Loading...
19-0311_TOLL WEST COAST LLC_Grading Surety Agreement GRADING SURETY AGREEMENT THIS AGREEMENT is made by and between the CITY OF SAN JUAN CAPISTRANO, a municipal corporation, hereinafter referred to as the "City," and Toll West Coast L.L.C., hereinafter referred to as "Developer." WITNESSETH WHEREAS, City will issue Precise Grading Permit No B16-0860 (Production) & B18-1041 (Models) to Developer to construct certain designated improvements upon a portion of that real property located at Tract 16752 Lots 1-82, San Juan Capistrano, CA, such work being commonly referred to as The Ocean Hills ("Project"). WHEREAS, San Juan Capistrano Municipal Code Section 8-2.08 requires the posting of financial security to secure the faithful performance for the grading and installation of related improvements connected with issuance of grading permits including the construction of drainage and protection devices and any other corrective work to remove and eliminate engineering and geological hazards. WHEREAS, San Juan Capistrano Municipal Code Section 8-2.09 authorizes the Building Official to require additional bonding as security to ensure against adverse aesthetic impacts arising from incomplete grading and/or improvements from development projects which have not been completed. WHEREAS, the Building Official finds that the proposed Project site is highly prominent and visible to the community, has unique topographic features or involves substantial grading of slope areas. NOW, THEREFORE, in consideration of the premises and promises hereinafter contained, City and Developer agree as follows: 1. Developer's Improvements Obligations. Developer shall, at its sole cost and expense, provide and furnish all labor, materials and equipment for the Project depicted on the plans entitled "PRODUCTION PRECISE GRADING FOR OCEAN HILLS — TRACT 16752 — LOTS 1-65 & 69-82" and MODEL PRECISE GRADING TRACT 16752 LOT 66- 68" as reviewed and signed by the City Engineer on F 62 e y 25 (v g c L( It 2019. The grading permit and plans, w ich describe all the work to be constructed pursuant to this Agreement, are on file in the office of the City's Building Official. Grading Surety Agreement, Permit#'s B16-0860 & B18-1041 Page 1 61147.02100\24835741.2 ORIGINAL 2. Developer's Security. Developer shall provide a cash deposit, irrevocable letter of credit, certificate of deposit or a bond by a duly authorized corporate surety subject to the approval of the City Attorney, or as approved by the City Engineer, to secure Developer's improvement obligations required under this Agreement ("Security"). The amount of the Security shall be $1,034,535 for all onsite grading, storm drain and street improvements as approved by the City Engineer and attached as Exhibit "D". This Security shall also serve as security for restoration of the Project site. A copy of the performance bond form, as approved by the City Attorney, is attached hereto as Exhibit"C" and incorporated herein by this reference. Copies of approved irrevocable letter of credit forms and certificate of deposit form are available upon request. 3. Completion of Improvements. To ensure the protection of the public safety, health and welfare, Developer shall construct the Project in accordance with the schedule as set forth in Exhibit"A", and the conditions as set forth in Exhibit"B". Exhibits "A" and "B" are attached hereto and incorporated herein by this reference. 4. Developer Default. In the event Developer does not complete the required improvements, including erosion and silt control measures within the time required, using Best Management Practices (BMP) in implementing a Water Quality Management Plan in full compliance with Orange County National Pollutant Discharge Elimination System (NPDES) Storm Water Implementation Agreement and San Juan Capistrano Municipal Code Section 8-14, or abandons the Project site, or suspends work for more than twenty (20) working days without written approval of the City, City shall have the right to immediately declare a default and to make demand on Developer's surety for performance of all obligations under this Agreement. 