22-0118_RIVER STREET AQUISITION COMPANY, LLC_Surety AgreementSURETY AGREEMENT
River Street Marketplace
Street and Storm Drain Improvement Plans
For Paseo Adelanto Street
THIS AGREEMENT is made by and between the CITY OF SAN JUAN CAPISTRANO, a
municipal corporation, hereinafter referred to as the "City," and RIVER STREET
ACQUISITION COMPANY LLC, hereinafter referred to as "Developer."
WITNESSETH
WHEREAS, City will issue construction permits to Developer to construct certain
designated public improvements near or adjacent to a portion of that real property located
at 31825 Los Rios Street, San Juan Capistrano, CA 92675. Said work includes construction
of certain STREET AND STORM DRAIN IMPROVEMENT PLANS for Paseo Adelanto,
Permit No. SIP20-003 hereinafter ("Project").
WHEREAS, Condition of Approval #14 of Resolution No. 19-09-24-03 requires the
posting of bonds or financial security in the amount equal to 100 percent of the estimated
improvement cost to ensure satisfactory performance for the installation of related
improvements connected with issuance of Permit No. SIP20-003.
WHEREAS, the City Engineer has reviewed and approved Street and Storm Drain
Improvement Plans and Cost Estimates for said work within the Public Rights -of -Way
(PROW).
NOW, THEREFORE, in consideration of the premises and promises hereinafter
contained, City and Developer agree as follows:
1. Developer's Improvements Obligations. Developer shall, at its sole cost and
expense, provide and furnish all labor, materials and equipment for the Project depicted on
the plans entitled "Street and Storm Drain Improvement Plans — Paseo Adelanto" as
approved by the City Engineer, on 11/08/2021.
2. Developer's Security. Developer shall provide a cash deposit, irrevocable
letter of credit, certificate of deposit or a bond by a duly authorized corporate surety subject
to the approval of the City Attorney, or as approved by the City Engineer, to secure
Developer's improvement obligations required under this Agreement ("Security").
Surety Agreement — Street and Storm Drain Improvement Plans Page 1 of 7
Permit No. SIP20-003
The amount of the Security shall be FIVE HUNDRED FIFTY-EIGHT THOUSAND,
NINE HUNDRED SEVENTY DOLLARS ($558,970.00) for all street and storm drain
improvements as approved by the City Engineer. A copy of the performance bond form, as
approved by the City Attorney, is attached hereto as Exhibit "C" and incorporated herein by
this reference. Copies of approved irrevocable letter of credit forms and certificate of
deposit form are available upon request.
3. Con Ietion of Im rovements. To ensure the protection of the public safety,
health and welfare, Developer shall construct the Project in accordance with the schedule
as set forth in Exhibit "A", and the conditions as set forth in Exhibit "B". Exhibit's "A" and "B"
are attached hereto and incorporated herein by this reference.
4. Developer Default. In the event Developer does not complete the required
improvements, San Juan Capistrano Municipal Code Section 8-14, or abandons the Project
site, or suspends work for more than thirty-one (31) Calendar days without written approval
of the City, or fails to comply with the provisions of San Juan Capistrano Municipal Code
Section 8-14, the City shall have the right to immediately declare a default and to make
demand on Developer's surety for performance of all obligations under this Agreement.
5. Attorney's Fees. Developer agrees to pay City such sum as the court may
judge as reasonable for the legal services of an attorney representing the City in an action
brought to enforce or interpret the obligations of this agreement, and such sum shall be
made a part of any judgment in such action against Developer if such action is determined
in favor of the City.
6. Developer's Work in Safe Condition. Developer shall perform all work in a
safe workmanlike manner and shall take such precautions as may be necessary to warn
and protect the public from any dangerous condition caused by the Project.
7. Liabifity. City, its officials, officers, employees, agents, and volunteers shall
not be liable for any injury to persons or property occasioned by reason of the acts or
omissions of Developer, its agents or employees in the performance of this Agreement.
