05-1014_CALEX ENGINEERING COMPANY_Construction Contract0
CONSTRUCTION CONTRACT
�J
THIS CONTRACT is made and entered into, to be effective, this day of
2005, by and between the CITY OF SAN JUAN
CAPISTRANO, hereinafter referred to as "City," and CALEX ENGINEERING
COMPANY, hereinafter referred to as "Contractor."
City and Contractor mutually agree as follows:
Section 1. General Conditions.
Contractor certifies and agrees that all the terms, conditions and obligations of
the Contract Documents as hereinafter defined, the location of the job site, and the
conditions under which the work is to be performed have been thoroughly reviewed, and
enters into this Contract based upon Contractor's investigation of all such matters and is
in no way relying upon any opinions or representations of City. It is agreed that this
Contract represents the entire agreement between the parties. It is further agreed that
the Contract Documents including the Notice Inviting Bids, Special Instructions to
Bidders, if any, and Contractor's Proposal are incorporated in this Contract by
reference, with the same force and effect as if the same were set forth at length herein,
and that Contractor and its subcontractors, if any, will be and are bound by any and all
of said Contract Documents insofar as they relate in any part or in any way, directly or
indirectly, to the work covered by this Contract.
"Project" as used herein defines the entire scope of the work covered by all the
Contract Documents. Anything mentioned in the Specifications and not indicated in the
Plans, or indicated in the Plans and not mentioned in the Specifications, shall be of like
effect as if indicated and mentioned in both. In case of discrepancy in the Plans or
Specifications, the matter shall be immediately submitted to City's Engineer, without
whose decision Contractor shall not adjust said discrepancy save only at Contractor's
own risk and expense. The decision of the Engineer shall be final.
CITY OF SAN JUAN CAPISTRANO
KRUM RESERVOIR PIPELINE REHABILITATION
AGREEMENT
B-1
SD
Section 2. Materials and Labor.
Contractor shall furnish, under the conditions expressed in the Plans and
Specifications, at Contractor's own expense, all labor and materials necessary, except
such as are mentioned in the Specifications to be furnished by the City, to construct and
complete the Project, in good workmanlike and substantial order. If Contractor fails to
pay for labor or materials when due, City may settle such claims by making demand
upon the surety to this Contract. In the event of the failure or refusal of the surety to
satisfy said claims, City may settle them directly and deduct the amount of payments
from the Contract price and any amounts due to Contractor. In the event City receives
a stop notice from any laborer or material supplier alleging non-payment by Contractor,
City shall be entitled to deduct all of its costs and expenses incurred relating thereto,
including but not limited to administrative and legal fees.
Section 3. Description of Project.
The Project is described as: Krum Reservoir Pipeline Rehabilitation as delineated
in the Plans and Specifications prepared by RBF Consulting, Inc., dated September 12,
2005, and Addendum 1 dated September 23, 2005. Work to include: the rehabilitation
of an existing domestic water line using caissons, and a tie-back/grade beam system.
Section 4. Plans and Specifications.
The work to be done is shown in a set of detailed Plans and Specifications
entitled:
Krum Reservoir Pipeline Rehabilitation
Said Plans and Specifications and any revisions, amendments or addenda
thereto are attached hereto and incorporated herein as part of this Contract and referred
to by reference.
CITY OF SAN JUAN CAPISTRANO
KRUM RESERVOIR PIPELINE REHABILITATION
AGREEMENT
B-2
Section 5. Time of Commencement and Completion.
Contractor agrees to commence the Project within ten (10) calendar days from
the date set forth in the "Notice to Proceed" sent by City and shall diligently prosecute
the work to completion within two hundred ten (210) calendar days from the date of the
"Notice to Proceed" issued by the City excluding delays caused or authorized by the
City as set forth in Sections 7, 8 and 9 hereof.
Section 6. Time is of the Essence.
Time is of the essence of this Contract. As required by the Contract Documents,
Contractor shall prepare and obtain approval of all shop drawings, details and samples,
and do all other things necessary and incidental to the prosecution of Contractor's work
in conformance with an approved construction progress schedule. Contractor shall
coordinate the work covered by this Contract with that of all other Contractors,
subcontractors and of the City, in a manner that will facilitate the efficient completion of
the entire work in accordance with Section 5 herein. City shall have complete control of
the premises on which the work is to be performed and shall have the right to decide the
time or order in which the various portions of the work shall be installed or the priority of
the work of other subcontractors, and, in general, all matters representing the timely and
orderly conduct of the work of Contractor on the premises.
