the cost of said sales, including without limitation syndication
costs, including but not limited to a syndication fee equal to two percent (2%) of the
gross sale proceeds of the Tax Credits by the Developer, attorney and accountant
fees, filing fees with governmental agencies having jurisdiction over the syndication,
brokerage or finder's fees, and consulting fees. The parties estimate as of the
Effective Date of this Agreement that the Tax _ Credit Sale Proceeds will be
approximately to 56 cents for every dollar of Tax Credits available to the Developer,
provided, however, that it is understood that the actual amount of the Tax Credit Sale
Proceeds may be greater or lesser than said amount.
1.46 "Very Low Income Household" means very low income households within
the meaning of California Health & Safety Code Section 50105 whose gross annual
income does not exceed 50 percent of the area median income adjusted for family
size in accordance with the adjustment factors adopted by the United States
Department of Housing and Union Redevelopment pursuant to Section 8 of the United
States Housing Act of 1937 as amended.
"Debt Service", "Gross Income", "Negative Cash Flow" Net Cash
Flow", and "Operating Expenses" all shall be determined as a cash basis.
ARTICLE 2. PERMITTED USE AND DEVELOPMENT OF THE PROPERTY.
2.1 Permitted Use and Development of the Property. The Developer shall
during construction and thereafter throughout the term of this Agreement have the
right and the obligation to use, develop, operate and maintain the Property in
accordance with the Redevelopment Plan, the provisions of this Agreement and the
Project Approvals.
a. Developer's Obligation to Develop Project. Developer will use best
efforts to develop the Project in accordance with the terms and conditions of this
Agreement, and with the conditions established in the Project Approvals. Developer's
Schedule of Performance for development of the Project is set forth in Exhibit G
hereof.
b. Scope of Development. The Project shall consist of the
development of multiple buildings for up to one hundred twelve (1 12) senior citizen
rental units and related interior and exterior improvements, including but not limited
to, uncovered parking areas, landscaping, and common recreation areas. Developer
SJCOPA.KB
091995
0
shall obtain the City's approval of a conceptual development for the Project within the
time set forth in the Schedule of Performance and Developer shall develop the Project
in conformity with the Project Approvals pursuant to this Agreement, subject to the
provisions of Article 8 below.
C. Development Protect/Architectural Plans. Developer shall within
the time set forth in the Schedule of Performance, prepare and submit to the City for
review and approval the preliminary architectural plans and related documents for the
Project. The preliminary architectural plans shall include the sizes, heights, and
locations of all buildings; building elevations; construction materials; construction
colors; site plan configuration/dimensions; parking; conceptual landscape plan;
conceptual sprinkler plan; and lighting concept.
d. Exterior Treatment Conceit. Developer shall within the time set
forth in the Schedule of Performance, prepare and submit to the City for review and
approval an exterior treatment concept for the Property. The exterior treatment
concept shall include a color and materials board; a signage program; a landscape
plan; and a sprinkler plan.
e. Final Construction Drawings. Developer shall within the time set
forth in the Schedule of Performance, submit final construction drawings to the City
for a finding of conformity with the approved preliminary architectural plans ("Final
Plans") and exterior treatment concept. If the City does not make such a finding,
Developer shall modify and resubmit the final construction drawings and obtain City
approval prior to the issuance of building permits for the Project.
f. Other City and Governmental Agency Permits. Before
commencement of construction of the Project, Developer shall at its own expense
secure or cause to be secured any and all permits and approvals which may be
required by the City or any other governmental agency having jurisdiction over the
Property. Execution of this Agreement does not constitute the granting of a
commitment by the Agency to obtain or to assist in obtaining any Project Approvals.
g. Cost of Development. Developer shall be responsible for all costs
of developing the Project, including but not limited to pre -development costs incurred
for items such as planning, design, engineering, and environmental remediation; all
development and building fees; the cost incurred to demolish and clear any and all
existing improvements, furnishings, fixtures, and equipment from the Property; costs
for insurance and bonds (as required); costs for financing; all on-site construction
costs; and costs for any necessary public improvements, including curb cuts, utility
connections, street repair, and similar items of work that may be necessary in the
street rights-of-way adjacent to the Property, provided however that Developer shall
have no obligation to construct any off-site improvements except those required by
the City in accordance with the normal development review and entitlement process.
SJCOPA.KB
091995
7
h. Schedule of Performance; Progress_ Retorts.
(i1 Developer shall begin and complete all construction and
development within the times specified in the Schedule of Performance, subject to the
provisions of Article 8 hereof. Once construction is commenced, it shall be
continuously and diligently pursued to completion, and stall not be abandoned for
more than sixty (60) consecutive business days, except when due to causes beyond
the control of Developer, as set forth in Article 8 hereof. The Schedule of
Performance is subject to revision from time to time as may be mutually agreed upon
in writing between Developer and the Agency.
(ii) During the course of construction, and prior to the Agency's
issuance of its Certificate of Completion for the Project, Developer shall upon written
request from the Agency keep the Agency informed of the progress of construction
on a monthly basis, which progress reports shall be in writing.
i. Entry by the Agency. Developer shall permit the Agency, through
its officers, agents, or employees, at all reasonable times to enter into the Property
and inspect the work during the construction of the Project on the Property to
determine that the same is in conformity with the Construction Plans. and all the
requirements hereof. Developer acknowledges that the Agency is under no obligation
to supervise, inspect, or inform Developer of the progress of construction, and
Developer shall not rely upon the Agency therefor. Any inspection by the Agency is
entirely for its purposes in determining whether Developer is in default under this
Agreement and is not for the purpose of determining or informing Developer of the
quality or suitability of construction. Developer shall rely entirely upon its own
supervision and inspection in determining the quality and suitability of the materials
and work, and the performance of architects, subcontractors, and material suppliers.
j. Compliance with Laws. The Developer shall comply with all
federal, state and local statutes, ordinances, regulations and laws with respect to the
Developer's ownership and development of the Property and the operation of the
Project.
2.2 Condition of the Pro grt .
a. Environmental Condition Prior to Agency Loan Disbursement. The
Developer represents to the Agency that it is not aware of, to the best of its actual
and/or constructive knowledge, and it has not received any notice or communication
from any governmental agency having jurisdiction over the Property, the owner of the
Property, or any other person or entity, notifying it of the presence of Hazardous
Materials or Hazardous Materials Contamination in, on, or under the Property, or any
portion thereof. Developer knows of no circumstances, conditions or events that
may, now or with the passage of time, give rise to any Environmental Claim against
or affecting the Property. True and correct copies of all of Developer's internal
SJCOPA.KB
091995
10
inspection reports with respect to the Property, environmental audits, reports and
studies received by Developer which concern the Property, and inspection reports
from applicable regulatory authorities with respect to the Property, if any, have been
delivered to Agency.
As soon as possible following the execution of this Agreement, the Developer
shall cause the environmental condition of the Property to be investigated, with the
cost of such investigation to be borne by the Developer. Such investigation shall
include such activities as the Developer's environmental expert or consultant (the
"Environmental Consultant") deems necessary or appropriate to determine the
environmental condition of the Property, but, in any case, including preparation of at
least a "Phase 1 " report for the Property which shall identify in reasonable detail the
remedial actions, if any, required for the Property. The Agency shall, at least five (5)
days prior to the close of escrow for the acquisition of the Property, be provided a
copy of all reports and test results produced by the Environmental Consultant. As a
condition precedent to the disbursement of any portion of the Agency Loan, the
Developer shall cause the Property to be remediated in accordance with the remedial
actions identified in the Environmental Consultant's report, and in accordance with all
Governmental Requirements.
b. Develo er's Obligation to Investigate and Remediate the Property
After Agency Loan Disbursement. After the disbursement of all or any portion of the
Agency Loan, and notwithstanding the obligation of Developer to indemnify Agency
pursuant to subparagraph (c) of this Paragraph 2.2 or any other obligations of the
Developer pursuant to this Agreement, Developer shall, at its sole cost and expense,
promptly take (i) all actions required by any federal, state or local governmental
agency or political subdivision or any Governmental Requirements with respect to the
Property, and (ii) all actions necessary to make full economic use of the Property for
the purposes described in this Agreement, which actions, requirements or necessity
arise from the presence upon, about or beneath the Property of any Hazardous
Materials or Hazardous Materials Contamination regardless of when such Hazardous
Materials or Hazardous Materials Contamination were introduced to the Property and
regardless of who is responsible for introducing such Hazardous Materials or
Hazardous Materials Contamination to the Property, or portion thereof (the
"Remediation"). The Remediation shall include, but not be limited to, an initial
investigation of the environmental condition of the Property, the preparation of any
feasibility studies or reports and the performance of any cleanup, remedial, removal
or restoration work required. The Developer shall take all actions necessary to
promptly restore the Property to an environmentally sound condition for uses
contemplated by this Agreement, notwithstanding any lesser standard of remediation
allowable under applicable Governmental Requirements. The Developer's obligations
under this subparagraph (b) of this Paragraph 2.2 shall survive the issuance of the
Certificate of Completion.
