Loading...
04-0824_PETEAN, VASILE AND ELENA_Surety Agreement (2) SURETY AGREEMENT THIS AGREEMENT is made by and between the CITY OF SAN JUAN CAPISTRANO, a municipal corporation, hereinafter referred to as the "City" and Vasile and Elena Petean, Owner/Builders referred to as "Developer". WITNESSETH WHEREAS, City will issue Grading Permit No. 48428 to Developer to construct certain designated improvements, more particularly described in Exhibit"A" attached and incorporated herein by reference,which said improvements constitute a portion of that real property at the location of APN 675-331-03, commonly referred to as 33571 Valle Road. WHEREAS, San Juan Capistrano Municipal Codes Section 8-2.08 requires the posting of financial security to secure the faithful performance and labor and materials for the grading and installation of improvements connected with issuance of grading permits including the construction of drainage and protection devices and any other corrective work to remove and eliminate engineering and geological hazards. WHEREAS, San Juan Capistrano Municipal Code Section 8-2.09 authorizes the Building Official to require additional bonding as security to ensure against adverse aesthetic impacts arising from incomplete grading and/or improvements from development projects which have not been completed. WHEREAS, the Building Official finds that the proposed project site is highly prominent and visible to the community, has unique topographic features or involves substantial grading of slope areas. NOW, THEREFORE, in consideration of the premises and promises hereinafter contained, City and Developer agree as follows: 1. Developer's Improvements Obligations. Developer shall, at its sole cost and expense, provide and furnish all labor, materials and equipment for the installation of improvements set forth in Exhibit"A". The grading permit and plans,which further defines the improvements in Exhibit "A", are on file in the office of the City's Building Official, and all documents referenced in Exhibit "A" are incorporated herein by reference. SD 2. Developer's Security. Developer shall provide a personal check drawn on Bank of America Account 99220730 Check No. 5147 subject to the approval of the City Attorney, to secure Developer's improvement obligations required under this agreement. The amount of the bond shall be $2,300.00 for that work described in Exhibit "A". This security of$2,300.00 shall also serve as security for restoration of the site. A copy of the surety instrument, as approved by the City Attorney, is attached as Exhibit "D". 3. Completion of Improvements. To ensure the protection of the public safety, health and welfare, Developer shall construct the improvements described in Exhibit"A"in accordance with the schedule as set forth in Exhibit"B", and the conditions as set forth in Exhibit "C". 4. Developer Default. In the event Developer does not complete the required improvements, including erosion and silt control measures within the time required, using Best Management Practices (BMP) in implementing a Water Quality Management Plan in full compliance with Orange County National Pollutant Discharge Elimination System (NPDES) Storm Water Implementation Agreement and San Juan Capistrano Municipal Code Section 8-14, or abandons the project site, or suspends work for more than twenty working days other than previously prescribed, City shall have the right to immediately declare a default and to make demand on the surety for performance. 5. Restoration of Site. San Juan Capistrano Municipal Code Section 8-2.09 allows the City to require bonding as security to ensure against adverse aesthetic impacts arising from uncompleted grading,drainage and/or improvements which includes illicit non- storm drain water discharge. The purpose of this bonding shall be to restore the property to its original condition if the Developer defaults. This restoration shall include but not be limited to the following: A. Dismantle and/or demolish improvements; B. Grade property to its original contours as shown on the grading plan referred to in Exhibit "A"; C. Remove all debris and construction materials from the site; and D. Install erosion and silt control devices, including hydroseeding, to insure a uniform vegetative cover, or equivalent stabilization measures which include the use of such Best Management Practices • • as blankets, fiber matrices, catch basin filters, or other erosion resistant soil coverings or treatments to satisfaction of the Director of Engineering and Building. 6. Attorney's Fees. Developer agrees to pay City such sum as the court may judge as reasonable for the legal services of an attorney representing the City in an action brought to enforce or interpret the obligations of this agreement, and such sum shall be made a part of any judgment in such action against Developer if such action is determined in favor of said City. 7. Developer's Work in Safe Condition. Developer shall perform all work in a safe workmanlike manner and shall take such precautions as may be necessary to warn and protect the public from any dangerous condition caused by the construction of said improvements. 