Section 7. Excusable Delays.
Contractor shall be excused for any delay in the prosecution or completion of the
Project caused by acts of God; inclement weather; damages caused by fire or other
casualty for which Contractor is not responsible; any act, neglect or default of City;
failure of City to make timely payments to Contractor; late delivery of materials required
by this Contract to be furnished by City; combined action of the workers in no way
caused by or resulting from default or collusion on the part of Contractor; a lockout by
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B-3
City; or any other delays unforeseen by Contractor and beyond Contractor's reasonable
control.
City shall extend the time fixed in Section 5 for completion of the Project by the
number of days Contractor has thus been delayed, provided that Contractor presents a
written request to City for such time extension within fifteen (15) days of the
commencement of such delay and City finds that the delay is justified. City's decision
will be conclusive on the parties to this Contract. Failure to file such request within the
time allowed shall be deemed a waiver of the claim by Contractor.
No claims by Contractor for additional compensation or damages for delays will
be allowed unless Contractor satisfies City that such delays were unavoidable and not
the result of any action or inaction of Contractor and that Contractor took all available
measures to mitigate such damages. Extensions of time and extra compensation as a
result of incurring undisclosed utilities will be determined in accordance with Section C -
9(f) of the General Provisions. The City's decision will be conclusive on all parties to
this Contract.
Section 8. Extra Work.
The Contract price includes compensation for all work performed by Contractor,
unless Contractor obtains a written change order signed by a designated representative
of City specifying the exact nature of the extra work and the amount of extra
compensation to be paid all as more particularly set forth in Section 9 hereof.
City shall extend the time fixed in Section 5 for completion of the Project by the
number of days reasonably required for Contractor to perform the extra work, as
determined by City's Engineer. The decision of the Engineer shall be final.
Section 9. Changes in Project.
A. City may at any time, without notice to any surety, by written order
designated or indicated to be a change order, make any change in the work within the
general scope of the Contract, including but not limited to changes:
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B-4
1) in the Specifications (including drawings and designs);
2) in the time, method or manner of performance of the work;
3) in the City -furnished facilities, equipment, materials, services or
site; or
4) directing acceleration in the performance of the work.
B. A change order shall also be any other written order (including direction,
instruction, interpretation or determination) from the City which causes any change,
provided Contractor gives the City written notice stating the date, circumstances and
source of the order and that Contractor regards the order as a change order.
C. Except as provided in this Section 9, no order, statement or conduct of the
City or its representatives shall be treated as a change under this Section 9 or entitle
Contractor to an equitable adjustment.
D. If any change under this Section 9 causes an increase or decrease in
Contractor's actual, direct cost or the time required to perform any part of the work
under this Contract, whether or not changed by any order, the City shall make an
equitable adjustment and modify the Contract in writing. Except for claims based on
defective specifications, no claim for any change under paragraph (B) above shall be
allowed for any costs incurred more than twenty (20) days before the Contractor gives
written notice as required in paragraph (B). In the case of defective specifications for
which the City is responsible, the equitable adjustment shall include any increased
direct cost Contractor reasonably incurred in attempting to comply with those defective
specifications.
E. If Contractor intends to assert a claim for an equitable adjustment under
this Section 9, it must, within thirty (30) days after receipt of a written change order
under paragraph (A) or the furnishing of a written notice under paragraph (B), submit a
written statement to the City setting forth the general nature and monetary extent of
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B-5
0
•
such claim. The City may extend the thirty (30) day period. Contractor may include the
statement of claim in the notice under paragraph (B) of this Section 9.
F. No claim by Contractor for an equitable adjustment shall be allowed if
made after final payment under this Agreement.
G. Contractor hereby agrees to make any and all changes, furnish the
materials and perform the work that City may require without nullifying this Contract.