SJCOPA.KB
091995
11
C. Indemnification. Developer shall save, protect, pay for, defend,
indemnify and hold harmless the Agency and its officers, employees, representatives
and agents, from and against any and all liabilities, suits, actions, claims, demands,
penalties, damages (including, without limitation, penalties, fines and monetary
sanctions), losses, costs or expenses (including, without limitation, consultants' fees,
investigation and laboratory fees, attorneys' fees and remedial and response costs)
(the foregoing are hereinafter collectively referred to as "Liabilities") which may now
or in the future be incurred or suffered by the Agency or its officers, employees,
representatives or agents by reason of, resulting from, in connection with or arising
in any manner whatsoever as a direct or indirect result of (i) the ownership of all or
any part of the Property, (ii) any act or omission on the part of Developer, or their
agents, employees, representatives, agents, contractors or invitees, (iii) the presence
on or under, or the escape, seepage, leakage, spillage, discharge, emission or release
from the Property of any Hazardous Materials or Hazardous Materials Contamination,
(iv) the environmental condition of the Property, and (v) any Liabilities incurred under
any Governmental Requirements relating to Hazardous Materials. Developer's
obligations under this Paragraph 2.2 shall survive after the issuance of the Certificate
of Completion, and shall be a covenant running with the land in perpetuity, binding
on all successors and assigns of Developer's interest in either this Agreement or the
Property. Developer may assign its obligations under this Paragraph 2.2 to the
successor or assign of Developer's interest in this Agreement or the Property for those
events or conditions related to the requirements in this Paragraph 2.2 which may
occur subsequent to such Developer conveyance, provided that the Developer shall
remain liable for all of its obligations hereunder. Notwithstanding the foregoing,
Developer shall not have any obligation to indemnify Agency where the Liabilities have
arisen as a result of the gross negligence or willful misconduct of Agency, its officers,
employees, representatives and agents.
d. Release. The Developer hereby waives, releases and discharges
forever the Agency, and its employees, officers, agents and representatives, from all
present and future claims, demands, suits, legal and administrative proceedings and
from all liability for damages, losses, costs, liabilities, fees and expenses, present and
future, arising out of or in any way connected with the Agency's or the Developer's
use, maintenance, ownership or operation of the Property, any Hazardous Materials
on the Property, or the existence of Hazardous Materials Contamination in any state
on the Property, however they came to be emplaced there.
The Developer acknowledges that it is aware of and familiar with the
provisions of Section 1542 of the California Civil Code which provides as follows:
SJCOPA. KB
091995
"A general release does not extend to claims which the
creditor does not know or suspect to exist in his favor at
the time of executing the release, which if known by him
must have materially affected his settlement with the
debtor."
12
As such relates to this Paragraph 2.2, the Developer hereby waives and
relinquishes all rights and benefits which it may have under Section 1542 of the
California Civil Code.
Notwithstanding the foregoing, this Release shall not be effective in the
event the presence or release of Hazardous Materials on the Property occur as a result
of the gross negligence or willful misconduct of Agency, its officers, employees,
representatives and agents.
e. Duty to Prevent Hazardous Material Contamination. Upon the execution
of this Agreement, the Developer shall take such actions as necessary or prudent to
prevent the release of any Hazardous Materials into the environment on or under the
Property. Such precautions shall include reasonable means to prevent or discourage
dumping or other releases of Hazardous Materials on the Property by third parties and
trespassers, including without limitation the erection of a fence surrounding the
Property if warranted. In the event any Remediation is required on the Property prior
to the disbursement of the Agency Loan, such Remediation shall be conducted in
accordance with subparagraph (a) of this Paragraph 2.2.
During the Rehabilitation of the Property, the Developer shall take all
necessary precautions to prevent the release of any Hazardous Materials into the
environment on or under the Property. Such precautions shall include compliance with
all Governmental Requirements with respect to Hazardous Materials. In addition, the
Developer shall install and utilize such equipment and implement and adhere to such
procedures as are consistent with the then prevailing standards as respects the
disclosure, storage, use, removal and disposal of Hazardous Materials.
f. Environmental Inquiries. The Developer shall notify the Agency, and
provide to the Agency a copy or copies, of the following environmental permits,
disclosures, applications, entitlements or inquiries relating to the Property: notices of
violation, notices to comply, citations, inquiries, clean-up or abatement orders, cease
and desist orders, reports filed pursuant to self -reporting requirements and reports
filed or applications made pursuant to any Governmental Requirement relating to
Hazardous Materials and underground tanks, and the Developer shall report to the
Agency, as soon as possible after each incident, any unusual, potentially important
incidents, including but not limited to, the following:
(i) All required reports of releases of Hazardous
Materials, including notices of any release of Hazardous Materials as required
by any Governmental Requirement;
(ii) All notices of suspension of any permits;
(iii) All notices of violation from Federal, State or local
environmental authorities;
SJCOPA.KB
091995
13
(iv) All orders under the State Hazardous Waste Control
Act and the State Hazardous Substance Account Act and corresponding federal
statutes, concerning investigation, compliance schedules, clean up, or other
remedial actions;
(v) All orders under the Porter -Cologne Act, including
corrective action orders, cease and desist orders, and clean-up and abatement
orders;
(vi) Any notices of violation from OSHA or Cal -OSHA
concerning employees' exposure to Hazardous Materials;
(vii) All complaints and_ other pleadings filed against the
Developer and/or the Agency relating to the Developer's storage, use,
transportation, handling or disposal of Hazardous Materials on the Property.
In the event of a release of any Hazardous Materials into the environment, the
Developer shall, as soon as possible after the release, furnish to the Agency a copy
of any and all reports relating thereto and copies of all correspondence with
governmental agencies .relating to the release. Upon request of the Agency, the
Developer shall furnish to the Agency a copy or copies of any and all other
environmental entitlements or inquiries relating to or affecting the Property including,
but not limited to, all permit applications, permits and reports including, without
limitation, those reports and other matters which may be characterized as confidential.
g. Definitions. For the purposes of this Paragraph 2.2, the following terms
shall have the meanings herein specified:
(i) The term "Hazardous Materials" shall mean (1) any
"hazardous substance" as defined by the Comprehensive Environmental
Response, Compensation and Liability Act of 1980 (42 U.S.C. Section 9601
et seq.), as amended from time to time, and regulations promulgated
thereunder; (2) any "hazardous substance" as defined by the
Carpenter -Presley -Tanner Hazardous Substance Account Act (California Health
and Safety Code Sections 25300 et seq. ), as amended from time to time, and
regulations promulgatedthereunder;(3) asbestos;(4) polychlorinatedbiphenyls;
(5) petroleum, oil, gasoline (refined and unrefined) and their respective
by-products and constituents; and (6) any other substance, whether in the form
of a solid, liquid, gas or any other form whatsoever, which by any
"Governmental Requirements" (as defined in subparagraph g (iii) of this
Paragraph 2.2) either requires special handling in its use, transportation,
generation, collection, storage, handling, treatment or disposal, or is defined as
"hazardous" or harmful to the environment.
SJCOPA.KB
091995
14
(ii) The term "Hazardous Materials Contamination" shall
mean the contamination (whether presently existing or hereafter occurring) of
the improvements, facilities, soil, groundwater, air or other elements on, in or
of the Property by Hazardous Materials, or the contamination of the buildings,
facilities, soil, groundwater, air or other elements on, in or of any other property
as a result of Hazardous Materials at any time (whether before or after the date
of this Agreement) emanating from the Property.
(iii) The term "Governmental Requirements" shall mean
all laws, ordinances, statutes, codes, rules, regulations, orders and decrees of
the United States, the state, the county, the city, or any other political
subdivision in which the Property is located, and of any other political
subdivision, agency or instrumentality exercising jurisdiction over the Agency,
the Developer or the Property.
(iv) The term "Environmental Claim" shall mean (1) any
judicial or administrative enforcement actions, proceedings, claims, orders
(including consent orders and decrees), directives, notices (including notices of
inspection, notices of abatement, notices of non-compliance or violation and
notices to comply), requests for information or investigation instituted or
threatened by any governmental authority pursuant to any Governmental
Requirement; or, (2) any suits, arbitrations, legal proceedings, actions or claims
instituted, made or threatened that relate to any damage, contribution, cost
recovery, compensation, loss or injury resulting from the release or threatened
release (whether sudden or non -sudden or accidental or non-accidental), of, or
exposure to, any Hazardous Materials, or the violation or alleged violation of
any Governmental Requirement, or the general, manufacture, use, storage,
transportation, treatment, or disposal of Hazardous Materials.
ARTICLE 3. FINANCING THE PROJECT.
3.1 Sources and Uses of Funds. The anticipated sources and uses of funds
for acquisition of the Property, development and construction of the Project are set
forth in the Project Budget. The Project Budget is Developer's best estimate based
upon the information available to it as of the Effective Date as to what the total
Project Cost will be. There is no assurance that the actual Project Cost will be limited
to the Project Budget and there is a possibility for substantial increases or decreases
in costs from these shown in the Project Budget.
3.2 Seller Financing Loan. Developer will finance a part of the acquisition
purchase price of the Property by the Seller Financing Loan which shall be secured by
a Lien on the Project subject and subordinate only to the First Mortgage Financing.
3.3 Bridge Loan and Develoger Loan.
SJCOPA.KB
091995
15
a. Necessity for Bridge Loan. In the event that any Project Cost is
due and payable before the initial funding of a Construction Loan, or if the funding of
the Construction Loan is insufficient to pay said costs as they come due, or if Project
Costs exceed the amount of the Seller Financing Loan and the Construction Loan,
Developer may obtain the Bridge Loan from K&B.
b. Amount of Bride Loan. The Bridge Loan shall not exceed the
Project Cost, and shall be reduced by the Net Proceeds of the Permanent Loan and the
Tax Credit Sale Proceeds.