Developer further agrees to protect, indemnify, and hold harmless City, its officials, officers,
employees, agents, and volunteers from any and all claims, demands, causes of action,
liability or loss of any sort, because of, or arising out of, the alleged acts or omissions of
Developer, its agents or employees in the performance of this Agreement, including all
claims, demands, causes of action, liability, or loss because of, or arising out of, in whole or
in part, the design or construction of the Project. This indemnification and agreement to
hold harmless shall extend to injuries to persons and damages or taking of property
resulting from the design or construction of said Project, and in addition, to adjacent
Surety Agreement — Street and Storm Drain Improvement Plans Page 2 of 7
Permit No. SIP20-003
property owners as a consequence of the diversion of waters from the design or
construction of drainage systems, streets and other improvements.
XXX
SIGNATURES ON FOLLOWING PAGE
Surety Agreement — Street and Storm Drain Improvement Plans Page 3 of 7
Permit No. SIP20-003
SIGNATURE PAGE TO SURETY AGREEMENT
BETWEEN
THE CITY OF SAN JUAN CAPISTRANO
AND
RIVER STREET ACQUISITION COMPANY LLC
FOR
STREET AND STORM DRAIN IMPROVEMENTS — PASEO ADELANTO
IN WITNESS WHEREOF, the parties have executed this Agreement as of
January 18 , 2022
CITY OF SAN JUAN CAPISTRANO RIVER STREET ACQUISITION
COMPANY LLC
D
Joe Par o, City Engineer
Dated:- $ ZZ
Approved as to Form:
Best Best & Krieger LLP
Jeff Ballinger, City Attorney
Dated: January 14, 2022
<_7? `--
Dan Almquist, Manager
Dated: 1 I `1I z
Surety Agreement— Street and Storm Drain Improvement Plans Page 4 of 7
Permit No. SIP20-003
EXHIBIT "Aly
SCHEDULE FOR COMPLETION OF IMPROVEMENTS
SIP20-003 Paseo Adelanto Street
Task
Commencement
and Drainage
Duration/Days
Improvements
Start Finish
1/19/22 1/19/22
0
Mobilization and Dig Alert
5
1/13/22
1/19/22
Demolition
15
1/19/22
2/8/22
WQMP BMP's & Erosion control est.
10
1/21/22
2/3/22
Relocate Water Line
10
2/7/22
2/18/22
Storm Drain Improvements
15
2/17/22
3/9/22
Curb and Gutter
15
3/10/22
3/30/22
Sidewalk PCC
10
10
5
3/31/22
4/14/22
4/28/22
5/5/22
4/13/22
4/27/22
5/4/22
Street Pavement
Striping and Signage
Final Inspection & Completion
10
5/18/22
Total Duration
90
Surety Agreement — Street and Storm Drain Improvement Plans Page 5 of 7
Permit No. SIP20-003
EXHIBIT"B"
CONDITIONS FOR COMPLETION OF IMPROVEMENTS
1. These Off-site Improvements for Street and Storm Drain Improvements shall be in
strict conformance with the approved Improvement Plans for SIP20-003 as well as
the San Juan Capistrano Municipal Code.
2. Street and Storm Drain Improvements shall commence within one hundred twenty
(120) calendar days after issuance of Permit for Sl P20-003.
3. Suspension in excess of thirty-one (31) calendar days of work authorized by
approved improvement plans for subject project, including water quality best
management practices and control measures, shall constitute default of this
agreement unless Developer has received approval from the City authorizing a
suspension in excess of thirty-one (31) calendar days.
4. All work shall be performed in strict observation of the Hours of Operation in
accordance with San Juan Capistrano Municipal Code Section 8-1.03 or as further
conditioned on the haul route and encroachment permit.
5. Contractor shall adhere to conditions of any haul route permit and encroachment
permit issued by the City Engineer.
6. Exoneration of Security: Developer's security shall be reduced to 90% upon signoff
of Street and Storm Drain Improvement Permit. The remaining 10% of the security
given by Developer shall not be released until the expiration of the warranty period
and until any claims filed during the warranty period have been settled. Nothing
herein shall limit the City's rights or the Developer or surety's obligations under this
Agreement.
7. Warranty Period: 1 year from permit signoff by City.
Surety Agreement — Street and Storm Drain Improvement Plans Page 6 of 7
Permit No. SIP20-003
EXHIBIT "C"
PERFORMANCE BOND FORM
Behind this page.