Contractor shall adhere strictly to the Plans and Specifications, unless a change
therefrom is authorized in writing by the City. Under no condition shall Contractor make
any changes to the Project, either in additions or deductions, without the written order of
the City and the City shall not pay for any extra charges made by Contractor that have
not been agreed upon in advance in writing by the City. Contractor shall submit
immediately to the City written copies of its firm's cost or credit proposal for change in
the work. Disputed work shall be performed as ordered in writing by the City and the
proper cost or credit breakdowns therefore shall be submitted without delay by
Contractor to City.
H. If in the opinion of the City's Engineer, it is in the City's best interest and it
is deemed necessary to proceed with a required change in the Contract Documents,
and time precludes submittal of the Contractor's proposal or, thorough analysis of the
Contractor's proposal, or the parties fail to reach an agreement, the City may order the
Contractor to proceed (Proceed Order) on the basis of a tentative, not to exceed price
based on the best estimate available at the time, with the firm price and time impact to
be determined later. If a Proceed Order is issued, the Contractor shall submit his
proposal for the changes in the work within 7 calendar days of the Proceed Order, and a
Change Order shall be negotiated and fully executed within 30 calendar days of the
Proceed Order.
Section 10. Liquidated Damages for Delay.
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B-6
0 .
The parties agree that if the total work called for under this Contract, in all parts
and requirements, is not completed within the time specified in Section 5 plus the
allowance made for delays or extensions authorized under Sections 7, 8 and 9, the City
will sustain damage, which would be extremely difficult and impracticable to ascertain.
The parties therefore agree that Contractor will pay to City the sum of Five Hundred
Dollars ($500) per day, as liquidated damages, and not as a penalty, for each and every
calendar day during which completion of the Project is so delayed.
Contractor agrees to pay such liquidated damages and further agrees that City
may offset the amount of liquidated damages from any monies due or that may become
due Contractor under this Contract.
Section 11. Contract Price and Method of Payment.
City agrees to pay and Contractor agrees to accept as full consideration for the
faithful performance of this Contract, subject to any subsequent additions or deductions
as provided in approved change orders, the lump sum of One Million Eight Hundred
Eighty -Four Thousand dollars and no cents ($1,884,000.00).
Within thirty (30) days from the commencement of work, there shall be paid to
the Contractor a sum equal to ninety percent (90%) of the value of the actual work
completed plus a like percentage of the value of material suitably stored at the worksite,
treatment plant or approved storage yards subject to or under the control of the City,
since the commencement of the work as determined by the City. Thereafter, on a
schedule issued by the City at the commencement of the job which shows a minimum of
one payment made to the Contractor per month for each successive month as the work
progresses and the request for payment due dates from the Contractor to meet the
payment schedule, the Contractor shall be paid such sum as will bring the total
payments received since the commencement of the work up to ninety percent (90%) of
the value of the work completed since the commencement of work as determined by the
City, less all previous payments, provided that the Contractor submits the request for
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B-7
0 •
payment prior to the end of the day required to meet the payment schedule. The City
will retain ten percent (10%) of each approved progress payment until the Work is fifty
percent (50%) complete. Then, the City may at its option suspend further retainage
until the final progress payment. The City reserves the right to reinstate up to ten
percent (10%) retainage of the total of the Work if the City determines, at its discretion,
that the Contractor is not performing the Work satisfactorily, or there is other specific
cause for such retainage.
Payments shall be made on demands drawn in the manner required by law,
accompanied by a certificate signed by the City's Engineer, stating that the work for
which payment is demanded has been performed in accordance with the terms of the
Contract, and that the amount stated in the certificate is due under the terms of the
Contract. Partial payments on the Contract price shall not be considered as an
acceptance of any part of the work.
Section 12. Substitution of Securities in Lieu of Retention of Funds.
Pursuant to Public Contract Code Section 22300 et seq., the Contractor will be
entitled to post approved securities with the City or an approved financial institution in
order to have the City release funds retained by the City to insure performance of the
Contract. Contractor shall be required to execute an addendum to this Contract
together with escrow instructions and any other documents in order to effect this
substitution.
Section 13. Completion.
Within ten (10) days after the contract completion date of the Project, Contractor
shall file with the City's Engineer its affidavit stating that all workers and persons
employed, all firms supplying materials, and all subcontractors upon the Project have
been paid in full, and that there are no claims outstanding against the Project for either
labor or material, except those certain items, if any, to be set forth in an affidavit
covering disputed claims, or items in connection with Stop Notices which have been
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B-8
filed under the provisions of the statutes of the State of California. City may require
affidavits or certificates of payment and/or releases from any subcontractor, laborer or
material supplier.