C. Determination of Project Cost. Within ninety (90) days after the
later of (i) the initial funding of the Permanent Loan, or (ii) the date the State of
California completes its audit of the Project Cost pursuant to the applicable regulations
of the California Tax Credit Allocation Committee, Developer shall notify the Agency
of the Bridge Loan amount and the Project Cost as calculated by Developer and shall
provide to the Agency a complete accounting of all actual sources of funds and uses
of funds (as reflected in the line items shown on the Project Budget) in order to enable
the Agency to verify the accuracy of Developer's statement with respect to the
Project Cost and the amount of the Bridge Loan.
d. Bridge Loan_ Terms. The unpaid principal balance of the Bridge
Loan during its term shall bear interest at the rate of ten percent (10%) per annum
(exclusive of late charges, penalties or fees in case of default) from the date of initial
funding of the Bridge Loan, provided that in no event shall additional interest be
earned on unpaid interest which has accrued. Developer shall be entitled to repay the
entire Bridge Loan or such part thereof as Developer elects, including accrued interest
thereon, as a priority payment out of funds available from any or all of the following:
(i) the Net Proceeds of the Construction or Permanent Loan; (ii) the Net Proceeds of
the Agency Loan; (iii) the net Tax Credit Sale Proceeds; and/or (iv) from twenty five
percent (25%) of Net Cash Flow after payment of Debt Service and after payment of
debt service of the Capital Improvement Loan and Negative Cash Flow Loan. From
and after the date the Seller Financing Loan is paid off in full or otherwise satisfied,
one-half 0 /2) of the fifty percent (50%) of the Net Cash Flow after payment of Debt
Service that otherwise would have been used to make payment on the Seller
Financing Loan shall instead be paid to K&B on the Bridge Loan after payment of debt
service of the Capital Improvement Loan and Negative Cash Flow Loan. The Bridge
Loan shall be secured by the Project by security documents in form and substance
satisfactory to K&B, which security documents shall be a Lien on the Project, subject
and subordinate only to: (i) the Construction or Permanent Loans when funded, (ii) the
Seller Financing Loan, (iii) the Agency Loan, (iv) the Restrictive Covenants provided
for by this Agreement and (v) such Regulatory Agreements as are required to obtain
the Tax Credits. The Bridge Loan, plus accrued and unpaid interest thereon shall be
all due and payable not more than fifteen (15) years from the initial funding of the
Bridge Loan. Payments on the Bridge Loan shall first be applied to accrued interest and
the remainder to principal. The security documents for the Bridge Loan shall be
SJCOPA. KB
091995
16
subordinate to the Agency Security Documents.
e. Purpose of 'Developer Loan. The Developer Loan is to facilitate
refinancing of the Construction Loan and Bridge Loan to the extent Net Proceeds of
the Permanent Loan and Tax Credit Sale Proceeds are insufficient to pay in full the
Construction Loan and the Bridge Loan. The Developer may obtain the Developer
Loan from K&B upon funding of the Permanent Loan and Tax Credit Sale Proceeds.
f. Amount of Developer Loan. The Developer Loan shall not exceed
the amount of the Construction Loan and the Bridge Loan, and shall be reduced by the
Net Proceeds of the Permanent Loan and Tax Credit Sale Proceeds.
g. Developer Loan Terms. The Developer Loan shall bear the same
ten percent 0 0%) interest rate and have the same payment provisions from Net Cash
Flow, after payment of Debt Service, the Seller Financing Loan, Capital Improvement
Loan and Negative Cash Flow Loan, as the Bridge Loan which it replaces, with
payments on the Developer Loan to first be applied to interest and then to principal,
provided that in no event shall additional interest be earned on unpaid interest which
has accrued. The term 'of the Developer Loan shall be fifteen 0 5) years from initial
funding, or if longer, the shortest term permitted by the Lender making the.Permanent
Loan. The Developer Loan shall be secured by the Project by security documents in
form and substance satisfactory to K&B, which security documents shall be a Lien on
the Project and shall be subject and subordinate only to (i) the Permanent Loan, (ii) the
Seller Financing Loan, (iii) the Agency Loan, (iv) the Restrictive Covenants provided
by this Agreement, and (v) such Regulatory Agreements as are required to obtain the
Tax Credits.
3.4 Construction Loan. Developer shall at anytime have the right to obtain
a Construction Loan for the Project which Construction Loan shall have the following
terms:
SJCOPA.KB
091995
(i) the original principal amount (not including interest that may
accrue thereon) shall not exceed 90% of Project Cost;
(ii) the interest on the unpaid principal amount shall not exceed the
Lender's prime rate of interest, or the equivalent thereof, plus
three points (exclusive of late charges, penalties and fees in case
of default);
(iii) the term of the Construction Loan shall be for at least fourteen
(14) months (exclusive of the Lender's right to accelerate the
maturity in the event of a default);
(iv) the Construction Loan shall be secured by a first Lien on the
17
Project, which first Lien shall be in the form and substance as
required by the Construction Loan Lender; and
(v) the Construction Loan shall have such other terms and conditions
as are required by Lender making the Construction Loan.
3.5 Permanent Loan. Developer shall at any time have the right to obtain a
Permanent Loan, the Net Proceeds of which shall first be used to pay the Construction
Loan in full. The Permanent Loan shall have the following terms:
(i) the original principal balance (exclusive of any interest accrued
thereon) shall be not more than 90% of the fair market value of
the Project as determined by the Lender making the Permanent
Loan;
(ii) the unpaid principal balance shall earn interest at a rate not to
exceed ten percent (10%) per annum (exclusive of late charges,
penalties or fees if in default);
(iii) the net operating income of the Project, as defined by the Lender
making the Permanent Loan, will be equal to at least 1.1 times the
scheduled debt service of the Permanent Loan;
(iv) the term of the Permanent Loan shall be for at least one hundred
eighty (180) months (exclusive of the Lender's right to accelerate
the maturity in the event of a default);
(v) the Permanent Loan shall be amortized over a period of not less
than fifteen (15) years, provided however that the term of the
Permanent Loan may expire prior to the full amortization of the
Permanent Loan with a lump sum payment for the unpaid principal
balance due at its maturity;
NO the Permanent Loan shall be secured by a first Lien on the Project,
which first Lien shall be in the form and substance as required by
the Permanent Loan Lender; and
(vii) the Permanent Loan shall have such additional terms and
conditions as are required by the Lender making the Permanent
Loan.
3.6 Loans for Negative Cash Flow and Future Capital Improvements.
Developer shall at any time after issuance of the Certificate of Completion have the
right to obtain a Loan or Loans to finance Negative Cash Flow or capital improvements
to be made to the Project. Said Loans shall have the following terms:
SJCOPA.KB
091995
18
a. The Loans may be secured by a Lien prior in right to the Lien securing
the Agency Loan;
b. The Loans may be in such amounts as are required to finance any
Negative Cash Flow or to make such capital improvements;
c. The Loans shall bear interest and contain such terms as the Lender
may require;
d. The maximum debt service on said Loans shall be as the Lender
making such Loan requires;
e. The principal amount of said Loans shall not exceed a maximum
of $100,000 per calendar year; and
f. Funds may not be drawn on said Loans until the reserves set aside
for the Project by Developer have first been expended (excluding any reserves required
to be maintained by any existing Mortgagee).
3.7 Refinancing of Loans. Developer shall have the right to refinance any of
the Loans hereinabove provided for on such terms and conditions, including but not
limited to amounts of the Loans, as it deems in the best interests of the Project,
including increasing the amounts of any such Loans, provided that, except for the
refinancing of a Mature Loan as hereinafter provided for, (i) the principal amount of
a refinancing Loan shall not exceed the outstanding balance of the Loan(s) to be
refinanced, plus costs and expenses of refinancing (including but not limited to
reasonable and customary brokerage and loan fees, prepayment fees, title and escrow
fees, recording fees and attorney fees), and (ii) the aggregate debt service on all
outstanding Loans secured by the Project and prior in right to the Agency Loan may
not exceed the maximum debt service ("Permitted Debt Service") on all aggregate of
the Loans permitted pursuant to Paragraphs 3.2, 3.4 or 3.5 and 3.6. The
determination of the Permitted Debt Service shall be based on the maximum debt
service on the Loans as provided in Paragraphs 3.4 or 3.5 and 3.6, inclusive, rather
than as the actual debt service on such Loans in place, and the actual debt service of
the Loan specified in Paragraph 3.2 at the time of refinancing; provided, however, that
in no event shall the net operating income of the Project as defined by the Lender
refinancing the Loan specified in Paragraph 3.5 or other Loan(s) to which the Agency
Loan is subordinate, be less than 1.1 times the scheduled debt service of such
refinancing loan. Notwithstanding anything contained herein to the contrary, in the
event that any Loan is due and payable (a "Mature Loan"), Developer shall have the
right to refinance the Mature Loan, without regard to the foregoing limitations, with
a new Loan ("Replacement Loan") on the best terms and conditions available to
Developer (without Developer's having any personal liability for the repayment thereof)
in the market place existing as of a period from one hundred twenty (120) to sixty
(60) days prior to the Mature Loan's maturity (as said maturity may be accelerated by
SJCOPA. KB
091995
19
a default thereon) and the debt service on said Loan shall be included in Debt Service.
As used herein "best terms and conditions available" shall mean the lowest interest
rate available and the longest amortization schedule available. If there is a conflict
between the lowest interest rate and the longest amortization schedule, Developer
shall select the combination of interest rate and amortization schedule so as to yield
the lowest annual debt service on the Replacement Loan (not including any balloon
payment due at maturity). The maximum principal amount of the Replacement Loan
shall not without Agency's prior written consent exceed the amount required to pay
the Mature Loan in full and the costs and expenses to obtain the Replacement Loan,
including, but not limited to, reasonable and customary commitment fees, points,
attorneys' fees, brokers' fees, finders' fees, closing costs, title insurance fees and
fees and charges assessed by the Lender making the Replacement Loan for making
the Replacement Loan.
