1992-0601_POCHIROWSKI, WM_Surety Agreement9 0
FOR
THIS AGREEMENT is made by and between the CITY OF SAN JUAN CAPISTRANO,
a municipal corporation, hereinafter referred to as the "City" and William Pochirowski,
owner/builder, referred to as "Developer".
WITNESSETH
WHEREAS, City will issue Grading Permit No.30141 to Developer to construct
certain designated improvements, more particularly described in Exhibit "A" attached
and incorporated herein by reference, which said improvements constitute a portion of
that real property at the location of Tract 10103/Lot 24 commonly referred to as
27712 Highland Drive, San Juan Capistrano, California.
WHEREAS, San Juan Capistrano Municipal Code 8-2.05 requires the posting of
financial security to secure the faithful performance and labor and materials for the
grading and installation of improvements connected with issuance of grading permits.
WHEREAS, San Juan Capistrano Municipal Code 8-2.06 authorizes the Building
Official to require additional bonding as security to ensure against adverse aesthetic
impacts arising from incomplete grading and/or improvements from development
projects which have not been completed.
WHEREAS, the Building Official finds that the proposed project site is highly
prominent and visible to the community, has unique topographic features or involves
substantial grading of slope areas.
NOW, THEREFORE, in consideration of the premises and promises hereinafter
contained, City and Developer agree as follows:
1. Developer's Improvements Obligations. Developer shall, at its sole cost and
expense, provide and furnish all Labor, materials and equipment for the installation of
improvements set forth in Exhibit "A". The grading permit and plans, which further
defines the improvements in Exhibit "A", are on file in the office of the City's Building
Official, and all documents referenced in Exhibit "A" are incorporated herein by
reference.
2. Developer's Security. Developer shall provide a time certificate of deposit
subject to the approval of the City's City Attorney, to secure Developer's improvement
obligations required under this agreement.
The amount of the bond shall be $16,091.00 for that work described in
Exhibit "A". This security of $16,091.00 shall also serve as security for restoration of the
site. A copy of the surety instrument, as approved by the City Attorney, is attached as
Exhibit "D".
3. Completion of Improvements. To ensure the protection of the public safety,
health and welfare, Developer shall construct the improvements described in Exhibit "A"
in accordance with the schedule as set forth in Exhibit "B", and the conditions as set
forth in Exhibit "C".
-1-
Alk An
4. Developer Default. In the event Developer does not complete the required
improvements, including erosion -control measures within the time required, or abandons
the project site, or suspends work for more than twenty working days other than
previously prescribed, City shall have the right to immediately declare a default and to
make demand on the surety for performance.
5. Restoration of Site. San Juan Capistrano Municipal Code Section 8-2.06 allows
the City to require bonding a security to ensure against adverse aesthetic impacts arising
from incompleted grading and/or improvements. The purpose of this bonding shall be to
restore the property to its original condition if the Developer defaults. This restoration
shall include:
Dismantle and/or demolish improvements;
2. Grade property to its original contours as shown on the grading plan
referred to in Exhibit "A";
3. Remove all debris and construction materials from the site; and
4. Install erosion control, including hydroseeding, to the satisfaction of the
Building Official.
6. Attorney's Fees. Developer agrees to pay City such sum as the court may
adjudge as reasonable for the legal services of an attorney representing City in an action
brought to enforce or interpret the obligations of this agreement, and such sum shall be
made a part of any judgment in such action against Developer if such action is
determined in favor of said City.
7. Developer's Work in Safe Condition. Developer shall perform all work in a safe
workmanlike manner and shall take such precautions as may be necessary to warn and
protect the public from any dangerous condition caused by the construction of said
improvements.
8. Liability. Developer shall hold City, its officers and employees harmless from
any and all claims, demands, causes of action, liability or loss of any sort because of, or
arising out of, the acts or omissions of Developer, his contractor, subcontractors, agents
or employees in the performance of this agreement.
-2-
EXHIBIT "A"
POCHIROWSKI PROPERTY
Lot 24/Tract 10103
27712 Highland Drive
ITEM 1: Construction of all on-site grading (cut, fill and slope stabilization) operations
in accordance with Grading Permit No. 30141 and the Developer's plans and
supporting documents as listed below:
(A) Grading Plan for Lot 24/Tract 10103 prepared by R.L. Brown & Assoc.,
engineer Richard Brown, RCE No. 16683 dated 6/20/91.
(B) Geotechnical Report for Lot 24/Tract 10103 prepared by Zeiser
Geotechnical, Inc., Henry Kling, engineer, No. 42395 dated 6/25/91.