Section 14. Contractor's Employees' Compensation.
A. Davis -Bacon Act:
Contractor will pay and will require all subcontractors to pay all employees on
said Project a salary or wage at least equal to the prevailing rate of per diem wages as
determined by the Secretary of Labor in accordance with the Davis -Bacon Act for each
craft or type of worker needed to perform the Contract.
The provisions of the Davis -Bacon Act shall apply only if the Contract is in
excess of Two Thousand Dollars ($2,000.00) or when twenty-five percent (25%) or
more of the Contract is funded by federal assistance. If the aforesaid conditions are
met, a copy of the provisions of the Davis -Bacon Act to be complied with are
incorporated herein as a part of this Contract and referred to by reference.
B. General Prevailing Rate:
City has ascertained from the State of California Director of Industrial Relations
the general prevailing rate of per diem wages and the general prevailing rate for legal
holiday and overtime work in the locality in which the work is to be performed for each
craft or type of work needed to execute this Contract, and copies of the same are on file
in the Office of the Engineer of City. The Contractor agrees that not less than said
prevailing rates shall be paid to workers employed on this public works contract as
required by Labor Code Section 1774 of the State of California.
C. Forfeiture For Violation:
Contractor shall, as a penalty to the City, forfeit Fifty Dollars ($50.00) for each
calendar day or portion thereof for each worker paid (either by the Contractor or any
subcontractor under it) less than the prevailing rate of per diem wages as set by the
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B"9
0 .
Director of Industrial Relations, in accordance with Sections 1770-1780 of the California
Labor Code for the work provided for in this Contract, all in accordance with Section
1775 of the Labor Code of the State of California.
D. Travel and Subsistence Pay:
Section 1773.8 of the Labor Code of the State of California, regarding the
payment of travel and subsistence payments, is applicable to this Contract and
Contractor shall comply therewith.
E. Apprentices:
Section 1777.5, 1777.6 and 1777.7 of the Labor Code of the State of California,
regarding the employment of apprentices, is applicable to this Contract and the
Contractor shall comply therewith if the prime contract involves Thirty Thousand Dollars
($30,000.00) or more or twenty (20) working days, or more; or if contracts of specialty
Contractors not bidding for work through the general or prime Contractor are Two
Thousand Dollars ($2,000.00) or more or five (5) working days or more.
F. Workday:
In the performance of this Contract, not more than eight (8) hours shall constitute
a day's work, and Contractor shall not require more than eight (8) hours of labor in a day
from any person employed by him hereunder except as provided in paragraph (B)
above. Contractor shall conform to Article 3, Chapter 1, Part 7 (Sections 1810 et seg.)
of the Labor Code of the State of California and shall forfeit to the City as a penalty, the
sum of Twenty-five Dollars ($25.00) for each worker employed in the execution of this
Contract by Contractor or any subcontractor for each calendar day during which any
worker is required or permitted to labor more than eight (8) hours in any one calendar
day and forty (40) hours in any one week in violation of said Article. Contractor shall
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B-10
keep an accurate record showing the name and actual hours worked each calendar day
and each calendar week by each worker employed by Contractor in connection with the
Project.
G. Record of Wages: Inspection:
Contractor agrees to maintain accurate payroll records showing the name,
address, social security number, work classification, straight -time and overtime hours
worked each day and week, and the actual per diem wages paid to each journeyman,
apprentice, worker or other employee employed by it in connection with the Project and
agrees to require that each of its subcontractors does the same. All payroll records
shall be certified as accurate by the applicable Contractor or subcontractor or its agent
having authority over such matters. Contractor further agrees that its payroll records
and those of its subcontractors shall be available to the employee or employee's
representative, the Division of Labor Standards Enforcement, and the Division of
Apprenticeship Standards and shall comply with all of the provisions of Labor Code
Section 1776, in general.
Section 15. Surety Bonds.
Contractor shall, before entering upon the performance of this Contract, furnish
bonds approved by the City Counsel -- one in the amount of one hundred percent
(100%) of the Contract price bid, to guarantee the faithful performance of the work, and
the other in the amount of one hundred percent (100%) of the Contract price bid to
guarantee payment of all claims for labor and materials furnished. This Contract shall
not become effective until such bonds are supplied to and approved by the City.