3.8 Agency Financial Assistance for the Promect.
a. Agency Loan. Subject to the terms and conditions set forth herein,
Agency shall loan to Developer the amount of One Million Five Hundred Fifty
Thousand Dollars ($1,550,000). The funding of the Agency Loan by the Agency shall
be One Hundred Fifty Five Thousand Dollars ($155,000) upon commencement of
construction of the Project (including grading), with the remainder to be disbursed in
accordance with the schedule (the "Funding Schedule") attached hereto an Exhibit I
and incorporated herein by reference.
b. Closing Agency Loan. On or before commencement of
construction of the Project, Developer shall execute the Agency Note and the Agency
Security Documents, and deposit said documents with Commonwealth Land Title
Company ("Title Company") at 888 W. 6th Street, Fourth Floor, Los Angeles,
California 90071, as escrow agent, with instructions to deliver the Agency Note to
the Agency and record said Agency Security Documents in the official records of the
County where the Property is located after the recordation of the Lien's securing the
Construction Loan and the Seller Financing Loan. Immediately upon making said
deposits into escrow, Developer shall so notify the Agency. Developer and the
Agency shall cooperate and execute such escrow instructions consistent with this
Agreement as may be required by the Title Company, the escrow agent, to
accomplish the foregoing. Developer shall pay the costs of the escrow.
C. Terms of Agency Loan. The unpaid principal balance of the
Agency Loan shall bear interest at the rate of five percent (5%) per annum, and be
payable out of twenty five percent (25%) of the Net Cash Flow after payment of
Debt Service and after payment of debt service of the Capital Improvement Loan and
Negative Cash Flow Loan, with payments thereon first applied to interest accrued and
the remainder to principal. Said payments shall be made on a calendar year basis with
the first payment due at the end of the first calendar year in which there is Net Cash
Flow after payment of Debt Service. From and after the date the Seller Financing
SJCOPA.KB
091995
20
Loan is paid off in full or otherwise satisfied, one-half (1 /2) of the fifty percent (50%)
of the Net Cash Flow after payment of Debt Service that otherwise would have been
used to make payment on the Seller Financing Loan shall instead be paid to the
Agency on the Agency Loan after payment of debt service of the Capital Improvement
Loan and Negative Cash Flow Loan. The Agency Loan may be prepaid at anytime
without premium or penalty and neither the Developer nor any partner, successor or
assign shall have any personal liability for the repayment of the Agency Loan. If not
sooner paid, the unpaid principal and accrued interest of the Agency Loan shall be due
and payable three hundred sixty (360) months from the date of funding the Agency
Loan and recording of the Agency Security Documents, or if longer, the shortest term
permitted by the Lender making the original Permanent Loan. The remaining terms of
the Agency Loan are set forth in the Agency Note and the Agency Security
Documents the forms of which are attached hereto -as Exhibits A, B and C.
d. Subordination of Agency Loan. The Agency Security Documents
shall be subject and subordinate to: (i) Liens securing the Construction Loan,
Permanent Loan, the Seller Financing Loan, Capital Improvement Loans, Negative
Cash Flow Loans and the Loans refinancing any of said Loans, (ii) the Restrictive
Covenants provided by this Agreement, and (iii) such Regulatory Agreements as may
be required to obtain the Tax Credits. Agency agrees from time to time upon written
request of Developer to execute and acknowledge such documents and instruments
in form and substance reasonably required by any Lender making any Loans to cause
the subordination of the Agency Loan to any such Loan, including without limitation
the subordination provisions required by this Agreement and Exhibit J hereto. The
Title Company shall issue to the Agency a standard ALTA lender's policy of title
insurance insuring the priority of the Agency Security Documents subject to the Liens
herein provided for, with coverage in the principal amount of the Agency Note and
Developer shall pay the premium for the title insurance policy upon the funding of the
Agency Loan. In the event that the Agency shall fail to fund any portion of the
Agency Loan in accordance with this Agreement and the Funding Schedule, the
restrictions set forth in Paragraph 4.2 hereto shall automatically terminate.
e. No Federafly Subsidized Financing. The Agency represents and
warrants to Developer that none of the funds constituting the Agency Loan shall
directly or indirectly be federally subsidized, including but not limited to being obtained
by the Agency through the sale of tax exempt bonds or have an ultimate source from
tax-exempt bond proceeds or a federal loan with a below-market interest rate, within
the meaning of the provisions and limitations of the Internal Revenue Code Section
42 and the rules and regulations thereof.
f. Agency Acknowledgement. The Agency acknowledges and agrees
that the Project will be operated subject to and in compliance with the requirements
of Subparagraphs 4.1 and 4.2 hereof and Section 42 of the Internal Revenue Code
of 1986, as amended and the rules and regulations promulgated thereunder, with
substantially restricted rents, which will have a substantial adverse effect on the Net
SJCOPA.KB
091995
21
Cash Flow and the repayment of the Agency loan. The Agency agrees to make the
Agency Loan notwithstanding the probability of such an adverse impact on the
repayment of the Agency Loan.
g. Conditions Precedent to Disbursement of Agency Loan Proceeds.
The Agency shall disburse the required portions of the Agency Loan proceeds in the
amounts set forth in Paragraph 3.8a and in accordance with the Funding Schedule
(Exhibit 1) and, subject to the requirements of this Paragraph 3.8g. No disbursement
of the Agency Loan shall be made until all of the following conditions precedent are
satisfied to the satisfaction of the Agency:
(i) Execution ,and Delivery of Documents. Developer shall have
executed and delivered into escrow the Agency Note, the Agency Security
Documents, the Restrictive Covenants, and any other documents and instruments
required to be executed and delivered, all in form and substance satisfactory to the
Agency.
(ii) Insurance. Developer shall have furnished the Agency with proper
evidence of the insurance coverage required in accordance with Article 6 of this
Agreement:
(iii) Title to Land. The Agency is reasonably satisfied that upon the
close of escrow Developer shall have good and marketable fee title to the Property
and there will exist thereon or with respect thereto no mortgage, lien, pledge or other
encumbrance of any character whatsoever other than liens for current real property
taxes and assessments not yet due and payable, the deeds of trust approved by the
Agency and any other matters approved in writing by the Agency. In furtherance of
this provision, upon issuance of a preliminary title report and the title insurance policy
pursuant hereto, Developer shall submit copies thereof to the Agency.
(iv) Project Approvals. Except for the initial disbursement, the
Developer shall have obtained any and all Project Approvals for the development of
the Project on the Property.
(v) Title Insurance. The Title Company is prepared at the close of
escrow to issue or cause the issuance to the Agency the American Land Title
Association policy of lender's title insurance required in accordance with subparagraph
3.8(d) with mechanic's lien coverage, together with such endorsements as the
Agency may require, which shall insure the Agency Security Documents as a lien upon
the Property subject only to the items specified in subparagraph 3.8(c) above.
NO Priority of Restrictive Covenants. The Restrictive Covenants have
been executed and the escrow agent is prepared to record the Restrictive Covenants
at the close of escrow, and such Restrictive Covenants shall be subordinate to the lien
of the Construction Loan, the Permanent Loan, the Seller Financing Loan and the
SJCOPA.KB
091995
22
Regulatory Agreement and shall be prior and superior to all other liens and
encumbrances of record with respect to the Property.
(vii) Environmental Report. Developer shall have provided the Agency
with a "Phase 1 " Environmental Report as required by Paragraph 2.2 hereof, and has
completed any remediation of the Property as required by that Paragraph.
(viii) Plans and Specifications. Except for the initial disbursement,
Developer shall have submitted to the Agency and the Agency shall have approved
the Construction Plans for the Construction of the Project. Such approval of Agency
shall not relieve Developer's obligation to obtain any and all permits and approvals
required by the Agency or other governmental agency for the Construction of the
Project, including without limitation, building permits, plans and specifications. As
used in this Agreement, "Construction Plans" shall mean all construction
documentation upon which the Developer and Contractor shall rely in undertaking the
Construction of the Project (including landscaping, parking and common areas) and
shall include without limitation final architectural drawings, landscaping plans and
specifications, final elevations, building plans and specifications (also known as
"working drawings") and a time schedule for Construction of the Project.
(ix) No Default. There shall exist no condition, event or act which
would constitute a default (as defined in Paragraph 14.1) hereunder or which, upon
the giving of notice or the passage of time, or both, would constitute a default.
(x) Environmental Compliance. All federal, state and local
environmental requirements applicable to the Project, including without limitation, the
California Environmental Quality Act California Public Resources Code Section 21000
et seq. have been satisfied.
(xi) representations and Warranties. All representations and
warranties of Developer herein contained shall be true and correct.
3.9 'Limitation on Financing -Restrictions. The foregoing restrictions and
limitations on financing set forth in Paragraphs 3.2, 3.3, 3.4, 3.5, 3.6 and 3.7 of this
Article and the definitions relating thereto shall only apply so long as the Agency Loan
remains outstanding. Notwithstanding anything contained in this Agreement to the
contrary, no restrictions shall apply to any Loan which is subordinate to the Agency
Loan.
ARTICLE 4. RESTRICTED UNITS AND TAX CREDIT PROGRAM
4.1 Low -Income Housing Tax Credit Program.
a. Qualification for Tax Credits. Developer proposes to qualify the
Project for and participate in the low-income housing tax credit program authorized
SJCOPA. KB
091995
23
pursuant to Internal Revenue Code of 1986, as amended Section 42, California Health
and Safety Code Sections 50199.6-50199.19, California Revenue and Taxation Code
Sections 17057.5, 17058, 23610.4, and 23610.5, and applicable federal and State
regulations such as 4 California Code of Regulations Sections 1 0300-1 0340
(collectively, the "Low -Income Housing Tax Credit Program"). Developer agrees to
submit to the Agency all of the following documents upon receipt by Developer:
(i) A copy of the Regulatory Agreement, if required, between the
Tax Credit Allocation Committee and Developer (4 California Code
of Regulations §10340(c)).
Copies of all correspondence or transmittals from the Tax
Allocation Credit Committee or other jurisdiction (such as the
Internal Revenue Service) containing any notification regarding the
Project's noncompliance with applicable provisions of the
Low -Income Housing Tax Credit Program.