Surety Agreement — Street and Storm Drain Improvement Plans Page 7 of 7
Permit No. SIP20-003
Bond Number: PB0235600005
Premium: $8,385
PUBLIC STREET AND DRAINAGE IMPROVEMENT AGREEMENT
PERFORMANCE AND PAYMENT (LABOR AND MATERIALS) BONDS
KNOW ALL PERSONS BY THESE PRESENTS:
THAT WHEREAS, the City of San Juan Capistrano, California ("City") and River Street
Acquisition Company LLC ("Principal"), have executed an agreement for work consisting of, but not
limited to, the furnishing all labor, materials, tools, equipment, services, and incidentals for all public
improvements and all other required facilities for Street and Storm Drain Improvement Plans for
Paseo Adelanto, hereinafter ("Public Improvements");
WHEREAS, the Public Improvements to be performed by Principal are more particularly
set forth in the Surety Agreement and approved Street and Storm Drain Improvement Plan (SIP20-
003); ("Improvement Agreement");
WHEREAS, the Improvement Agreement is hereby referred to and incorporated herein by
reference; and
WHEREAS, Principal is required by the Improvement Agreement to provide a good and
sufficient bond for performance of the Improvement Agreement, and to guarantee and warranty
the Public Improvements constructed thereunder.
WHEREAS, Principal is required by the Improvement Agreement before entering upon the
performance of the work to provide a good and sufficient payment bond to secure the claims to
which reference is made in Title 3 (commencing with Section 9000) of Part 6 of Division 4 of the
California Civil Code.
NOW, THEREFORE, Principal and Philadelphia Indemnity Insurance Company ("Surety") a corporation
organized and existing under the laws of the State of Pennsylvania ,
and duly authorized to transact business under the laws of the State of California, are held and
firmly bound unto City and all contractors, subcontractors, laborers, material suppliers, and other
persons employed in the performance of the Improvement Agreement and referred to in Title 3
(commencing with Section 9000) of Part 6 of Division 4 of the California Civil Code in the sum of
FIVE HUNDRED FIFTY-EIGHT THOUSAND, NINE HUNDRED SEVENTY DOLLARS
($558,970.00), said sum being not less than one hundred percent (100%) of the total cost of the
Public Improvements as set forth in the Improvement Agreement, we bind ourselves, our heirs,
executors and administrators, successors and assigns, jointly and severally, firmly by these
presents, for materials furnished or labor thereon of any kind, or for amounts due under the
Unemployment Insurance Act with respect to this work or labor, that the Surety will pay the same in
an amount not exceeding the amount hereinabove set forth.
THE CONDITION OF THIS OBLIGATION is such, that if Principal, his or its heirs,
executors, administrators, successors or assigns, shall in all things stand to and abide by, and
well and truly keep and perform the covenants, conditions, agreements, guarantees, and
warranties in the Improvement Agreement and any alteration thereof made as therein provided,
to be kept and performed at the time and in the manner therein specified and in all respects
according to their intent and meaning, and to indemnify and save harmless City, its officers,
employees, and agents, as stipulated in the Improvement Agreement, then this obligation shall
become null and void; otherwise it shall be and remain in full force and effect.
61147 02100\24632175.1
As part of the obligation secured hereby, and in addition to the face amount specified
therefor, there shall be included costs and reasonable expenses and fees, including reasonable
attorney's fees, incurred by City in successfully enforcing such obligation, all to be taxed as costs
and included in any judgment rendered.
It is hereby expressly stipulated and agreed that this bond shall inure to the benefit of any
and all persons, companies, and corporations entitled to file claims under Title 3 (commencing
with Section 9000) of Part 6 of Division 4 of the Civil Code, so as to give a right of action to them
or their assigns in any suit brought upon this bond.
Surety, for value received, hereby stipulates and agrees that no change, extension of time,
alteration, or addition to the terms of the Improvement Agreement, or to any plans, profiles, and
specifications related thereto, or to the Public Improvements to be constructed thereunder, shall
in any way affect its obligations on this bond, and it does hereby waive notice of any such change,
extension of time, alteration, or addition.
Should the condition of this bond be fully performed, then this obligation shall become null
and void, otherwise it shall be and remain in full force and effect.
This bond is executed and filed to comply with Section 66499, et seq., of the California
Government Code as security for performance of the Improvement Agreement and security for
the one-year guarantee and warranty of the Public Improvements.
After substantial completion of the water improvements, City will withhold 25% of the
bond as warranty of the improvement or receive a Warranty Bond for 25% of the construction cost
for one full year after acceptance of the water facilities by the City.