ITEM 2: Construction of all on-site improvements in accordance with Grading Permit
No. 30141 and Developer's grading plans referenced in Item 1 above, including,
but not limited to: driveways, parking areas, retaining walls, terrace drains,
down drains, subdrains, area drainage systems, and private storm drain systems
not a part of Developer's Improvement Plans filed with City Engineer. (Under
separate current bond.)
-4-
0
EXHIBIT "B"
0
SCHEDULE FOR COMPLETION OF IMPROVEMENTS
- ON-SITE IMPROVEMENTS ONLY -
Completion Date Task
July 31, 1992
Rough Grade Certification
August 30, 1992
Terrace Drains
March 31, 1993
Driveway
April 30, 1993
Area Drains
-5-
0 0
EXHIBIT "C"
CONDITIONS FOR COMPLETION OF IMPROVEMENTS
A. All work shall be performed in strict observation of the Hours of Operation in
accordance with San Juan Capistrano Municipal Code Section 8-107.
B. Parking for construction crew is to be on-site.
C. Construction and grading equipment traffic shall take access from Junipero Serra
and Rancho Viejo Roads. No heavy equipment traffic will be permitted on Ortega
Highway. Developer shall provide all traffic control measures as required for safe
vehicular movement and shall secure an encroachment (haul -route) permit from
Public Works prior to issuance of the grading permit.
M
STATUTORY PERFORMANCE BOND
KNOW ALL MEN BY THESE PRESENTS, that
Mr. William Pochirowski as Principal, hereinafter called
CONTRACTOR, and Mariners Rank ,
as Surety, hereinafter called SURETY, are held and firmly bound unto
the City of San Juan Capistrano, as Obligee, hereinafter called CITY,
in the amount Of sixteen thousand. ninety-nne F nn/inn Dollars
($ 15,091.00 ) for payment whereof Contractor and Surety bind them-
selves, their heirs, executors, administrators, successors, and
assigns, jointly and severally, fairly by these presents.
WHEREAS, Contractor is required to provide a faithful per-
formance bond pursuant to the statutory requirements of the San Juan
Capistrano Municipal Code to guarantee certain work, more particularly
described as follows: "on-site imorovema.,r G" 41,,,14,,gy driveway_ rara;n;,,g
walls, terrace drains, area drains, etc., for lot 94/mrnrr ming (97719 1:4.,1,111a n,-;..,,)
San Juan Capistrano, as authorized by permit 1130141: excludes rough grading covered
by separate bonding.
NOW, THEREFORE, the condition of this obligation is such that,
if Principal shall promptly and faithfully perform said statutory
obligation, then this obligation shall be null and void; otherwise
it shall remain in full force and effect. Surety waives whatever
legal right it may have to require that a demand be made first against
the Principal in the event of default.
i
BE IT FURTHER RESOLVED, that:
1. As a part of the obligation secured hereby, and in addition
to the face amount specified, there shall be included costs and
reasonable expenses and fees, including reasonable attorney's fees,
H
,
incurred by City in successfully enforcing such obligation, all to
be taxed as costs and included in any judgment rendered.
2. Said Surety, for value received, hereby stipulates and
agrees that no change, extension of time, alteration, or modificati
of statutory obligation, or of the work to be performed thereunder,
shall in any way affect its cbligations or this bond, and it does
hereby waive notice of any such change, extension of time, alterati
or modifications, or of the work to be performed thereunder.
Executed this IS day of MAY 19��, at
112Y1NE California.
APPROVED AS TO FORM.
J n R. Shaw
11
y Attorney
Page 2 - STATUTORY PERFORMANCE BOND
i
Title
(NOTARIZATION AND SEAL)
-------------
OrTICIAL BEAT,
John C. Feathers
® NOTARY PUBLIC • CALIFORNIA
ORANGE COUNTY
My Comm. Expires FW 3. 1995
SURETY
By_
Title
(NOTARIZATION AND SEAL)
9
December 15, 1993
see
WOMEN
•
J
IA111141A111
116111 1961
1776
Mr. William Pochirowski
27112 Highland Drive
San Juan Capistrano, CA 92675
Re: Release of Time Certificate of npnna;t -
Dear Mr. Pochirowski:
MEMBERS OF THE CITY COUNCIL
COLLENE CAMPBELL
GARY L. HAUSDORFER
GIL JONES
CAROLYN NASH
JEFF VASOUEZ
CITY MANAGER
GEORGESCARSOROUGH
Attached is your Time Certificate of Deposit No. 0240968225, issued
by Mariners Bank, in the amount of $16,091.00. Said Time
Certificate of Deposit was given to the City as security for on-
site improvements for property located at 27112 Highland Drive,
San Juan Capistrano (Tract 10103, Lot 24). Work has been completed
to the satisfaction of the City of San Juan Capistrano and the Time
Certificate is hereby released.
If you have any questions, please do not hesitate to call.
Very truly your
jGl L LZ!