8. Liability. Developer shall hold City, its officers,and employees harmless from any and all claims, demands, causes of action, liability or loss of any sort because of, or arising out of,the acts or omissions of Developer, his contractor,subcontractors,agents or employees in the performance of this agreement. In witnes where , the parties have executed this agreement as of Q� , 200e>at San Juan Capistrano, California. Developer City of San Juan Capistran By: Vasile or Elena Pet an By. niel W. Wr land Owner/Builder Building Official Approved as Form: By: MI-6 Shaw City Attorney EXHIBIT "A" 33571 Valle Road Petean Residence Item 1: Construction of all on-site grading (cut, fill and slope stabilization) operations in accordance with Grading Permit No. 48428 and the Developer's plans and supporting documents as listed below: (A) Grading Plan for Petean Residence dated June 24, 2004, prepared by Karl O. Mosby, Consulting Civil Engineer, RCE No. 42642. (B) Geotechnical Report for Petean Residence dated May 5, 2004, prepared by Petra Geotechnical, Inc.,Ahmad Ghazinoor, SeniorAssociate Engineer, GE No. 2019. Item 2: Construction of all on-site improvements in accordance with Grading Permit No. 48428 and Developer's grading plans referenced in Item 1 above, including, but not limited to: driveways, parking areas, retaining walls, erosion and silt control, terrace drains, down drains, sub-drains, area drainage systems, and private storm drain systems not a part of Developer's Improvement Plans filed with the City Engineer. EXHIBIT "B" SCHEDULE FOR COMPLETION OF IMPROVEMENTS Completion Date Task February 2005 Rough Grade Certification February 2005 Landscape Irrigation February 2005 Landscape Planting EXHIBIT "C" CONDITIONS FOR COMPLETION OF IMPROVEMENTS 1. The grading for this project shall be in strict conformance with the grading plans and related documents as described in Exhibit "A" and Grading Permit No. 48428. 2. Grading operations shall commence within fourteen (14) calendar days after issuance of Grading Permit No. 48428. Winter grading will be conducted in strict accordance with the dynamic erosion and silt control plan submitted by the Developer, and approved by the City. This erosion and silt control plan reflects erosion and silt mitigation measures for expected grading conditions as the work progresses through the winter season and shall not be amended except with the permission of the City. In the event Developer does not wish to implement winter grading,or permission for winter grading is rescinded, static erosion and silt control plans reflecting current conditions of grading shall be submitted within ten (10) days of cessation of work. These plans shall: 1. Identify all pollutant sources including sources of sediment that may affect the quality of storm water discharges associated with the construction activity. 2. Include the erosion and sediment control planting and hydroseeding to insure a uniform vegetative cover or equivalent stabilization measures which include the use of such Best Management Practices as blankets, fiber matrices, catch basin filters or other erosion resistant soil covering or treatments to the satisfaction of the City Engineer. 3. A sequence plan of grading operations shall be approved by the City prior to the issuance of any grading permit for this project. Any variation or deviation in the sequence of operations must be recommended, in writing, by the supervising civil and soils engineers and approved by the Building Official prior to performing any work related to the variation or deviation. 4. The supervising civil engineer and soils engineer shall file biweekly progress reports of all grading operations with the Building Official. An interim compaction report,for that work completed at the time work is suspended for the rainy season, shall be filed with the Building Official. This interim report shall conform to the grading code requirements for final compaction reports. 5. Contractor shall control dust to the satisfaction of the Building Official or his deputy. During grading, Contractor shall keep water truck on site and dampen work area, grounds, and loaded trucks. 6. Grading operations suspended during the rainy season shall be resumed no later than 15 days from date of suspension termination. 7. Installation of interim erosion and sediment control devices and systems shall commence within seven (7)days after rough grade certification has been approved by the Building Official and must be completed within fifteen (15) days of rough grade certification. Final erosion and sediment control devices, planting, landscaping and irrigation systems shall be installed prior to final inspection of the grading permit. 