4.2 Restricted Units. The Restricted Units shall be restricted with respect to
occupancy and rents as herein provided, and as more particularly described in the
Restrictive Covenants Affecting Real Property in the form attached as Exhibit F hereto,
which Restrictive Covenants shall be recorded against the Property within the time set
forth in the Schedule of Performance.
a. Very Low Income Households. Eighteen (18) of the Restricted
Units shall be held for occupancy at Affordable Rents for Senior Citizens who are Very
Low Income Households. For purposes of this Subparagraph, a Restricted Unit
occupied by a Very Low Income Household who at the commencement of the term
of occupancy is a Very Low Income Household shall be treated as occupied by such
household as provided in the Restrictive Covenants. Moreover, a Restricted Unit
previously occupied by a Very Low Income Household and then vacated shall be
considered occupied by a Very Low Income Household until reoccupied, at which time
the character of the Restricted Unit shall be redetermined.
b. Qualified Low Income Households. The remaining seventy four
(74) Restricted Units shall be held for occupancy at Affordable Rents for Senior
Citizens who are Qualified Lower Income Households (exclusive of one unit for on-site
management and maintenance personnel). For purposes of this Subparagraph, a
Restricted Unit occupied by a Qualified Lower Income Household who at the
commencement of the term of occupancy is a Qualified Lower Income Household shall
be treated as occupied by such household as provided in the Restrictive Covenants.
Moreover, a Restricted Unit previously occupied by a Qualified Lower Income
Household and then vacated shall be considered occupied by a Qualified Lower
Income Household until reoccupied, at which time the character of the Restricted Unit
shall be redetermined.
SJCOPA.KB
091995
24
C. Determination of Income Eligibilit . Prior to renting a Restricted
Unit, Developer shall obtain and maintain on file an income certification from each
tenant household for such unit. In determining income eligibility for a particular
Restricted Unit, Developer shall be entitled to rely upon the documentation provided
by the prospective tenant as required pursuant to the Low -Income Housing Tax Credit
Program procedures for determining household income eligibility. Developer shall not
be required to do further investigations into the household income than are required
pursuant to the Low -Income Housing Tax Credit Program requirements. The
Developer shall provide to the Agency such additional tenant income certification or
additional tenant income information as the Agency may reasonable require.
d. Compliance with Regulatory Agreement Records and Repo
Requirements. Developer agrees to perform all of Developer's obligations under the
Regulatory Agreement between the California Tax Credit Allocation Committee and
Developer (4 California Code of Regulations §10340(c)).
e. Term of Restricted Units. The obligations of Developer under this
Subparagraph 4.2 shall terminate fifty seven (57) years from the issuance of the
Certificate of Completion.
4.3 Tax Credit Sale. Developer shall use its best efforts to sell Tax Credits
available to it with the right to retain up to one percent (1 %) of the Tax Credits for
its general partner. Developer shall use the Tax Credit Sale Proceeds in the following
order: (i) first, to pay the Construction Loan to the extent not paid by the Permanent
Loan, (ii) second, to establish such reserves as the Developer in its sole discretion
deems prudent or required, (iii) third, to payoff the Bridge Loan to the extent that
funds are available, (iv) fourth, the pay off or reduce the Seller Financing Loan to the
extent that funds are available, and (v) fifth, use such remaining funds as it, in its sole
discretion, may elect that funds are available. Developer shall have the right to
reverse the order of priorities of items (iii) and (iv) above at its sole discretion.
ARTICLE 5. CONDITIONS OF DEVELOPER OBLIGATIONS
5.1 Developer Conditions. The obligations of Developer under this Agreement,
in addition to the provisions hereof, are expressly conditioned upon and subject to the
following: (a) the issuance of the Density Bonus Permit to Developer pursuant to the
application by Developer or on terms and conditions otherwise approved in writing by
Developer, and (b) the acquisition of fee title to the Property by Developer pursuant
to the option agreement held by Developer or such terms and conditions otherwise
agreed in writing by Developer.
ARTICLE 6. INSURANCE; INDEMNIFICATION
6.1 Commercial. General Liability, Workers' Compensation, and Builders Risk
Insurance.
SJCOPA.KB
091995
25
a. Liability Insurance. Prior to commencing construction of the
Project, Developer shall furnish or cause to be furnished to the Agency evidence,
reasonably satisfactory to the Agency of commercial general liability insurance
coverage for the Property and the Project and Developer's activities thereon, including
products, completed operations, contractual, bodily injury, personal injury, and
property damage in the amount of at least One Million Dollars ($1,000,000) combined
single limits, and naming the Agency as an additional insured with respect to the
Property and the Project except as caused by the acts or omissions of the Agency.
In addition, all such insurance:
(i) shall be primary insurance for the Property and the Project
and not contributory with any other insurance which the
Agency, may have other than for their own acts and
omissions;
(ii) shall be "per occurrence" rather than "claims made"
insurance;
(iii) shall provide that the policy will not be cancelled or limited
in scope by the insurer unless there is a minimum of thirty
(30) days prior written notice by certified mail, return
receipt requested to the Agency; and
(iv) shall be written by a California licensed insurer with a Best
rating of not less than B+, Class X.
b. Worker's Compensation Insurance. Developer shall also furnish
or cause to be furnished prior to commencement of construction work on the Project
to the Agency evidence reasonably satisfactory to the Agency that Developer and any
contractor with whom Developer has contracted for the performance of work on and
around the Property have current Workers' Compensation insurance as required by the
State of California Labor Code as well as Employer's Liability Coverage of not less
than One Million Dollars ($1,000,000) per accident. Such insurance shall be endorsed
to include a waiver of subrogation rights against the Agency.
C. Hazard Insurance. Prior to commencement of any construction
work on the Project, Developer shall furnish to the Agency evidence reasonably
satisfactory to the Agency property damage insurance which shall be maintained in
force throughout the course of development of the Project on the Property. Such
coverage shall include limits sufficient to cover 100% of the replacement cost of
improvements and betterments and shall include the Agency as a loss payee under a
mortgagee endorsement subject to the rights of any Mortgagees prior in right to the
Agency. Furthermore, such coverage shall provide that the policy cannot be cancelled
without a minimum of thirty (30) days prior written notice by certified mail, return
receipt requested to the Agency. Such policy shall be written by a California licensed
SJCOPA.KB
091995
26
insurer with a Best rating of not less than B+, Class X.
The foregoing obligations shall remain in effect until the Agency Loan is
paid in full.
Developer shall have the right at all times to obtain insurance, as a
Project Cost or Operating Expense, which is more extensive than set forth above,
including obtaining earthquake insurance for the Project in the sole discretion of
Developer.
d. Additional Remedies. In addition to any other remedies Agency may have
if Developer fails to provide or maintain any insurance policies or policy endorsements
to the extent and within the time herein required, Agency may, at its sole option:
(1) Obtain such insurance and deduct and retain the
amount of the premiums for such insurance from the Agency Loan.
(2) Withhold any disbursement of the Agency Loan until
Developer demonstrates compliance with the requirements hereof.
(3) In the event Developer has failed to commence curing
such default within ten (10) days of notice from the Agency or thereafter fails
to diligently pursue such cure, declare the Developer to be in default, terminate
this Agreement and declare the Agency Note due and payable.
Exercise of any of the above remedies, however, is an alternative
to other remedies Agency may have and is not the exclusive remedy for Developer's
failure to maintain insurance or secure appropriate endorsements. Nothing herein
contained shall be construed as limiting in any way the extent to which Developer
may be held responsible for payments of damages to persons or property resulting
from Developer's performance of the work covered under this Agreement.
6.2 Indemnification for Construction Activities. Developer agrees to and shall
indemnify, defend, and hold harmless the Agency from and against all liability, loss,
damage, costs, and expenses (including reasonable attorney's fees and litigation and
defense costs) arising from or as a result of the death or injury of any person or any
accident, injury, loss, or damage (whether or not covered by insurance) caused to any
person or to the property of any person which is caused or alleged to have been
caused by the (1) actions or operations of or any errors or omissions of Developer or
any of its agents, servants, employees, or contractors in developing the Project,
whether or not such liability, loss, damage, costs, or expenses are covered by
insurance or (2) approval and implementation of this Agreement provided however
that such indemnification shall not extend to the negligence or malfeasance of the
Agency or its representatives.
SJCOPA.KB
091995
27
ARTICLE 7. INSPECTION
For the purpose of assuring compliance with this Agreement, representatives
of the Agency shall have the reasonable right of access to the Project and the books
and records of Developer pertaining to the Project, upon at least twenty-four (24)
hours prior notice to Developer, during normal business hours during the term of this
Agreement, including but not limited to the inspection of the work being performed
by Developer in constructing the Project and the books and records for determining
the Project Cost and the Net Cash Flow. Such representatives of the Agency shall be
those who are so identified in writing to Developer by the Agency. The Agency shall
indemnify, defend, and hold harmless Developer and Developer's partners, officers,
employees, and agents from any damage caused or liability arising out of the
negligence or willful acts or omissions of the Agency; its officers, officials, employees,
volunteers, agents, or representatives in their exercise of this right of access and
inspection; provided that it is understood that the Agency does not by this Article
assume any responsibility or liability for a negligent inspection or failure to inspect.
ARTICLE 8. FORCED DELAY; EXTENSION OF TIME
In addition to specific provisions of this Agreement, performance by Developer
hereunder shall not be deemed to be in default and Developer shall be entitled to an
extension of time to perform its obligations hereunder where delays in performance
are due to causes beyond the control and without the fault of Developer, including as
applicable: war; insurrection; strikes; lockouts; riots; floods; earthquakes; fires;
casualties; supernatural causes; acts of the public enemy; epidemics; quarantine
restrictions; freight embargoes; lack of transportation; governmental restrictions or
priority; litigation; unusually severe weather; inability to secure necessary labor,
materials or tools; delays of any contractor, subcontractor or supplies; acts or
omissions of the other party or any third party; acts or the failure to act of the Agency
or any other public or governmental agency or entity (except that any act or failure
to act by the Agency shall not excuse performance by the Agency).