Cyhia LPendleton
y Treasurer
Attachment
cc: Daniel W. McFarland, Building & Safety Manager
Mariners Bank
This is to acknowledge that I have received the Time Certificate
of Deposit No. 0240968225 issued by Mariners B n 'n the amount` of
$16,091.00. /
G� v
am J. Pochirowski
Dated this day of Devember, }993.
vanuaj , Iqq q
32400 PASEO ADELANTO, SAN JUAN CAPISTRANO, CALIFORNIA 92675 0 (714) 498.1171
E
MEMORANDUM
EJ
December 3, 1993
TO: Dawn Schanderl, Deputy City Clerk
FROM: Daniel W. McFarland, Building & Safety Manager
Department of Engineering and Building
SUBJECT: Bond Release for Pochirowski, 2711'12 Highland Drive
This memo serves as authorization to release the referenced bond, Certificate of Deposit
No. 024968225, in the amount of $16,091.00. All work covered by this bond has been
completed to the satisfaction of the Building Division.
DM/st
cc: Building File
0
C7
rn
� n
Z
a®
aa�
SURETY AGREEMENT FOR
TION
THIS AGREEMENT is made by and between the CITY OF SAN JUAN CAPISTRANO,
a municipal corporation, hereinafter referred to as the "City" and William Pochirowski,
owner/builder, referred to as "Developer".
WITNESSETH
WHEREAS, City will issue Grading Permit No.30141 to Developer to construct
certain designated improvements, more particularly described in Exhibit "A" attached
and incorporated herein by reference, which said improvements constitute a portion of
that real property at the location of Tract 10103/Lot 24 commonly referred to as
r-Z77t-2 Highland Drive, San Juan Capistrano, California.
� 7/ice
WHEREAS, San Juan Capistrano Municipal Code 8-2.05 requires the posting of
financial security to secure the faithful performance and labor and materials for the
grading and installation of improvements connected with issuance of grading permits.
WHEREAS, San Juan Capistrano Municipal Code 8-2.06 authorizes the Building
Official to require additional bonding as security to ensure against adverse aesthetic
impacts arising from incomplete grading and/or improvements from development
projects which have not been completed.
WHEREAS, the Building Official finds that the proposed project site is highly
prominent and visible to the community, has unique topographic features or involves
substantial grading of slope areas.
NOW, THEREFORE, in consideration of the premises and promises hereinafter
contained, City and Developer agree as follows:
1. Developer's Improvements Obligations. Developer shall, at its sole cost and
expense, provide and furnish all labor, materials and equipment for the installation of
improvements set forth in Exhibit "A". The grading permit and plans, which further
defines the improvements in Exhibit "A", are on file in the office of the City's Building
Official, and all documents referenced in Exhibit "A" are incorporated herein by
reference.
2. Developer's Security. Developer shall provide a time certificate of deposit
subject to the approval of the City's City Attorney, to secure Developer's improvement
obligations required under this agreement.
The amount of the bond shall be $16,091.00 for that work described in
Exhibit "A". This security of $16,091.00 shall also serve as security for restoration of the
site. A copy of the surety instrument, as approved by the City Attorney, is attached as
Exhibit "D".
3. Completion of Improvements. To ensure the protection of the public safety,
health and welfare, Developer shall construct the improvements described in Exhibit "A"
in accordance with the schedule as set forth in Exhibit "B", and the conditions as set
forth in Exhibit "C".
-1-
4. Developer Default. In the event Developer does not complete the required
improvements, including erosion -control measures within the time required, or abandons
the project site, or suspends work for more than twenty working days other than
previously prescribed, City shall have the right to immediately declare a default and to
make demand on the surety for performance.
5. Restoration of Site. San Juan Capistrano Municipal Code Section 8-2.06 allows
the City to require bonding a security to ensure against adverse aesthetic impacts arising
from incompleted grading and/or improvements. The purpose of this bonding shall be to
restore the property to its original condition if the Developer defaults. This restoration
shall include:
Dismantle and/or demolish improvements;
2. Grade property to its original contours as shown on the grading plan
referred to in Exhibit "A";
3. Remove all debris and construction materials from the site; and
4. Install erosion control, including hydroseeding, to the satisfaction of the
Building Official.
6. Attorney's Fees. Developer agrees to pay City such sum as the court may
adjudge as reasonable for the legal services of an attorney representing City in an action
brought to enforce or interpret the obligations of this agreement, and such sum shall be
made a part of any judgment in such action against Developer if such action is
determined in favor of said City.
7. Developer's Work in Safe Condition. Developer shall perform all work in a safe
workmanlike manner and shall take such precautions as may be necessary to warn and
protect the public from any dangerous condition caused by the construction of said
improvements.