Section 16. Insurance.
A. Contractor is also aware of the provisions of Section 3700 of the Labor
Code, which requires every employer to be insured against liability for Workers'
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B-11
• 0
Compensation or undertake self-insurance in accordance with the provisions of that
Code and will comply with such provisions before commencing the performance of the
work of this Contract.
B. Contractor and all subcontractors will carry workers' compensation
insurance for the protection of its employees during the progress of the work. The
insurer shall waive its rights of subrogation against City, its officers, agents and
employees and shall issue a certificate to the policy evidencing same.
C. Contractor shall at all times carry, on all operations hereunder, bodily
injury, including death, and property damage liability insurance, including automotive
operations, bodily injury and property damage coverage. All insurance coverage shall
be in amounts specified by City in the Insurance Requirements and shall be evidenced
by the issuance of a certificate in a form prescribed by the City and shall be
underwritten by insurance companies satisfactory to City for all operations, subcontract
work, contractual obligations, product or completed operations, all owned vehicles and
non -owned vehicles. Said insurance coverage obtained by the Contractor, excepting
workers' compensation coverage, shall name the City, its Directors, Officers, Agents,
Employees, Engineers, and Consultants for this contract, and all public agencies from
whom permits will be obtained and their Directors, Officers, Agents and Employees, as
determined by the City, as additional insureds on said policies.
D. Before Contractor performs any work at, or prepares or delivers materials
to, the site of construction, Contractor shall furnish certificates of insurance evidencing
the foregoing insurance coverages and such certificates shall provide the name and
policy number of each carrier and policy and that the insurance is in force and will not
be canceled without thirty (30) days' written notice to City.
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B-12
0
0
Contractor shall maintain all of the foregoing insurance coverages in force until
the work under this Contract is fully completed. The requirement for carrying the
foregoing insurance shall not derogate from the provisions for indemnification of City by
Contractor under Section 17 of this Contract. Notwithstanding nor diminishing the
obligations of Contractor with respect to the foregoing, Contractor shall subscribe for
and maintain in full force and effect during the life of this Contract, the following
insurance in amounts not less than the amounts specified and issued by a company
admitted in California and having a Best's Guide Rating of A -Class VII or better:
Worker's Compensation In accordance with the Workers'
Compensation Act of the State of
California -- Minimum of
$1,000,000
Public Liability, in the form of
either Comprehensive General $1,000,000, per occurrence, or
Liability or Commercial General alternatively,
Liability written on a per -occurrence $5,000,000 aggregate, separate
basis for this project.
Automobile liability, including $1,000,000 per occurrence
non -owned and hired vehicles
City or its representatives shall at all times have the right to inspect and receive
the original or a certified copy of all said policies of insurance, including certificates.
Contractor shall pay the premiums on the insurance hereinabove required.
Section 17. Risk and Indemnification.
All work covered by this Contract done at the site of construction or in preparing
or delivering materials to the site shall be at the risk of Contractor alone. Contractor
agrees to save, indemnify and keep City, its Directors, Officers, Agents, Employees,
Engineers, and Consultants for this Contract, and all public agencies from whom
permits will be obtained and their Directors, Officers, Agents and Employees harmless
against any and all liability, claims, judgments, costs and demands, including demands
arising from injuries or death of persons (Contractors' employees included) and damage
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B-13
0 •
to property, arising directly or indirectly out of the obligations herein undertaken or out of
the operations conducted by Contractor, save and except claims or litigation arising
through the sole negligence or sole willful misconduct of City, and will make good to and
reimburse City for any expenditures, including reasonable attorneys' fees City may incur
by reason of such matters, and if requested by City, will defend any such suits at the
sole cost and expense of Contractor.
Section 18. Stop Notice Administration.
City reserves the right to charge Contractor for City's actual administrative time
(including attorney's time) to administer and process stop notices filed by Contractor's
subcontractors, materialmen, or any other claimant or lienholder.
Section 19. Termination.
A. This Contract may be terminated in whole or in part in writing by either
party in the event of substantial failure by the other party to fulfill its obligations under
this Contract through no fault of the terminating party, provided that no termination may
be effected unless the other party is given: (1) not less than ten (10) calendar days'
written notice (delivered by certified mail, return receipt requested) of intent to terminate,
and (2) an opportunity for consultation with the terminating party prior to termination.