8. All work shall be performed in strict observation of the Hours of Operation in accordance with San Juan Capistrano Municipal Code Section 8-1.03. 9. Contractor shall adhere to conditions of haul route permit and encroachment permit issued by the City Engineer. 10. Parking for construction crew is to be on-site. �Sao Plan Check Application No. O Permit No. 4J¢!M tit 1961 n,u 1961 17n CITY OF SAN JUAN CAPISTRANO MISCELLANEOUS __RECEIPT Project Name ProjectAddress/ G�t�Bt��< Applicant ,� Phone Y!� e!1�37^e 5� Address �32 �-rsryll�r�—i-� It/li Sd� V40 92Zo Q/ Building Plan Check ...................................................... $ (01-4411) Grading Plan Check ...................................................... $ (01-4413) On-Site Plan Check ...................................................... $ (01-4413) Special Inspection/Re-Inspection .................................. $ (01-4412) Geotechnical/Soils Plan Review .................................... $ (01-4419) ( ) Co/pies @ 0.20/each ........................................ $ (01-4521) Other ....4�s�r ..c�� ... ......... TOTAL ....................................... NOTE: APPLICATIONS FOR WHICH NO PERMIT IS ISSUED WITHIN 180 DAYS FOLLOWING THE DATE OF APPLICATION/DEPOSIT SHALL EXPIRE BY LIMITATION AND BECOME NULL AND VOID. UNIFORM B aUILDING CODE SECTION 304 (d) pp Prepared By eik2ii/�- -71 Department of Engineerirfg&Building Date F J k: p i41 s 4 " F ii ffir 9 :54(r 3 jl fAf MY.n P. a daWIKJF BANK - TRANSIT $CHECKS E CASH DATE NAME DESCRIP770N EIVED NO. BY INVALID _ THOUT 1 0 7 7 0S SIGNATURE LL y ✓qq Illi CITY OF SAN JUAN CAPISTRANO 32400 PASEO ADELANTO SAN JUAN CAPISTRANO, CALIFORNIA 92675 M211M(M) MEMORANDUM April 25, 2007 TO: Accounts Payable, Admin Services FROM: Nasser Abbaszadeh, Engineering and Building Director SUBJECT: Grading Bond Release, Petean Residence, 33571 Valle Road This memorandum is to authorize the release the grading bond posted in the amount of $2,300.00 for the grading on 33571 Valle Road, Petean Residence. The grading and on-site improvements that were secured by the bond have been completed to the satisfaction of the City. A Personal Check No. 5147 drawn on Bank of America, Account Number 099220730 was posted as the security. A copy of the Surety Agreement and check request is attached for your information. Thanks for your assistance. Attachment cc: Meg Monahan, City Clerk file V City of San Juan Capistrano CHECK REQUEST Administrative Services Department Address Check to: Name: Mr. Vasile Petean Address: 33571 Valle Road San Juan Capistrano, CA 92675 Check Amount Requested Invoice No. Invoice Date Amount Account No.: 48428 8/27/07 2300.00 19-2302 2300.00 CHECK TOTAL: Check stub to contain the following: Grading Surety Release Check Requested By: Employee: Deena Berens Department Eng & Bldg Date: 4125107 Department Approval: Nasser Abbaszadeh --- Transmittal Instructions: ❑ Return Check To: ® Mail With Attached: ❑ Other (Specify): For Administrative Services Use Only Vendor Number: Warrant Number: Date: Approved: �T PtXddr+ Pte '^L[4t RD Tract woo, :F22 Ott �1-03 �; ,I ­ slis mi,�.*4,2,0. A 6f ooft -AT -Ot 40 _4 A iadft $7 *4 tw IN I - it JJ 6L ......... Al OW iL�� In OA ...... tk jtc 1vt 1w, 42 11iO1 Dome AJ V6, ........ .. '�L 7 oq**RNA radfni av�r,_q ,10'al Moit p1 SURETY AGREEMENT THIS AGREEMENT is made by and between the CITY OF SAN JUAN CAPISTRANO, a municipal corporation, hereinafter referred to as the "City" and Vasile and Elena Petean, Owner/Builders referred to as "Developer". O Py WITNESSETH WHEREAS, City will issue Grading Permit No. 48428 to Developer to construct certain designated improvements, more particularly described in Exhibit"A" attached and incorporated herein by reference,which said improvements constitute a portion of that real property at the location of APN 675-331-03, commonly referred to as 33571 Valle Road. WHEREAS, San Juan Capistrano Municipal Codes Section 8-2.08 requires the posting of financial security to secure the faithful performance and labor and materials for the grading and installation of improvements connected with issuance of grading permits including the construction of drainage and protection devices and any other corrective work to remove and eliminate engineering and geological hazards. WHEREAS, San Juan Capistrano Municipal Code Section 8-2.09 authorizes the Building Official to require additional bonding as security to ensure against adverse aesthetic impacts arising from incomplete grading and/or improvements from development projects which have not been completed. WHEREAS, the Building Official finds that the proposed project site is highly prominent and visible to the community, has unique topographic features or involves substantial grading of slope areas. NOW, THEREFORE, in consideration of the premises and promises hereinafter contained, City and Developer agree as follows: 1. Developer's Improvements Obligations. Developer shall, at its sole cost and expense, provide and furnish all labor, materials and equipment for the installation of improvements set forth in Exhibit"A". The grading permit and plans,which further defines the improvements in Exhibit "A", are on file in the office of the City's Building Official, and all documents referenced in Exhibit "A" are incorporated herein by reference. 