8. Liability. Developer shall hold City, its officers and employees harmless from
any and all claims, demands, causes of action, liability or loss of any sort because of, or
arising out of, the acts or omissions of Developer, his contractor, subcontractors, agents
or employees in the performance of this agreement.
-2-
0 0
In Witness Whereof, the parties have executed this agreement as
of .�� /!�� / , 19 P7; at San Juan Capistrano, California.
Approved s to
By: Joh aw
City Attorney
C'4 of San Juan C pistrano
ByU:Aaniel W. McFarldnd
Building Official
Principal(s)��
By. ` S."
Title: Li -�i{ N
By:
Title:
By:
Title:
-3-
EXHIBIT "A"
POCHIROWSKI PROPERTY
Lot 24/Tract 10103
27712 Highland Drive
ITEM 1: Construction of all on-site grading (cut, fill and slope stabilization) operations
in accordance with Grading Permit No. 30141 and the Developer's plans and
supporting documents as listed below:
(A) Grading Plan for Lot 24/Tract 10103 prepared by R.L. Brown & Assoc.,
engineer Richard Brown, RCE No. 16683 dated 6/20/91.
(B) Geotechnical Report for Lot 24/Tract 10103 prepared by Zeiser
Geotechnical, Inc., Henry Kling, engineer, No. 42395 dated 6/25/91.
ITEM 2: Construction of all on-site improvements in accordance with Grading Permit
No. 30141 and Developer's grading plans referenced in Item 1 above, including,
but not limited to: driveways, parking areas, retaining walls, terrace drains,
down drains, subdrains, area drainage systems, and private storm drain systems
not a part of Developer's Improvement Plans filed with City Engineer. (Under
separate current bond.)
-4-
EXHIBIT "B"
SCHEDULE FOR COMPLETION OF IMPROVEMENTS
- ON-SITE IMPROVEMENTS ONLY -
Completion Date Task
July 31, 1992
Rough Grade Certification
August 30, 1992
Terrace Drains
March 31, 1993
Driveway
April 30, 1993
Area Drains
-5-
EXHIBIT "C"
CONDITIONS FOR COMPLETION OF IMPROVEMENTS
A. All work shall be performed in strict observation of the Hours of Operation in
accordance with San Juan Capistrano Municipal Code Section 8-107.
B. Parking for construction crew is to be on-site.
C. Construction and grading equipment traffic shall take access from Junipero Serra
and Rancho Viejo Roads. No heavy equipment traffic will be permitted on Ortega
Highway. Developer shall provide all traffic control measures as required for safe
vehicular movement and shall secure an encroachment (haul -route) permit from
Public Works prior to issuance of the grading permit.
MARINERS BANK
TIME CERTIFICATE OF DEPOSIT
Date 05-28-92 AccounlN0240968225
Purchased by WILLIAM J POCHIROWSKI Amounts 16,091.00
Rate 4.000%
Payable ii CITY OF SAN
JUAN
ayyS,Ca��A{�P�1IIST?ch
R�A{NO yry� Term 365 DAYS
Sngle Maturity 'c U Multiple Maturity /�I
/yl�ntere5l on this Deposit Shall be paid Cl Monthly ElQuarterly 11AnnuallyO at Maluniy
X 0 Reinves!at Maturity(Multipie MaWntyonly)[ICradillo X�(VV X�(
C1OtherInterest shall be baaed`rin ❑ 365 Days ❑ 360 Days ❑ S,AAJ Compounded
No intaaaet will be pato on ain't. mMuslh dapoana alder the maturity data Multiple Iii ohnoxii w"t be tahawed
aulomehcally for the same term at the interest rate in ellect on the maturity date unless Medeposit Is reeeemedwithln 10 oaysalter the
maturity date The Bank reserves the right to redeem this dedi on the Ork iN! Or any Subsequent maturity In this event. you will be
given a an dayadvence written notice of the Bank s Intent Presentation of this Receipt is not required to withdraw funds from ini5 account
FDIC Regulation. Require a Substairri lasuralthilifnE.6,101I ba(_F IC fill
NOTNEGOTIABLE NOTTMNSFERABLE ��►►��
AQTMNATVIRE
EARLY WITHDRAWAL PENALTY
A. MINIMUM SII( (6) DAY PENALTY.
For all time deposits. any withdrawal made within the first sul6j calendar days after the date of deposit or within si. 16,
calendar days following any partial withdrawal made prior to the maturity date will be subject to a minimum penally soul ro
Seven 171 days simple Interest on the amount wOndrawn
B. TIME DEPOSITS BY INDIVIDUALS.CC j
c Time deposits. made by or for the benefit of one or more individuals. that nave a maturity of365 _ DAYpNtn_ w pe J
Subject to a minimum penalty equal to
Seven V I days interest on the amount withdrawn it the withdrawal U made within six 16) calendar days from the 98!s c'