Prior to the release of 75% of the water improvement bond or acceptance of a replacement
warranty bond, the Principal must submit a request in writing for release of the bond along with
proofs of all payments to the contractors and vendors working under the water and sewer
improvement bond to the City Utilities Department for review and approval. Once there is no
evidence of any lien from vendors and contractors, City has 45 days to release the bond and/or
accept a replacement warranty bond.
IN WITNESS WHEREOF, we have hereunto set our hands and seals this 22nd day of
December 2021.
(Corporate Seal) Principal
RIVER STREET ACQUISITION COMPANY
LLC
�1
Dan Almquist, Manager
Surety
(Corporate Seal) Philadelphia Indemnity Insurance Com an
By yt'f C &=
Matthew C. Gaynor
61147 02100\24632175.1
(Attach Attorney -in -Fact Certificate)
Title Attorney -in -Fact
The rate of premium on this bond is $15.00 per thousand. The total amount of premium
charges is $ 8.385.00
(The above must be filled in by corporate attorney.)
THIS IS A REQUIRED FORM
Any claims under this bond may be addressed to:
(Name and Address of Surety) Philadelphia Indemnity Insurance Company
One Bala Plaza Suite 100
Bala Cynwyd. PA 19004-0950
(Name and Address of Agent or Representative for service of process in California, if different
from above)
Rancho Mesa Insurance Services, Inc.
250 Riverview Parkway, Suite 401
Santee CA 92071
(Telephone number of Surety and Agent or Representative for service of process in
California)
Philadelphia Indemnity Insurance Company: 626-660-5695
Rancho Mesa Insurance Services: 619-937-0164
61147.02100\24632175.1
Notary Acknowledgment
A notary public or other officer completing this certificate
verifies only the identity of the individual who signed the
document to which this certificate is attached, and not the
truthfulness, accuracy, or validity of that document.
STATE OF CALIFORNIA
COUNTY OF
On 20 , before me, v Notary Public, personally
appeared l C ( who proved to me on the basis of satisfactory
evidence to be theerson(A whose name(o is/d subscribed to the within instrument and acknowied eto
me that he/Akthoi executed the same in his/h lthor authorized capacity(it-s�, and that by his/; /tk6ir
signature(g on the instrument the person(s), or the entity upon behalf of which the person(s�,acted, executed
the instrument.
I certify under PENALTY OF PERI Y under the laws of the State of California that the foregoing paragraph
IS true an MARY W, CARNES
Notary Public - California 1
a Los Angeles County WITNESS my hand and official seal.
Commission M 2267227
My Comm. Expires Dec 13. 7.Q
Signature of Notary Public
OPTIONAL
Though the information below is not required by law, it may prove valuable to persons relying on the document
and could prevent fraudulent removal and reattachment of this form to another document.
CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT
❑ Individual
❑ Corporate Officer
Title(s)
❑ Partner(s) ❑ Limited
❑ General
❑ Attorney -In -Fact
❑ Trustee(s)
❑ Guardian/Conservator
❑ Other:
Signer is representing:
Name Of Person(s) Or Entity(ies)
NOTE: This acknowledgment is to be completed for Principal.
61147.02100\24632175.1
Title or Type of Document
Number of Pages
Date of Document
ACKNOWLEDGMENT
A notary public or other officer completing this
certificate verifies only the identity of the individual
who signed the document to which this certificate is
attached, and not the truthfulness, accuracy, or
validity of that document.
State of California
County of San Diego
On December 27, 2021 before me, Andrew Roberts, Notary Public
(insert name and title of the officer)
personally appeared Matthew C. Gaynor
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are
subscribed to the within instrument and acknowledged to me that he/she/they executed the same in
his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the
person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing
paragraph is true and correct.
WITNESS my ha d and official seal.;'DQc' ROAMNr=•�t'. "ei�31c-:;,lifurni
1 ,I,• �3r�+t:
Signature (Seal)
PHILADELPHIA INDEMNITY INSURANCE COMPANY
One Bala Plaza, Suite 100
Bala Cynwyd, PA 19004-0950
Power of Attorney
KNOW ALL PERSONS BY THESE PRESENTS: That PHILADELPHIA INDEMNITY INSURANCE COMPANY (the Company), a corporation organized and
existing under the laws of the Commonwealth of Pennsylvania, does hereby constitute and appoint Matthew C. Gaynor, Daniel Frazee, Kim Vasquez, of
Rancho Mesa Insurance Services, Inc. its true and lawful Attorney-in-fact with full authority to execute on its behalf bonds, undertakings, recognizances and
other contracts of indemnity and writings obligatory in the nature thereof, issued in the course of its business and to bind the Company thereby, in an amount not to
exceed'S5M90.000.