2. Developer's Security. Developer shall provide a personal check drawn on Bank of America Account 99220730 Check No. 5147 subject to the approval of the City Attorney, to secure Developer's improvement obligations required under this agreement. The amount of the bond shall be $2,300.00 for that work described in Exhibit "A". This security of$2,300.00 shall also serve as security for restoration of the site. A copy of the surety instrument, as approved by the City Attorney, is attached as Exhibit "D". 3. Completion of Improvements. To ensure the protection of the public safety, health and welfare, Developer shall construct the improvements described in Exhibit"A"in accordance with the schedule as set forth in Exhibit "B", and the conditions as set forth in Exhibit "C". C O P 4. Developer Default. In the event Developer does not complete the required improvements, including erosion and silt control measures within the time required, using Best Management Practices (BMP) in implementing a Water Quality Management Plan in full compliance with Orange County National Pollutant Discharge Elimination System (NPDES) Storm Water Implementation Agreement and San Juan Capistrano Municipal Code Section 8-14, or abandons the project site, or suspends work for more than twenty working days other than previously prescribed, City shall have the right to immediately declare a default and to make demand on the surety for performance. 5. Restoration of Site. San Juan Capistrano Municipal Code Section 8-2.09 allows the City to require bonding as security to ensure against adverse aesthetic impacts arising from uncompleted grading, drainage and/or improvements which includes illicit non- storm drain water discharge. The purpose of this bonding shall be to restore the property to its original condition if the Developer defaults. This restoration shall include but not be limited to the following: A. Dismantle and/or demolish improvements; B. Grade property to its original contours as shown on the grading plan referred to in Exhibit "A"; C. Remove all debris and construction materials from the site; and D. Install erosion and silt control devices, including hydroseeding, to insure a uniform vegetative cover, or equivalent stabilization measures which include the use of such Best Management Practices as blankets, fiber matrices, catch basin filters, or other erosion resistant soil coverings or treatments to satisfaction of the Director of Engineering and Building. 6. Attorney's Fees. Developer agrees to pay City such sum as the court may judge as reasonable for the legal services of an attorney representing the City in an action brought to enforce or interpret the obligations of this agreement, and such sum shall be made a part of anyjudgment in such action against Developer if such acticy},��dp r n in favor of said City. ((�"U V 7. Developer's Work in Safe Condition. Developer shall perform all work in a safe workmanlike manner and shall take such precautions as may be necessary to warn and protect the public from any dangerous condition caused by the construction of said improvements. 8. Liability. Developer shall hold City, its officers,and employees harmless from any and all claims, demands, causes of action, liability or loss of any sort because of, or arising out of,the acts or omissions of Developer, his contractor, subcontractors, agents or employees in the performance of this agreement. In witnes whereqt, the parties have executed this agreement as of 20 at San Juan Capistrano, California. Developer City of San Juan Capistran A 2� By: Vasile or Elena Pet an By. niel W. Mc a and Owner/Builder Building Official Approved as y Form: By: hn Shaw City Attorney EXHIBIT "A" 33571 Valle Road Petean Residence Item 1: Construction of all on-site grading (cut, fill and slope stabilization) operations in accordance with Grading Permit No. 48428 and the Developer�p supporting documents as listed below: c0py (A) Grading Plan for Petean Residence dated June 24,2004, prepared by Karl O. Mosby, Consulting Civil Engineer, RCE No. 42642. (B) Geotechnical Report for Petean Residence dated May 5, 2004, prepared by Petra Geotechnical, Inc.,Ahmad Ghazinoor, Senior Associate Engineer, GE No. 2019. Item 2: Construction of all on-site improvements in accordance with Grading Permit No. 48428 and Developer's grading plans referenced in Item 1 above, including, but not limited to: driveways, parking areas, retaining walls, erosion and silt control, terrace drains, down drains, sub-drains, area drainage systems, and private storm drain systems not a part of Developer's Improvement Plans filed with the City Engineer. EXHIBIT "B" SCHEDULE FOR COMPLETION OF IMPROVEMENTS Completion Date Task February 2005 Rough Grade Certification February 2005 Landscape Irrigation COPY February 2005 Landscape Planting EXHIBIT "C" CONDITIONS FOR COMPLETION OF IMPROVEMENTS 1. The grading for this project shall be in strict conformance with the grading plans and related documents as described in Exhibit "A" and Grading Permit No. 48428. 