X Oftpsi! and - Interest it wrthorawn thereafter
month Interest regardless Of when the withdrawal Occurs
C. TIME DEPOSITS BY DEPOSITORS OTHER THAN INDIVIDUALS.
Time deposits. made by a depositor other than an motviduai. that hayea stated maturity or notice Period of eighteen 1161
months or more. will De subject to a minimum penalty equal to
.7 Seven (%) days interest On the amovnl withdrawn d withdrawal is made with n six (61 cajendardays from the date of dep05'
and one month'5 Simple Interest if made after six (61 Calendar days and before eighteen 118) months
One months simple interest on the amount withdrawn
months Interest regardless of when the withdrawal occurs
Tl me deposits. made DY—a deposdor oche, Ihan an mdim dual Inst have a —ma turth or notica parlod of bas then ug h lean
(1 BI Tont he, vin 11 be Sul eCt 10 a minimum penalty equal to
E Seven Ill days interest On ins am punt wl the ra win if the A, i mdra waI is made within six (6) Ca lends days from the da'a
deposit and _ _ interest if withdrawn thereafter
Mont ns Interest regardless of when wi t no rawaI occurs ,
r/r/' —7—
EXHIBIT
M•fT)nT!uYA.k!� .. b ...,- ... • 11: a.. �r. _. �.,
... s.
.-V- r s .. . -.!r m
i�iwL.{ �a.c_,"
MARINERS BANK
TIME CERTIFICATE OF DEPOSIT
Date 05-28-92 AccounlN0240968225
Purchased by WILLIAM J POCHIROWSKI Amounts 16,091.00
Rate 4.000%
Payable ii CITY OF SAN
JUAN
ayyS,Ca��A{�P�1IIST?ch
R�A{NO yry� Term 365 DAYS
Sngle Maturity 'c U Multiple Maturity /�I
/yl�ntere5l on this Deposit Shall be paid Cl Monthly ElQuarterly 11AnnuallyO at Maluniy
X 0 Reinves!at Maturity(Multipie MaWntyonly)[ICradillo X�(VV X�(
C1OtherInterest shall be baaed`rin ❑ 365 Days ❑ 360 Days ❑ S,AAJ Compounded
No intaaaet will be pato on ain't. mMuslh dapoana alder the maturity data Multiple Iii ohnoxii w"t be tahawed
aulomehcally for the same term at the interest rate in ellect on the maturity date unless Medeposit Is reeeemedwithln 10 oaysalter the
maturity date The Bank reserves the right to redeem this dedi on the Ork iN! Or any Subsequent maturity In this event. you will be
given a an dayadvence written notice of the Bank s Intent Presentation of this Receipt is not required to withdraw funds from ini5 account
FDIC Regulation. Require a Substairri lasuralthilifnE.6,101I ba(_F IC fill
NOTNEGOTIABLE NOTTMNSFERABLE ��►►��
AQTMNATVIRE
EARLY WITHDRAWAL PENALTY
A. MINIMUM SII( (6) DAY PENALTY.
For all time deposits. any withdrawal made within the first sul6j calendar days after the date of deposit or within si. 16,
calendar days following any partial withdrawal made prior to the maturity date will be subject to a minimum penally soul ro
Seven 171 days simple Interest on the amount wOndrawn
B. TIME DEPOSITS BY INDIVIDUALS.CC j
c Time deposits. made by or for the benefit of one or more individuals. that nave a maturity of365 _ DAYpNtn_ w pe J
Subject to a minimum penalty equal to
Seven V I days interest on the amount withdrawn it the withdrawal U made within six 16) calendar days from the 98!s c'
X Oftpsi! and - Interest it wrthorawn thereafter
month Interest regardless Of when the withdrawal Occurs
C. TIME DEPOSITS BY DEPOSITORS OTHER THAN INDIVIDUALS.
Time deposits. made by a depositor other than an motviduai. that hayea stated maturity or notice Period of eighteen 1161
months or more. will De subject to a minimum penalty equal to
.7 Seven (%) days interest On the amovnl withdrawn d withdrawal is made with n six (61 cajendardays from the date of dep05'
and one month'5 Simple Interest if made after six (61 Calendar days and before eighteen 118) months
One months simple interest on the amount withdrawn
months Interest regardless of when the withdrawal occurs
Tl me deposits. made DY—a deposdor oche, Ihan an mdim dual Inst have a —ma turth or notica parlod of bas then ug h lean
(1 BI Tont he, vin 11 be Sul eCt 10 a minimum penalty equal to
E Seven Ill days interest On ins am punt wl the ra win if the A, i mdra waI is made within six (6) Ca lends days from the da'a
deposit and _ _ interest if withdrawn thereafter
Mont ns Interest regardless of when wi t no rawaI occurs ,
r/r/' —7—
STATUTORY PERFORMANCE BOND
KNOW ALL MEN BY THESE PRESENTS, that
Mr. William Pochirowski , as Principal, hereinafter called
CONTRACTOR, and Mariners Bank
as Surety, hereinafter called SURETY, are held and firmly bound unto
the City of San Juan Capistrano, as Obligee, hereinafter called CITY,
in the amount of Sixteen thousand, ninety-one_ 5 nn/inn Dollars
($ 16,091.00 ) for payment whereof Contractor and Surety bind them-
selves, their heirs, executors, administrators, successors, and
assigns, jointly and severally, fairly by these presents.