This Power of Attorney is granted and is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of
PHILADELPHIA INDEMNITY INSURANCE COMPANY on the 14' of November, 2016.
RESOLVED: That the Board of Directors hereby authorizes the President or any Vice President of the
Company: (1) Appoint Attomey(s) in Fact and authorize the Attorney(s) in Fact to execute
on behalf of the Company bonds and undertakings, contracts of indemnity and other
writings obligatory in the nature thereof and to attach the seal of the Company thereto; and
(2) to remove, at any time, any such Attorney -in -Fact and revoke the authority given. And,
be it
FURTHER
RESOLVED: That the signatures of such officers and the seal of the Company may be affixed to any
such Power of Attorney or certificate relating thereto by facsimile, and any such Power of
Attorney so executed and certified by facsimile signatures and facsimile seal shall be valid
and binding upon the Company in the future with respect to any bond or undertaking to
which it is attached.
IN TESTIMONY WHEREOF, PHILADELPHIA INDEMNITY INSURANCE COMPANY HAS CAUSED THIS INSTRUMENT TO BE SIGNED AND ITS
CORPORATE SEALTO BE AFFIXED BY ITS AUTHORIZED OFFICE THIS 5TH DAY OF MARCH, 2021,
1927 4C
(Seal),,,,
Joh Glomb. President & CrQ
Philadelphia Indemnity Insurance Company
On this 5" day of March, 2021 before me came the individual who executed the preceding instrument, to me personally known, and being by me duly sworn said that he
is the therein described and authorized officer of the PHILADELPHIA INDEMNITY INSURANCE COMPANY; that the seal affixed to said instrument is the
Corporate seal of said Company; that the said Corporate Seal and his signature were duly affixed.
Notary Public:
Oommorkwoallh at Pennaylvanle - Notary seal
Veimnsa tlrkcynzie, NotaryPublic
Montgomery County
My commiselon explres November 3, 2024
Commisslon number 1366394
Memner. asnnsyrva^ ATsa[letanof Holmes residing at: Bala Cynwyd, PA
My commission expires: November 3, 2024
I, Edward Sayago, Corporate Secretary of PHILADELPHIA INDEMNITY INSURANCE COMPANY, do hereby certify that the foregoing resolution of the Board of
Directors and the Power of Attorney issued pursuant thereto on the 5' day March, 2021 are true and correct and are still in full force and effect I do further certify that
John Glomb, who executed the Power of Attorney as President, was on the date of execution of the attached Power of Attorney the duly elected President of
PHILADELPHIA INDEMNITY INSURANCE COMPANY.
In Testimony Whereof I have subscribed my name and affixed the facsimile seal of each Company this 27th day of December 20 21
Edward Sayago, Corporate Secretary
PHILADELPHIA INDEMNITY INSURANCE COMPANY
R I D E R
To be attached to and form part of Bond No. PB0235600005
on behalf of River Street Acquisition Company LLC , as Principal
in favor of The City of San Juan Capistrano _ , as Obligee
executed by Philadelphia Indemnity Insurance Company , as Surety
Project: Street and Storm Drain Improvement Plan (SIP20-003) for Paseo
Adelanto
in the amount of FIVE HUNDRED FIFTY-EIGHT THOUSAND, NINE HUNDRED ($558,970.00)
SEVENTY DOLLARS
Effective: December 27.2021
NOW THEREFORE, it is hereby agreed and understood that the bond is amended to read as follows:
The bond number has changed:
From: Bond Number PB0235600005
To: Bond Number PB02356000005
Effective: December 27, 2021
PROVIDED, HOWEVER, that all conditions of this bond remain unchanged.