ARTICLE 9. REPRESENTATIONS AND WARRANTIES
Developer and each person executing this Agreement on behalf of Developer
represents and warrants that: (i) Developer is a limited partnership organized and
existing under the laws of the State of California, in good standing, and authorized to
do business and doing. business in the State of California; (ii) Developer has all
requisite power and authority to carry out its business as now and whenever
conducted and to enter into and perform its obligations under this Agreement; (iii) by
proper action of Developer, Developer's signatories have been duly authorized to
execute and deliver this Agreement; (iv) the execution of this Agreement by Developer
does not violate any provision of any other agreement to which Developer is a party;
and (v) except as may be specifically set forth in this Agreement, no approvals or
consents not heretofore obtained by Developer are necessary in connection with the
SJCOPA.KB
091995
28
execution of this Agreement by Developer or with the performance by Developer of
its obligations hereunder.
ARTICLE 10. MORTGAGEE PROTECTION
10.1 Developer's Right to Encumber the Prolect. Subject to the limitations in
Article 3, the parties hereto agree that this Agreement shall not prevent or limit
Developer in any manner, at Developer's sole discretion, from encumbering the Project
or any part thereof by any Lien securing financing with respect to the Property. The
Agency acknowledges that the Mortgagees providing such financing may require
certain interpretations and modifications of this Agreement, and the Agency agrees
upon written request, from time to time, to meet with Developer and representatives
of such Mortgagees to negotiate in good faith any such request for interpretation or
modification. The Agency will not unreasonably withhold its consent to any such
requested interpretation or modification provided such interpretation or modification
is consistent with the intent and purposes of this Agreement. Any Mortgagee of the
Property now and hereafter shall be entitled to the following rights and privileges:
a. Preservation of Liens. Neither entering into this Agreement nor a
violation or breach of this Agreement shall defeat, render invalid, diminish or impair
any Lien thereof made in good faith and for value.
b. No Assumption of Obligations by Mortgagee. Any Mortgagee who
comes into possession of the Project, or any part thereof, pursuant to foreclosure of
Lien, or deed in lieu of such foreclosure, shall take the Project, or part thereof, subject
to the terms of this Agreement; provided, however, in no event shall such Mortgagee
be liable for any defaults or monetary obligations of Developer arising prior to
acquisition of title to the Project by such Mortgagee and provided further in no event
shall any such Mortgagee or its successors or assigns be entitled to a building permit
or occupancy certificate until any default under this Agreement has been cured.
10.2 Notice of Default. Before the Agency may resort to any remedy provided
for in Article 14 hereof, the Agency must give (i) written notice of the default or
breach (the "Initial Default Notice") and (ii) written notice of the failure of the
Developer to cure the default or breach (the "Second Default Notice") to each
Mortgagee concurrent with transmittal of such notices to Developer and afford each
Mortgagee the opportunity after service of such Second Default Notice to:
a. Monetary Default. Cure the breach or default within thirty (30)
days after service on each Mortgagee of the Second Default Notice where the default
can be cured by the payment of money to the Agency or some other person;
b. Non Monetary Default. Commence to cure the breach or default
within sixty (60) days after service on each Mortgagee of the Second Default Notice
where the breach or default must be cured by something other than the payment of
SJCOPA.KB
091995
W
money and can be cured within that time; or
C. Extended Richt to Cure Non Monetary Default. Cure the breach
or default in such reasonable time as may be required where something other than the
payment of money is required to cure the breach or default and cannot be reasonably
performed within sixty (60) days after service on each Mortgagee of the Second
Default Notice provided that acts to cure the breach or default are commenced within
that time period after service of the Second Default Notice on each Mortgagee by the
Agency and are thereafter diligently continued by such Mortgagee.
10.3 Foreclosure in Lieu of Curing Default. Notwithstanding any other
provision of this Agreement, a Mortgagee may forestall any remedy of the Agency for
a default under or breach of this Agreement by Developer by commencing proceedings
to foreclose any Lien. The proceedings so commenced may be for foreclosure of any
such Lien by order of court or for foreclosure of any such Lien under a power of sale
contained in the Lien. The proceedings shall not, however, forestall the Agency's
right to execute any remedy or right under this Agreement for the default or breach
by Developer unless: (i) they are commenced within sixty (60) days after service on
each Mortgagee of the Second Default Notice; and (ii) they are, after having been
commenced, diligently pursued in the manner provided by law.
10.4 Assignment Without Consent on Foreclosure. The consent of the
Agency shall not be required for transfer of Developer's right, title and interest in the
Project or this Agreement to:
a. any purchaser, which includes a Mortgagee, at a foreclosure sale
of the Lien, whether the foreclosure is conducted pursuant to court order or pursuant
to a power of sale in the instrument creating the Lien; or
b. A purchaser from a Mortgagee after foreclosure where a
Mortgagee was the purchaser of Developer's interest at the foreclosure sale of the
Lien, or acquired Developer's interest by transfer in lieu of foreclosure.
10.5 Mortgagee as Including Subsequent _Security Holders. The term
"Mortgagee" as used in this Article shall mean not only the person, persons or entity
that loaned money to Developer and is named as beneficiary, mortgagee, secured
party or security holder in the instrument creating any Lien, but also all subsequent
assignees and holders of the instrument and interest secured by such instrument who
give written notice to the Agency setting forth the name and address of the
transferee.
10.6 Estoppel Certificates. The Agency shall provide to any Mortgagee, on
request, an estoppel certificate certifying to such matters as to the continuation of
this Agreement as being in full force and effect, the satisfaction of the terms and
conditions of this Agreement and the existence of any defaults hereunder, if any.
SJCOPA.KB
091995
30
10.7 Amendments. The Agency shall cooperate in including in this Agreement
by suitable amendment from time to time any provision which may reasonably be
requested by any proposed or existing Mortgagee for the purpose of implementing the
mortgagee -protection provisions contained in this Article and allowing such Mortgagee
reasonable means to protect or preserve any Lien on the occurrence of a default under
the terms of this Agreement. The Agency agrees to execute and deliver (and to
acknowledge, if necessary, for recording purposes) any agreement necessary to effect
any such amendment consistent with the terms and conditions of this Agreement and
the parties' interest in entering into this Agreement. Any modification or amendment
of this Agreement shall require the prior written consent of each Mortgagee.
10.8 Special Provisions for Permanent Loan Affecting the Restrictive
Covenants and this Agreement and for Subordination of Agency Loan to Permanent
Loan. The Agency agrees that, in addition to all the Mortgagee protection provisions
hereinabove, the following additional provisions shall be applicable to any Permanent
Loan or refinancing thereof which is funded to Developer on or after completion of
construction of the Project and issuance of the Certificate of Completion by the
Agency, and which provisions shall apply in favor of the Lender, Mortgagee or other
holder of the Permanent Loan or refinancing thereof, and their successors and assigns
in interest (the "Permanent Lender"), including without limitation the Federal National
Mortgage Association ("Fannie Mae"):
a. Indemnification. Neither the Permanent Lender nor any successor
in interest to the Permanent Lender will assume or take subject to any liability for the
indemnification obligations of the Developer under the Restrictive Covenants or this
Agreement for acts or omissions of the Developer prior to any transfer of title to the
Project to the Permanent Lender, whether by foreclosure, deed in lieu of foreclosure
or conversion of the Permanent Loan, and further the Developer must remain liable
under the indemnification provisions of the Restrictive Covenants and this Agreement
for its actions and omissions prior to any transfer of title to the Permanent Lender.
The Permanent Lender will agree to indemnify the Agency but only for acts and
omissions of the Permanent Lender which occur following acquisition of the Project
by the Permanent Lender and occurring during the period of the Permanent Lender's
ownership and operation of the Project, whether such acquisition is by foreclosure,
deed in lieu of foreclosure or comparable conversion of the Permanent Loan.
b. Sale or Transfer. No restrictions on sale or transfer of the Project
shall apply to any transfer of title to the Project to the Permanent Lender by
foreclosure, deed in lieu of foreclosure or comparable conversion of the Permanent
Loan. No transfer of the Project may operate to release the Developer from its
obligations under the Restrictive Covenants or this Agreement arising prior to such
transfer. Nothing contained in the Restrictive Covenants or this Agreement may
affect any provision of the Permanent Loan or any Permanent Loan document which
requires the Developer to obtain the consent of the holder of the Permanent Loan as
a precondition to sale, transfer or other disposition of the Project.
SJCOPA.KB
091995
31
C. Termination. The Permanent Lender shall have the right to
terminate the Restrictive Covenants and this Agreement (if applicable) in the event of
an involuntary noncompliance with the provisions of the Restrictive Covenants or this
Agreement caused by foreclosure of the lien of the Permanent Loan, delivery of a deed
in lieu of foreclosure or comparable conversion of the Permanent Loan, fire, seizure,
requisition, change in a federal law, or an action of a federal agency which prevents
the Agency from enforcing the provisions of the Restrictive Covenants or this
Agreement, or condemnation or a similar event, but only if (i) within a reasonable
period thereafter the bonds ("Bonds") issued in connection with the Permanent Loan,
in an aggregate principal amount equal to the Permanent Loan are paid in full and
retired, and further that -the Restrictive Covenants and this Agreement (if applicable)
shall be reinstated if, at any time subsequent to the termination of the Restrictive
Covenants and this Agreement as the result of the foreclosure of the lien of the
Permanent Loan, the delivery of a deed in lieu of foreclosure or comparable conversion
of the Permanent Loan, the Developer or any related person (within the meaning of
Section 1.103-10(e) of the Treasury Regulations) obtains an interest in the Project
which constitutes an ownership interest for federal income tax purposes, or (ii) an
opinion of bond counsel is delivered to the issuer of the Bonds to the effect that such
termination will not adversely affect the exclusion from gross income for federal
income tax purposes of the interest payable on the Bonds.
d. Enforcement. Upon any default by the Developer under the
Restrictive Covenants or this Agreement, the Agency may seek specific performance
of the Restrictive Covenants or this Agreement or enjoin acts which may be unlawful
or in violation of the Restrictive Covenants or this Agreement, but the Agency may
not seek to recover damages from the Developer apart from any claim of
indemnification thereunder.