WHEREAS, Contractor is required to provide a faithful per-
formance bond pursuant to the statutory requirements of the San Juan
Capistrano Municipal Code to guarantee certain work, more particularly
described as follows: "on-site imnroyPmPnt." ;,,,.i„A;.g* driveway_ raraini�g
walls, terrace drains, area drains, etc., for ter 9L/Tr.rr lnlni (97119 F;nhl�n.i ngi;',�
San Juan Capistrano, as authorized by permit 1130141; excludes rough grading covered
by separate bonding.
NOW, THEREFORE, the condition of this obligation is such that,
if Principal shall promptly and faithfully perform said statutory
obligation, then this obligation shall be null and void; otherwise
it shall remain in full force and effect. Surety waives whatever
legal right it may have to require that a demand be made first against
the Principal in the event of default.
BE IT FURTHER RESOLVED, that:
1. As a part of the obligation secured hereby, and in additio:
to the face amount specified, there shall be included costs and
reasonable expenses and fees, including reasonable attorney's fees,
0 0
incurred by City in successfully enforcing such obligation, all to
be taxed as costs and included in any judgment rendered.
2. Said Surety, for value received, hereby stipulates and
agrees that no change, extension of time, alteration, or modificat:
of statutory obligation, or of the work to be performed thereunder,
shall in any way affect its cbligations or this bond, and it does
hereby waive notice of any such change, extension of time, alterati
or modifications, or of the work to be performed thereunder.
Executed this 17 day of MAY 1992 at
14NARS. , Califor:ia.
APPROVED AS TO FORM.
C�L evAa-Lo
J n R. Shaw
y Attorney
Paqe 2 - STATUTORY PERFORMANCE BOND
(NOTARIZATION AND SEAL)
--------------
OMCM SEAL
John C. Feathers
m • NOTARY PUBLIC - CALIFORNIA
ORANGE COUNTY
My Comm. Emms Feb. 3, 1995
SURETY
By
Title
(NOTARIZATION AND SEAL)
d
MEMORANDUM
TO: David P. Bentz, Director of Administrative Services
FROM: Dawn M. Schanderl, Deputy City Clerk
DATE: June 3, 1992
SUBJECT: Time Certificates of Deposit (William Pochirowski)
On June 2, 1992, 1 received the following Time Certificate's of Deposit from the Building
Department:
1. Time Certificate of Deposit No. 0240968225 in the amount of $16,091.00.for
the onsite improvement bond regarding Surety Agreement for Lot 24 of Tract
10103 (27712 Highland Drive).
2. Time Certificate of Deposit No. 0240968224 in the amount of $45,688.00 for
the rough grade performance bond regarding Surety Agreement for Lot 24,
Tract 10103 (27712 Highland Drive)
Please put the attached Time Certificate of Deposit's into the safety Deposit box.
Thank you for your cooperation.
cc: Cheryl Johnson, City Clerk
Daniel McFarland, Building Manager
L
• MARINERS 8�1DE
TIME CERTIFICATENK
POSIT
Date 05-28-92 Account N0240968225
Purch..etlbyWILLIAM J POCHIROWSKI Amount 16,091.00
Rate 4.000'%
Payableto THE CITY OF SAN
SANJJUAAANCAPISTRANO Term 365 DAYS
0of IMrL /MAPI e0i"1
1U
Multipm M fumy
Interest on this Deposit shell be Mid: ❑ MMthly
X h Rainiest at Maturity (Multiple Maturity only) ❑ Credit to
❑ Quarterly ❑ Annually X I. -I At Maturity
❑ Other InteleSt shall txbased uX ❑ 365 Daye ❑ 360 Day. ❑ Simi compounded
No Interest will be "to on .Ingle maturk, deposit. after the maturity date. Multiple Maturity deposits will be renewed
automatically for the same tent, et rho Interest wte rn eeact on the m.tuntyd.w hisse the deposit is redeemed within 10day3afterme
maturity date. The Bank reserves the right to redeem this deposit on the Original or any subsequent maturity. In thq event, you will M
given ten day advance wntten notice oftno Banka intent presentation of this Receipt is nobepmred to withdraw funds from this account.