Signed, Sealed and Dated this 30th
day of December
2021
Philadelphia Indemnity Insurance Company
BY: 17
L
Matthew C. Gaynor, Atlo y -in -Fact
PHILADELPHIA INDEMNITY INSURANCE COMPANY
One Bala Plaza, Suite 100
Bala Cynwyd, PA 19004-0950
Power of Attorney
KNOW ALL PERSONS BY THESE PRESENTS: That PHILADELPHIA INDEMNITY INSURANCE COMPANY (the Company), a corporation organized and
existing under the laws ofthe Commonwealth of Pennsylvania, does hereby constitute and appoint Matthew C. Gaynor, Daniel Frazee, Kim Vasquez, of
Rancho Mesa Insurance Services, Inc. its true and lawful Attorney-in-fact with full authority to execute on its behalfbonds, undertakings, recognizances and
other contracts of indemnity and writings obligatory in the nature thereof, issued in the course of its business and to bind the Company thereby, in an amount not to
exceed $30.000.000".
This Power of Attorney is granted and is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of
PHILADELPHIA INDEMNITY INSURANCE COMPANY on the 14" of November. 2016,
RESOLVED: That the Board of Directors hereby authorizes the President or any Vice President of the
Company: (1) Appoint Attorney(s) in Fact and authorize the Attorney(s) in Fact to execute
on behalf of the Company bonds and undertakings, contracts of indemnity and other
writings obligatory in the nature thereof and to attach the sea] ofthe Company thereto; and
(2) to remove, at any time, any such Attorney -in -Fact and revoke the authority given. And,
be it
FURTHER
RESOLVED: That the signatures of such officers and the sea] of the Company may be affixed to any
such Power of Attorney or certificate relating thereto by facsimile, and any such Power of
Attorney so executed and certified by facsimile signatures and facsimile sea] shall be valid
and binding upon the Company in the future with respect to any bond or undertaking to
which it is attached.
IN TESTIMONY WHEREOF, PHILADELPHIA INDEMNITY INSURANCE COMPANY HAS CAUSED THIS INSTRUMENT TO BE SIGNED AND ITS
CORPORATE SEALTO BE AFFIXED BY ITS AUTHORIZED OFFICE THIS 5TH DAY OF MARCH, 2021.
1927 _
Lu k7 -
(Sea]) ""'"
Joh Glomb. President iL CEO
Philadelphia Indemnity Insurance Company
On this 5' day of March, 2021 before me came the individual who executed the preceding instrument, to me personally known, and being by me duly sworn said that he
is the therein described and authorized officer of the PHILADELPHIA INDEMNITY INSURANCE COMPANY; that the seal affixed to said instrument is the
Corporate seal of said Company; that the said Corporate Seal and his signature were duly affixed.
commonws4 tth a I Pe nn sytya nis - Notl ry Sea I
Vanessa Mckenzie, Notary Public
Montgomery County
My commission ezplres November 3, 2024
Commission number 1366394
M 0r0or. odn n syryV R As soei Ilion o! Holarkol
Notary Public:
residing at: Bala Cynwyd, PA
My commission expires: November 3, 2024
I, Edward Sayago, Corporate Secretary of PHILADELPHIA INDEMNITY INSURANCE COMPANY, do hereby certify that the foregoing resolution of the Board of
Directors and the Power of Attorney issued pursuant thereto on the 5h day March, 2021 are true and correct and are still in full force and effect. I do further certify that
John Glomb, who executed the Power of Attorney as President, was on the date of execution of the attached Power of Attorney the duly elected President of
PHILADELPHIA INDEMNITY INSURANCE COMPANY.
In Testimony Whereof I have subscribed my name and affixed the facsimile sea] of each Company this 30th day of December 20 21
1 1927 s Edward Sayago, Corporate Secretary
PHILADELPHIA INDEMNITY INSURANCE COMPANY
ACKNOWLEDGMENT
A notary public or other officer completing this
certificate verifies only the identity of the individual
who signed the document to which this certificate is
attached, and not the truthfulness, accuracy, or
validity of that document.
State of California
County of San Diego
On December 30, 2021
before me, Andrew Roberts, Notary Public
(insert name and title of the officer)
personally appeared Matthew C. Gaynor
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are
subscribed to the within instrument and acknowledged to me that he/she/they executed the same in
his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the
person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing
paragraph is true and correct.
uANDREW RMEWS
WITNESS my h nd o cial seal < d N`A Notary f ubliC • Ulifornia
Sari Diega County
Corrurrissiocr A 2317120
`my Comm. Expires Nx 26, 2023
Signature (Seal)