The obligations of the Developer under the Restrictive Covenants or this Agreement
for the payment of its indemnification obligations may not be secured by or in any
manner constitute a lien on the Project, and no person may have the right to enforce
such indemnification obligations other than directly against the Developer. No
subsequent owner of the Project may be liable or obligated for the breach or default
of any obligation of any prior owner under the Restrictive Covenants or this
Agreement, including, but not limited to, any payment or indemnification obligation.
In addition, promptly upon determining that a violation of the Restrictive Covenants
or this Agreement has occurred, the Agency must, by notice in writing to the
Permanent Lender inform the Permanent Lender that such violation has occurred, the
nature of the violation and that the violation has been cured or has not been cured,
but is curable within a reasonable period of time, or is incurable.
e. Subordination of Agency Loan. Upon request, the Agency shall
execute and deliver to the Permanent Lender for recordation, a subordination
agreement in the form of the Fannie Mae Subordination Agreement attached as Exhibit
SJCOPA. KB
091995
32
J hereto or as may otherwise be required by Fannie Mae, for the subordination of the
Agency Loan to the Permanent Loan.
ARTICLE 11. CERTIFICATE OF COMPLETION
11.1 Certificate of Completion. Upon the satisfactory completion of
construction of the Project, the Agency shall furnish Developer with a final Certificate
of Completion for such work in such form as Exhibit K hereto or as may reasonably
be accepted to Developer upon written request therefor by Developer. Construction
of the Project shall be deemed to have been completed when it has been constructed
in accordance with the Final Plans, as the Final Plans may be amended by agreement
between Developer and the Agency. Such Certificate of Completion shall be in a form
so as to permit recordation in the Office of the Recorder of the County where the
Property is located.
The Certificate of Completion shall be, and shall so state, a conclusive
determination of satisfactory completion of Developer's development obligations under
this Agreement, and of full compliance with the terms of this Agreement relating to
construction of the Project on the Property. Except for the obligation to develop the
Property, the issuance and recordation of the Certificate of Completion shall not limit
the continued enforceability of Developer's obligations relating to the maintenance,
operation and use of the Property or any other obligations in compliance with the
terms of this Agreement and the Restrictive Covenants. The Agency shall not
unreasonably withhold issuance of the Certificate of Completion. If the Agency
refuses or fails to furnish the Certificate of Completion after written request from
Developer, the Agency shall, within ten (10) days after such written request, provide
Developer with a written statement of the reasons the Agency refused or failed to
furnish the Certificate of Completion. The statement shall also contain the Agency's
opinion of the action Developer must take to obtain the Certificate of Completion. If
the reason for such refusal is confined to the immediate availability of specific items
or materials for landscaping, the Agency shall issue its Certificate of Completion upon
the Developer posting a cash deposit with the Agency in one hundred percent (100%)
of an amount representing the fair cost of the work not yet completed.
The Certificate of Completion shall not constitute evidence of compliance
with or satisfaction of any obligation of Developer to any holder of a mortgage or any
insurer of a mortgage on or with respect to the Property. The Certificate of
Completion is not a notice of completion as referred to in California Civil Code Section
3093.
ARTICLE 12. DISCRIMINATION
There shall be no discrimination against, or segregation of, any persons, or
group of persons, on account of race, color, creed, religion, sex, marital status,
ancestry, or national origin in the enjoyment of the Property, nor shall Developer itself,
SJCOPA.KB
091995
33
or any person claiming under or through it, establish or permit any such practice or
practices of discrimination or segregation with reference to the selection, location,
number, use, or occupancy of tenants, lessees, subtenants, sublessees, or vendees
of the Property or any portion thereof. The foregoing covenants shall run with the land
and shall be included in the Restrictive Covenants, as set forth in Exhibit F hereto.
ARTICLE 13. [PURPOSELY LEFT BLANK]
ARTICLE 14. DEFAULTS, REMEDIES, AND TERMINATION
14.1 Defaults -General.
Subject to the extensions of time set forth in Article 8 hereof, failure or
delay by any Developer to perform any term or provision of this Agreement
constitutes a default under this Agreement; provided, however, Developer shall not
be deemed to be in default if (i) Developer cures, correct or remedies such default
within thirty (30) days after receipt of a notice of default, from the party specifying
the default, where the default can be cured by the payment of money to the Agency
or some other person, or (ii) Developer cures, corrects, or remedies such default
within sixty (60) days after receipt of a notice from the party specifying such failure
or delay, where the default must be cured by something other than the payment of
money and can be cured within that time, or (iii) for defaults where something other
than the payment of money is required to cure the default and the default cannot
reasonably be cured, corrected, or remedied within such sixty (60) day period, if
Developer commences to cure, correct, or remedy such failure or delay within such
sixty (60) day period after receipt of a notice from the Party giving notice of said
default specifying such failure or delay, and diligently prosecutes such cure, correction
or remedy to completion.
The Agency claiming a default (the "Notifying Party") shall give written
notice of default to Developer, specifying the default complained of by the Notifying
Party. Copies of any notice of default given to Developer shall also be given to each
Mortgagee. Except as required to protect against further damages, the Notifying Party
may not institute proceedings against Developer in default until the time for cure,
correction, or remedy of a default has expired. Upon the expiration of time to cure the
default of Developer, the Notifying Party shall give written notice to Developer and
each Mortgagee of Developer's failure to cure the default or breach ("Second Default
Notice"). Except as otherwise expressly provided in this Agreement, any failure or
delay by a Party in giving a notice of default or in asserting any of its rights and
remedies as to any default shall not constitute a waiver of any future default.
14.2 Termination by Agency. Subject to the provisions of Articles 8 and 10
hereof, and provided that the Agency is not in default under this Agreement, the
Agency shall have the right to terminate this Agreement upon written notice to
SJCOPA.KB
091995
34
Developer if: (i) Developer shall have failed to obtain any of the Project Approvals
required for construction of the Project as required by this Agreement within the
applicable time set forth in the Schedule of Performance, or (ii) Developer shall have
failed to commence construction of the Project pursuant to a valid building permit or
permits and has not diligently completed such construction as required under this
Agreement within the applicable time set forth in the Schedule of Performance, or (iii)
if Developer shall after the expiration of any applicable grace period herein provided
for be in default under the terms of this Agreement. If such termination occurs after
the Agency has made the Agency Loan, the Agency shall be entitled to an immediate
reimbursement of such funds, together with any interest accrued thereon.
14.3 Legal Actions.
a. Institution of Legal Actions. In addition to any other rights or
remedies, any party may institute legal action to cure, correct, or remedy any default,
to recover damages for any default, or to obtain any other remedy consistent with the
purposes of this Agreement. Such legal actions must be instituted and maintained in
the Superior Court of the County of Orange, State of California, or in any other
appropriate court in that county.
b. Applicable Law. The laws of the State of California shall govern
the interpretation and enforcement of this Agreement.
14.4 Rights and Remedies are Cumulative. Except as otherwise expressly
stated in this Agreement, the rights and remedies of the parties are cumulative, and
the exercise by either party of one or more of its rights or remedies shall not preclude
the exercise by it, at the same or different times, of any other rights or remedies for
the same default or any other default by the other Party.
14.5 Attorney's l=ees. If any Party to this Agreement is required to initiate or
defend litigation in any way connected with this Agreement, the prevailing Party in
such litigation, in addition to any other relief which may be granted, whether legal or
equitable, shall be entitled to reasonable attorney's fees. If any Party to this
Agreement is required to initiate or defend litigation with a third party because of the
violation of any term or provision of this Agreement by the other party, then the Party
so litigating shall be entitled to reasonable attorney's fees from the other Parties to
this Agreement. Attorney's fees shall include attorney's fees on any appeal, and in
addition a Party entitled to attorney's fees shall be entitled to all other reasonable
costs for investigating such action, retaining expert witnesses, taking depositions and
discovery, and all other necessary costs incurred with respect to such litigation. All
such fees shall be deemed to have accrued on commencement of such action and
shall be enforceable whether or not such action is prosecuted to judgment.
SJCOPA. KB
091995
35
ARTICLE 15. INDEMNIFICATION
Developer agrees to indemnify, defend, and hold harmless the Agency and its
respective officers, employees, and agents (collectively, the "Indemnitee") from and
against any and all claims, causes of action, liabilities, and damages arising out of any
acts or omissions of Developer or Developer's partners, officers, employees, and
agents, and arising out of Developer's performance under this Agreement or with
respect to the Property, provided this indemnity shall not extend to any negligence or
willful acts or omissions on the part of any Indemnitee. The Indemnitee shall promptly
notify Developer of the filing of any such action and cooperate with Developer in the
defense thereof (at no cost to Indemnitee). So long as Developer is not in default
under this Paragraph, the Indemnitee shall not compromise the defense of such action
or permit a default judgment to be taken against the Indemnitee without the prior
written approval of Developer, or its successors in interest.
ARTICLE 16. EFFECT OF COVENANTS
The Agency is deemed beneficiary of the terms and provisions of this
Agreement and of the restrictions and covenants running with the land for and in its
own rights and for the purposes of protecting the interests of the community and
other parties, public or private, in whose favor and for whose benefit the covenants
running with the land have been provided. The covenants in favor of the Agency shall
run without regard to whether the Agency has been, remains, or is an owner of any
land or interest therein in the Property.