FDIC Regulations Require a SugmwAI*I Penalty For Early yalthdr> ♦ ba[_FyIC
NOTNEOOTIABLE NOTTMNSFEMSLE
AUTH 1 NAT E
EARLY WITHDRAWAL PENALTY
A. MINIMUM SIX (S) DAY PENALTY.
For all time deposits. any withdrawal made within the first six(6) calendar days after the date of deposit or within six (6)
calendar days following any partial withdrawal made prior to the maturity date will be subject to a minimum penalty equal to
seven )7) day0 simple Interest on the amount withdrawn.
B, TIME DEPOSITS BY INDIVIDUALS. 365 DAVC
Time deposits. made by Or for the benefit of one or more individuals. that have a maturity of_q the. will be
subject to a minimum penalty equal to:
❑ Seven 17) daysinterest on the amount withdrawn if the withdrawal m made within six (6) calendar days from the date of
X Oflj and interest if withdrawn thereafter.
❑ month's interest regardless of when the withdrawal occurs.
❑ —
C. TIME DEPOSITS BY DEPOSITORS OTHER THAN INDIVIDUALS.
Time deposits. mads by a depositor other then an individual, that haw a stated maturity or notice period of eighteen (1 B)
months or mon, will be subject to a minimum Penalty equal to:
❑ Seven (7) days interest on the amount withdrawn If Withdrawal is madewlmin surd) calendar daysfrom the date of deposit
and one month's simple interest if made after six (6) calendar days and before eighteen (18) months.
❑ One month's simple interest on the amount withdrawn.
❑ months' interest regardless of when the withdrawal occurs
Time deposits. made by a depositor other than an individual, that hate a maturity or notice period of lose than eighteen
(18) months. will be subject to a minimum penalty equal to:
❑ Seven (7) days' interest on the amount withdrawn if the withdrawal is made within six (B) calendar days from the date of
deposit and interest it withdrawn thereafter.
❑ months' Interest regardless of when withdrawal occurs.
HOW THE PENALTY WORKS.
epanalty is caltulaletl asalodsdure of wit of the interesithet would beearned onthe rime da
otted from eathu bNnaameI the0therat already
has
not yet earned enough interest ao that tut the pelnait can ucted from earned mtereal, or d tae interest alreaoy ass be M, the penalty will be deducted from the principal,
HOW THE PENALTY IS CALCULATED.
The penalty 13 calculated as follows:
❑ Fixed Rate. If the rate of interest is lixed for the term of the deposit, then the penalty will be Calculated using the nominal
(simple interest) rate being paid on the deposit.
❑ Variable Rate. If during the term Of the deposit the rate of interest will very based on an index not within the control of the
financial institution, then the penalty designated above on the amount withdrawn will be Calculated using (check One):
❑ The rete in effect On the deposit de
ate the depowas OpeOetl.
❑ The retain affect On the date of posit l.w
C An average of the rates m affect during the term of the deposit.
EXCEPTIONS TO EARLY WITHDRAWAL PENALTIES.
The financial institution at Its Option may pay a time depoait, or a portion thereof, before maturity without imposing an early
withdrawal penalty under the following Circumstances:
A When an ownerof the deposit dies or is determined legally incompetent byacourt or0therbodyof COmpetentiunsdiction.
' a Where the time deposit is an Individual Retirement ACCOunt(IRA) and any portion is paid within seven T)days aflat establish.
1 menti or where the time deposit is a Keogh Plan lKeogh), provided that the depositor forfeits an amount at least equal to the
simple interest earned on the amount withdrawn; or where the time deposit is an IRA or Keogh and the Owner attains age
591h or becomes disabled.
G Where a timedeppsn swithdrawn within ton (10) days after a specified
video for automatic renewal at the maturity date. seta even though t deposit contract pro.
Each parson algning below acknowledges receipt of this db ate I.