B. This Contract may be terminated in whole or in part in writing by the City
for its convenience, provided that the Contractor is given (1) not less than ten (10)
calendar days' written notice (delivered by certified mail, return receipt requested) of
intent to terminate, and (2) an opportunity for consultation with the terminating party
prior to termination.
C. If termination for default or convenience is effected by the City, an
equitable adjustment in the price provided for in this Contract shall be made, but (1) no
amount shall be allowed for anticipated profit on unperformed services or other work,
and (2) any payment due to the Contractor at the time of termination may be adjusted to
cover any additional costs to the City because of the Contractor's default. If termination
for default is effected by the Contractor, the equitable adjustment shall include a
reasonable profit for services or other work performed, but no adjustment will be
allowed for anticipated profits. The equitable adjustment for any termination shall
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B-14
0 •
provide for payment to the Contractor for services rendered and expenses incurred prior
to the termination, in addition to termination settlement costs reasonably incurred by the
Contractor relating to commitments which had become firm prior to the termination.
D. Upon receipt of a termination action under paragraphs (A) or (B) above,
the Contractor shall (1) promptly discontinue all affected work (unless the notice directs
otherwise), and (2) deliver or otherwise make available to the City all data, drawings,
specifications, reports, estimates, summaries and such other information and materials
as may have been accumulated by the Contractor in performing this Contract whether
completed or in process.
E. Upon termination under paragraphs (A) or (B) above, the City may take
over the work and may award another party an agreement to complete the work under
this Contract.
Contractor agrees to perform all work under this Contract in accordance with the City's
designs, drawings and specifications. The Contractor guarantees for a period of at least
one (1) year from the date of substantial completion of the work that the completed work
is free from all defects due to faulty materials, equipment or workmanship and that he
shall promptly make whatever adjustments or corrections which may be necessary to
cure any defects, including repairs of any damage to other parts of the system resulting
from such defects. The City shall promptly give notice to the Contractor of observed
defects. In the event that the Contractor fails to make adjustments, repairs, corrections
or other work made necessary by such defects, the City may do so and charge the
Contractor the cost incurred. The performance bond shall remain in full force and effect
through the guarantee period.
The Contractor's obligations under this clause are in addition to the Contractor's
other express or implied assurances under this Contract or state law and in no way
diminish any other rights that the City may have against the Contractor for faulty
materials, equipment or work.
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B-15
•
Section 20. Assignment.
is
No assignment by the Contractor of this Contract or any part hereof, or of funds
to be received hereunder, will be recognized by the City unless such assignment has
had prior written approval and consent of the City and the surety.
Section 21. Attorneys' Fees.
If any action at law or in equity is necessary to enforce or interpret the terms of
this Contract, the prevailing party shall be entitled to reasonable attorneys' fees, costs
and necessary disbursements in addition to any other relief to which it may be entitled.
If any action is brought against the Contractor or any subcontractor to enforce a Stop
Notice or Notice to Withhold, which names the City as a party to said action, the City
shall be entitled to reasonable attorneys' fees, costs and necessary disbursements
arising out of the defense of such action by the City, The City shall be entitled to deduct
its costs for any Stop Notice filed, whether court action is involved or not.
Section 22. Resolution of Disputes.
The City and the Contractor shall comply with the revisions of California Public
Contracts Code Section 20104, et seg., regarding resolution of construction claims for
any claims which arise between the Contractor and the City.
Section 23. Notices.
Any notice required or permitted under this Contract may be given by ordinary
mail at the address set forth below. Any party whose address changes shall notify the
other party in writing.
To City: City of San Juan Capistrano
32400 Paseo Adelanto
San Juan Capistrano, CA 92675
Attn: Director of Public Works
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B-16
0
To Contractor: Steven Lapsley
CALEX Engineering Company
23651 North Pine Street
Newhall, CA 91321
0
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B-»
0
IN WITNESS WHEREOF, the parties hereto have executed this Construction
Contract as of the date first hereinabove written.
CITY OF SAN JUAN CAPISTRANO
Dave Adams, City Manager
CONTRACT
C,
By:
CALEX En meed pany
Ryan Seitz, Vice President
ATTEST:
B
R. Monahan, City Clerk
�
NOR'.