ARTICLE 17. TERM; RECORDATION; BINDING EFFECT
17.1 Term. The term of the Restrictive Covenants provided for by this
Agreement shall be fifty seven (57) years from the issuance of the Certificate of
Completion, unless extended or earlier terminated.
17.2 Recordation of Restrictive Covenants. Within the time provided in the
Schedule of Performance, the Developer shall cause the Restrictive Covenants
provided for by this Agreement to be recorded in the Official Records of the County
where the Property is located.
17.3 Binding Effect. This Agreement, and the terms and conditions hereof,
shall be binding upon and inure to the benefit of the parties hereto, and their
respective successors and assigns, as provided herein.
ARTICLE 18. GENERAL PROVISIONS.
18.1 Notices and Demands Between the Parties. All notices and demands
between the Agency and Developer shall be in writing and shall be given either by (i)
SJCOPA.KB
091995
36
personal service, (ii) delivery by reputable document delivery service such as Federal
Express that provides a receipt showing date and time of delivery, or (iii) mailing in the
United States mail, certified mail, postage prepaid, return receipt requested, addressed
to:
To Agency: San Juan Capistrano Redevelopment Agency
32400 Paseo Adelanto
San Juan Capistrano, California 92675
Attn: Executive Director
with a copy to: Stradling, Yocca, Carlson & Rauth
600 Newport Center Drive, Suite 1600
Newport Beach, California 92660
Attn: Thomas P. Clark, Jr.
To Developer: San Juan Capistrano Housing Investors, L.P.
c/o- Kaufman and Broad Multi -Housing Group, Inc.
10990 Wilshire Boulevard
7th Floor
Los Angeles, California 90024
Attn: Michael Costa
with a copy to: John Bertero
Kaufman and Broad
5000 Hopyard, Suite 190
Pleasanton, California 94588
Notices personally delivered or delivered by document delivery service shall be deemed
effective upon receipt. Notices mailed shall be deemed effective on the fifth business
day following deposit in the United States mail. Such written notices and demands
shall be sent in the same manner to such other addresses as either party may from
time to time designate by mail.
18.2 Nonliability of Aqencv Officials and Employees; Conflicts of Interest. No
member, official, employee, or contractor of the Agency shall be personally liable to
Developer in the event of any default or breach by the Agency or for any amount
which may become due to Developer or on any obligations under the terms of this
Agreement. No member, official, employee, or agent of the Agency shall have any
direct or indirect interest in this Agreement nor participate in any decision relating to
this Agreement which is prohibited by law.
18.3 No Agency or Partnership. The parties acknowledge that, in entering into
and performing this Agreement, each is acting as an independent entity and not as an
agent of the other in any respect. Nothing contained in this Agreement or in any
SJCOPA.KB
091995
37
document executed in connection herewith shall be construed as making the City or
the Agency joint venturers or partners with the Developer.
18.4 Inter retation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either party by reason of the authorship of this Agreement or any other rule
of construction which might otherwise apply.
18.5 Captions Recitals and Exhibits. The Article, Section and paragraph
captions and headings are for purposes of convenience only, and shall not be
construed to limit or extend the meaning of this Agreement, the text of which shall
control. The Recitals of and the Exhibits to this Agreement are hereby incorporated
into this Agreement.
18.6 Entire Agreement, Waivers and Amendments. This Agreement integrates
all of the terms and conditions mentioned herein, or incidental hereto, and supersedes
all negotiations and previous agreements between the parties with respect to all or
any part of the subject matter hereof. All references herein to this Agreement shall
mean and include the Exhibits hereto unless the context otherwise requires. All
waivers of the provisions of this Agreement must be in writing and signed by the
appropriate authorities of the party to be charged, and all amendments and
modifications hereto must be in writing and signed by the appropriate authorities of
the Agency and Developer.
18.7 Severability. If any term, provision, covenant, or condition of this
Agreement is held by a court of competent jurisdiction to be invalid, void, or
unenforceable, the remainder of this Agreement shall not be affected thereby to the
extent such remaining provisions are not rendered impractical to perform taking into
consideration the purposes of this Agreement. In the event that all or any portion of
this Agreement is found to be unenforceable, this Agreement or that portion which
is found to be unenforceable shall be deemed to be a statement of intention by the
parties; and the parties further agree that in such..event, and to the maximum extent
permitted by law, they shall take all steps necessary to comply with such procedures
or requirements as may be necessary in order to make valid this Agreement or that
portion which is found to be unenforceable.
18.8 Authority of Signators to Bind Principals. The persons executing this
Agreement on behalf of their respective principals represent that they have been
authorized to do so and that they thereby bind the principals to the terms and
conditions of this Agreement.
18.9 Assignment and Transfer.
a. Prohibition. The identity and qualifications of the Developer are of
particular concern to the Agency. It is because of this identity and these
SJCOPA.KB
091995
38
qualifications that the Agency has entered into this Agreement with the Developer.
Except as provided in Articles 3 and 10 of this Agreement, during the term of this
Agreement, no voluntary or involuntary successor in interest of the Developer shall
acquire any rights or powers under this Agreement by assignment or otherwise, nor
shall Developer make any total or partial sale, transfer, conveyance, encumbrance to
secure financing, assignment or lease of the whole or any part of the Property without
the prior written approval of the Agency, except as expressly set forth herein. Any
purported transfer, voluntary or by operation of law, in violation of this Paragraph
18.9 shall constitute a default hereunder and shall be void.
b. Permitted Transfers. Notwithstanding any other provision of this
Agreement to the contrary, Agency approval of an assignment of this Agreement or
conveyance of the Property or any part thereof, shall not be required in connection
with any of the following:
(i) The conveyance or dedication of any portion of the Property to the
City, the Agency or other appropriate governmental agencies, or the granting of
easements or permits to public utilities to facilitate the construction of the Project on
the Property, or
(ii) Subject to the restrictions set forth in the Restrictive Covenants
(Exhibit F), the rental of units in the Project, including the rental of the Restricted
Units to Qualified Lower Income and Very Low Income Households, and the rental of
units to Senior Citizens as provided in the Restrictive Covenants, or
(iii) The encumbering of the Project by Liens and Mortgages as
provided in this Agreement, or
(iv) The transfers described in Article 10 of this Agreement for
Mortgagee protection, or
(v) The replacement of personal property or fixtures.
C. Agency Consideration of Requested Transfer. The Agency agrees that
it will not unreasonably withhold approval of a request made pursuant to this
Paragraph 18.9, provided the Developer delivers written notice to the Agency
requesting such approval. Such notice shall be accompanied by evidence regarding
the proposed assignee's or purchaser's development, operation and management
qualifications and experience and its financial commitments and resources sufficient
to enable the Agency to evaluate the proposed assignee or purchaser pursuant to the
criteria set forth in this Paragraph 18.9 and other criteria as reasonably determined by
the Agency.
Within thirty (30) days after the receipt of the Developer's written notice
requesting Agency approval of an assignment or transfer pursuant to this Paragraph
SJCOPA.KB
091995
39
18.9, the Agency shall respond in writing by stating what further information, if any,
the Agency requires in order to determine the request complete and determine
whether or not to grant the requested approval. Upon receipt of such a response, the
Developer shall promptly furnish to the Agency such further information as may be
requested.
An assignment approved by the Agency pursuant to this subdivision (c)
shall not be effective unless and until the proposed assignee executes and delivers to
the Agency an agreement in form reasonably satisfactory to Agency's legal counsel
assuming the obligations of Developer which have been assigned. Thereafter, the
assigner shall remain responsible to the Agency for performance of the obligations
assumed by the assignee unless the Agency releases the assigner in writing.
d. Successors and Assigns. All of the terms, covenants and conditions of
this Agreement shall be binding upon the Developer and the permitted successors and
assigns of the Developer. Whenever the term "Developer" is used in this Agreement,
such term shall include any other permitted successors and assigns as herein
provided.
e. Changes in Partners. Notwithstanding anything contained to the contrary
in this Agreement, Developer shall have the right to:
(i) Admit additional limited or general partners,
(ii) Permit the initial limited partner to withdraw from the Developer,
and
(iii) Replace the general partner of Developer for cause with another
general partner who, or the principals of which, have substantial
experience in owning or operating apartment projects similar to
the Project.
18.10 Counterparts. This Agreement may be executed in counterparts,
each of which shall be deemed to be an original, and such counterparts shall
constitute one and the same instrument.
18.11 Developer's Affiliates. Nothing in this Agreement shall prevent
Developer from having the right to obtain goods or services for acquisition and
transfer of the Property and for development, operation, and transfer of the Project
thereon from K&B, any subsidiary of Kaufman and Broad Home Corporation, or any
affiliates of any of them, so long as such goods or services are provided at rates
which do not exceed the amounts collectively provided therefor in the Project Budget
or as authorized as an Operating Expense, and to the extent that such goods or
services are not identified in the Project Budget, Project Costs or in Operating
Expenses, such fees shall be at competitive rates based at least 3 bids, provided that
SJCOPA.KB
091995
40
one such bid may be from an affiliate of K&B.
18.12 This Agreement shall be null and void if Developer has not acquired
title to the Property on or before December 31, 1995.
IN WITNESS WHEREOF, the parties hereto have executed this Agreement as
of the Effective Date specified herein.
Date: October 17, 1995
AGENCY:
SAN JUAN CAPISTRANO REDEVELOPMENT
AGENCY,
a public bo corporate doli p
rr'
By:
Name: David Swerdiin
Title: Chairman
APPROVED AS TO FORM:
By:
Juan Capistrano
Agency
DEVELOPER:
SAN JUAN CAPISTRANO HOUSING INVESTORS,
L.P.,
a California limited partnership
By: LINC Housing Corporation,
a California nonprofit corporation,
General a er
Date: p ? By:
Name• f2,J. 16("f' t,
Title: �� ip C--� �--
SJCOPA.KB
091995
41