Date 5 28 92
Depositor WILLI M P CHIROW KI
Depositor
DATE Co'
ENTRY
ACCOUNT RECORD OF RATE AND TERM
RATE OF NEW EFFECTIVE BALANCE
EARNINGS MATURITY DATE DATE
MARINERS BANK
• TIME CERTIFICAT)o DEPOSIT
iData 5-28— Account No 0240968224
Purchased by WILLIAM J POCHIROWSKI ,ppoupt $,_ 45,688.00
P19P R.I. 3.650%
Payableto THE CITY OF SAN JUAN CAPISTRANO Te,m 90 DAYS
II �� p AingeM unt Bmiilofr ❑yM yyyy h., Maturity yyyy
interest
on this Deposit shall be paid.' ❑ Monthly ❑ originally❑ Annually ❑u Maturity
Nlfln
` ❑ vest at Maturity(Mulbpie Maturity only) ❑Credit to -yyyy
1
11 Other Interest shall be baaeo on C&5 Days C3060 Days 11Simple❑yAmpoended
No Interest will M paid on single maturity deposits after the maturity data Multiple Maturity deposit$ will be renewed
automatically for the same term at the interest rate in effect on the maturity date unless the deposit is redeemed within t 0 days after the
matunty date. The Bank reserves the fight to redeem this pill on the original or any Subsequent maturity In thisevent, you will be
green amen day advance .,,"an notice of the Bank's Intent. Presentation of this Receipt Is not required to withdraw funds from this account
NOT Regulation,IABL RVOT a SubstaANSFE ifat penalty For Early WIthO %�O
NOTNEGOTIABLE NOTTMNSFERABLE �
AUTRORI NATU�IE
EARLY WITHDRAWAL PENALTY
A. MINIMUM SIX (6) DAY PENALTY.
For all time deposits, any withdrawal made within the first six(6) calendar days atter the date of deposit or within six (6)
calendar days following any partial withdrawal made prior to the maturity date will be subject too minimum penalty equal to
v seven (7) daysSimple interest on the amount withdrawn.
B. TIME DEPOSITS BY INDIVIDUALS. TT�1��yycQ
Time deposits. made by or for the benefit of one or more individuals, that have a maturity of _90 nQUICtiivill be
subject to a minimum penalty equal to:
❑ Seven (7) days' interest on the amount withdrawn if the withdrawal is made within six (6) calendar days from the date of
d�potl1 interest if withdrawn thereafter.
month'a interest regardless of when the withdrawal occur.
C
C. TIME DEPOSITS BY DEPOSITORS OTHER THAN INDIVIDUALS.
Time depoeits, made bye depositor other than an indh idual,that have stated maturity or mollies Period of eighteen (18)
months of mom, will be subject to a minimum Penalty equal to:
❑ Seven (T) days' interest on the amount withdrawn it withdrawal is madewithin six (6) calendar days from the dale of deposit
_ and one month's simple interest if made after six (6) calendar days and before eighteen (18) months.
• One month 'a simple Interest on the amount withdrawn.
❑ months' ,merest regardless of when the withdrawal occurs.
Time deposits, made by a depositor other than an individual, Met have a maturity or notice period of Ins then eighteen
(I8) months, will be subject to a minimum penalty equal to:
Seven (7) days' interest on the amount withdrewn d the withdrawal is made within six (6) calendar days from the date of
— deposit and interest if withdrawn thereafter.
❑ months' interest regardless of when withdrawal occurs.
HOW THE PENALTY WORKS.
The "natty Is Calculated as a forterture of part of themterestacrwuukl be earned on the time deposit It aW
"Iste heer
th
• or notthUntereathae beeneametl. In otherwords.d thea has not yet earned enough interest so that the penalty ca
enough
deducfed from earned Interest. Or if the interest already hes paid, the penalty, will be deducted from the pnncipal.
HOW THE PENALTY IS CALCULATED.
The Penalty is calculated as follows:
❑ Fixed Rate. If the rate of interest is fixed for the term of the deposit then the penalty will be calculated using the nominal
(simple interest) rate being aid On the deposit.
❑ Variable Rate. If during the term of the deposit the rate of interest will vary bated on an index rot within the control of the
financial institution, then the penalty designated above On the amount withdrawn will be calculated using (Check Oral:
❑ The rate m effect on the date the deposit was opened.
❑ The retain effect on the date of withdrawal.
❑ An average of the rates in effect during the term of the deposit
EXCEPTIONS TO EARLY WITHDRAWAL PENALTIES.
The financial institution at its option may pay a time deposit or a Portion thereof. before maturity without imposing an early
withdrawal penalty under the following circumstances:
A When an owner of the deposit dies or is determined legally incompetent by a court or other body of competent jurisdiction.
6 Where the time deposit is an Individual Retirement Account(IRA) andany portion is paid within eaven(7) days afterestablish-
menb or where the time deposit is a Keogh Plan (Kiii Provided that the depositor forfeits an amount at least e0ual to the
simple interest earned on the amount withdrawn; or where the time deposit is an IRA or Keogh and the owner attains age
59n, or becomes disabled.
C. Where a time deposit is withdrawn within ton 11 Dj days atter a specified maturity date even though the deposit contract pro-
vides for automatic renewal at the maturity date.
Each person signing below acknowledges reaipt of this discl eM.
Date 519811:0 i Z� C
Depositor
ACCOUNT RECORD OF RATE AND TERM
I�
DATE OF
RATE OF
NEW
EFFECTIVE
BALANCE
ENTRY
EARNINGS
MATURITY DATE
DATE
%
s
s
%
s
%
S
%
S
%
S
f