2. Grading operations shall commence within fourteen (14) calendar days after issuance of Grading Permit No. 48428. C O I OP Winter grading will be conducted in strict accordance with the dynamic erosion and silt control plan submitted by the Developer, and approved by the City. This erosion and silt control plan reflects erosion and silt mitigation measures for expected grading conditions as the work progresses through the winter season and shall not be amended except with the permission of the City. In the event Developer does not wish to implement winter grading,or permission for winter grading is rescinded, static erosion and silt control plans reflecting current conditions of grading shall be submitted within ten (10)days of cessation of work. These plans shall: 1. Identify all pollutant sources including sources of sediment that may affect the quality of storm water discharges associated with the construction activity. 2. Include the erosion and sediment control planting and hydroseeding to insure a uniform vegetative cover or equivalent stabilization measures which include the use of such Best Management Practices as blankets, fiber matrices, catch basin filters or other erosion resistant soil covering or treatments to the satisfaction of the City Engineer. 3. A sequence plan of grading operations shall be approved by the City prior to the issuance of any grading permit for this project. Any variation or deviation in the sequence of operations must be recommended, in writing, by the supervising civil and soils engineers and approved by the Building Official prior to performing any work related to the variation or deviation. • 4. The supervising civil engineer and soils engineer shall file biweekly progress reports of all grading operations with the Building Official. An interim compaction report,for that work completed at the time work is suspended for the rainy season, shall be filed with the Building Official. This interim report shall conform to the grading code requirements for final compaction reports. 5. Contractor shall control dust to the satisfaction of the Building Official or his deputy. During grading, Contractor shall keep water truck on site and dampen work area, grounds, and loaded trucks. � QnoateFr 'y 6. Grading operations suspended during the rainy season shall be resumed than 15 days from date of suspension termination. 7. Installation of interim erosion and sediment control devices and systems shall commence within seven (7)days after rough grade certification has been approved by the Building Official and must be completed within fifteen (15) days of rough grade certification. Final erosion and sediment control devices, planting, landscaping and irrigation systems shall be installed prior to final inspection of the grading permit. 8. All work shall be performed in strict observation of the Hours of Operation in accordance with San Juan Capistrano Municipal Code Section 8-1.03. 9. Contractor shall adhere to conditions of haul route permit and encroachment permit issued by the City Engineer. 10. Parking for construction crew is to be on-site. �awl" Plan Check Application No. O Permit No. ' I�rINYR• Im 1961 CITY OF SAN JUAN CAPISTRANO MISCELLANEOUS RECEIPT COPY Project Name e A�a 2gpszce� Project Address �j3�!/ y��G Zol Applicant Phone Address 949432- 112 - 6ar7-i_/ /t/li Sd�o�-, Yeo 92eo Building Plan Check ...................................................... $ (01-4411) Grading Plan Check ...................................................... $ (01-4413) On-Site Plan Check ...................................................... $ (01-4413) Special Inspection/Re-Inspection .................................. $ (01-4412) Geotechnical/Soils Plan Review .................................... $ (01-4419) ( ) Copies @ 0.20/each ........................................ $ (01-4521) Other ....4// ..:5� ....� ............. TOTAL ....................................... $ �i NOTE: APPLICATIONS FOR WHICH NO PERMIT IS ISSUED WITHIN 180 DAYS FOLLOWING THE DATE OF APPLICATION/DEPOSIT SHALL EXPIRE BY LIMITATION AND BECOME NULL AND VOID. UNIFORM BUILDING CODE SECTION 304 (d) Prepared By�� / h-� . eZI 710¢ Department of Engineeritig&Building Date '� O U t S� ♦ `. 1 ax � _ � � �, . �� � ..�j , , � � r N n� Ion O BANK - �EIVED TRANSIT E CHECKS E CASH DATE NAME DESCRIPTION By NO. • INVALID - 107720 �1 1 7 7 2 0 S IG ITHOUT NATTURE ltl Im CITY OF SAN JUAN CAPISTRANO 32400 PASEO ADELANTO SAN JUAN CAPISTRANO,CALIFORNIA 92675 ccz+ima anal