�l,
CITY OF SAN JUAN CAPISTRANO AGREEMENT
KRUM RESERVOIR PIPELINE REHABILITATION B-18
City of San Juan Capistrano
Krum Pipeline Rehabilitation
Contract Change Order No. 1
CONTRACTOR:
0
27 June 2006
This Change Order covers changes to the subject contract as described herein. The
Contractor is to construct or furnish equipment and materials, and performs all work as
necessary or required to complete the Change Order items for the prices agreed upon
between the Contractor and the City.
The additional work contained within this Change Order can be performed incidental to
the prime work and within the time allotted for the original Contract and any extensions to
the Contract Time made by this and all previously issued Change Orders, if any. It is
therefore mutually agreed that the number of calendar days extension of time, if any,
provided for in this Change Order is required for the change of work provided herein, and
that no direct or indirect, incidental or consequential costs, expenses, losses or damages
have been or will be incurred by Contractor, except as expressly granted and approved by
this Change Order and, further, that the payment under this Change Order is the final and
complete compensation for the subject work. Payment to the contractor for this Change
Order shall provide full compensation for all equipment, materials, labor, field and home
office overhead, mark-ups and profit necessary to complete the work. By executing this
Change Order, contractor agrees to proceed with the work as a change order per Section
9 of the Construction Contract and waives any right to additional compensation arising out
of work listed in this change order, including without limitation, any claims relating to any
cumulative effect of changer orders, delays, productivity impact or interruption.
In accordance with the contract provisions, the following changes in the contract and/or
contract work are hereby authorized and as compensation, the following additional to or
deductions from the contract price are hereby approved.
Item
Description
Amount
16" HDPE Overflow line relocation as detailed in the attached
$ 9,980.69
01
Exhibit "A"
02
Delete Fire Hydrant as detailed in the attached Exhibit "A"
$ (3,730.74)
E
•
The original cost for this work was: $1,884,000.00
The cost of amendments/change order(s) to date is: $ 0.00
The cost of this amendment/Change Order No. 1 is: $ 5,733.12
Upon approval, the total cost of this project is: $1,889,733.12
The original contract completion date for this work was: 15 May 2006
The additional work included in this Change Order shall add: 32 calendar days
The contract completion date shall be revised as: 16 June 2006
The Contractor agrees to furnish all labor and materials and to perform all other
necessary work required to complete the Change Order items. This document will
become a supplement to the contract and all provision will apply hereto. It is understood
that the Change Order shall become effective when approved by the City.
Furnish and Mychorhizal addition to the hydroseeding as detailed
$ 103.50
03
in the attached Exhibit "A"
04
Delete Rip Rap as detailed in the attached Exhibit "A"
$ (4,131.63)
05
Delete Blow off valve as detailed in the attached Exhibit "A"
$ (3,098.50)
06
Repair existing 10" Line to Krum Reservoir as detailed in the
"A"
$ 12,821.60
attached Exhibit
Demolition and removal of concrete encased well as detailed in
$ 783.20
07
the attached Exhibit "A"
Non Compensable Time Extension due to inclement weather as
$ 0.00
08
detailed in the attached Exhibit "A"
09
Credit for Repair by City Crews and Overtime
$ (6,995.00)
Total for Change Order No. 1
$ 5,733.12
The original cost for this work was: $1,884,000.00
The cost of amendments/change order(s) to date is: $ 0.00
The cost of this amendment/Change Order No. 1 is: $ 5,733.12
Upon approval, the total cost of this project is: $1,889,733.12
The original contract completion date for this work was: 15 May 2006
The additional work included in this Change Order shall add: 32 calendar days
The contract completion date shall be revised as: 16 June 2006
The Contractor agrees to furnish all labor and materials and to perform all other
necessary work required to complete the Change Order items. This document will
become a supplement to the contract and all provision will apply hereto. It is understood
that the Change Order shall become effective when approved by the City.
RECOMMENDED:
a� G'Al"O"
Dave Adams, City Manager
JohnjEllwell, Public Works Director
Civil Engineer
Bill Seitz'RBF, Construction Manager
Gene 06K,4, Calex Engineering
Date
D to
Date
oc ; c' mac'
Date
Date