5. Restoration of Site. San Juan Capistrano Municipal Code Section 8-2.09 allows the City to require bonding as security to ensure against adverse aesthetic impacts arising from incomplete grading, drainage and/or improvements which includes illicit non- storm drain water discharge. The purpose of this security shall be to restore the property to a safe and acceptable condition in the event the Developer defaults. This restoration shall include but not be limited to the following: A. Dismantle and/or demolish improvements; B. Grade property to its original contours as shown on the approved grading plans or to contours as directed by the City Engineer. Grading Surety Agreement, Permit#'s B16-0860 & B18-1041 Page 2 61147.02100\24835741.2 C. Remove all debris and construction materials from the site; and D. Install erosion and silt control devices, including hydroseeding, to insure a uniform vegetative cover, or equivalent stabilization measures which include the use of such Best Management Practices as blankets, fiber matrices, catch basin filters, or other erosion resistant soil coverings or treatments to satisfaction of the Director of Engineering and Building. 6. Attorney's Fees. Developer agrees to pay City such sum as the court may judge as reasonable for the legal services of an attorney representing the City in an action brought to enforce or interpret the obligations of this agreement, and such sum shall be made a part of any judgment in such action against Developer if such action is determined in favor of the City. 7. Developer's Work in Safe Condition. Developer shall perform all work in a safe workmanlike manner and shall take such precautions as may be necessary to warn and protect the public from any dangerous condition caused by the Project. 8. Liability. City, its officials, officers, employees, agents, and volunteers shall not be liable for any injury to persons or property occasioned by reason of the acts or omissions of Developer, its agents or employees in the performance of this Agreement. Developer further agrees to protect, indemnify, and hold harmless City, its officials, officers, employees, agents, and volunteers from any and all claims, demands, causes of action, liability or loss of any sort, because of, or arising out of, the alleged acts or omissions of Developer, its agents or employees in the performance of this Agreement, including all claims, demands, causes of action, liability, or loss because of, or arising out of, in whole or in part, the design or construction of the Project. This indemnification and agreement to hold harmless shall extend to injuries to persons and damages or taking of property resulting from the design or construction of said Project, and in addition, to adjacent property owners as a consequence of the diversion of waters from the design or construction of drainage systems, streets and other improvements. SIGNATURES ON FOLLOWING PAGE Grading Surety Agreement, Permit#'s B16-0860 & B18-1041 Page 3 61147.02100\24835741 2 SIGNATURE PAGE TO GRADING SURETY AGREEMENT BETWEEN THE CITY OF SAN JUAN CAPISTRANO AND Toll West Coast L.L.C., Developer IN WITNESS WHEREOF, the parties have executed this Agreement as of , 2019 CIT OF SAN JUAN CAPISTRANO By By: -o, Building Official Developer Date I 3 1' / ' 7714.- m'z Printed Name g,040 4,2 er Approved as to Form: By: Title hl ✓/S/o ti f'��(ge717 Jeff Ballinger, City Attorney By: Printed Name P074)—/ i7/ Title 7 Grading Surety Agreement, Permit#'s B16-0860 & B18-1041 Page 4 61147.02100\24835741.2 SIGNATURE PAGE TO GRADING SURETY AGREEMENT BETWEEN THE CITY OF SAN JUAN CAPISTRANO AND Toll West Coast L.L.C., Developer IN WITNESS WHEREOF, the parties have executed this Agreement as of 2019 CITY 1:2/4 SA 1 JUAF4 CAPISTRANO By: / (4.- By: CT1-os Yado, Building Official Developer Dated: 3 U //`� — 7714.'" Sera Printed Name *040 L 7 ti ►te' Approved as to Form: By: -� Title hi v/5/o Av ®' b f 7 7 t'_ Jeff Ballinger, City Attorney • By: Printed Name -0'-/ �/ Title //• 0 . Grading Surety Agreement, Permit#'s B16-0860&B18-1041 Page 4 61147.02100\24835741.2 EXHIBIT "A" SCHEDULE FOR COMPLETION OF IMPROVEMENTS Task Completion Date 1 . Complete precise grading 3///20 2. Start installation of onsite Storm drain work /// /7 3. Start & Finish Erosion Control work 2////7 4. Street Improvements 2/ ///1 5. Storm Drain Improvements 2////1 Grading Surety Agreement, Permit#'s B16-0860 & B18-1041 Page 5 61147.02100\24835741 2 EXHIBIT "B" CONDITIONS FOR COMPLETION OF IMPROVEMENTS 1 . The grading for this project shall be in strict conformance with the grading plans as well as the San Juan Capistrano Municipal Code. 2. Grading operations shall commence within fourteen (14) calendar days after issuance of Grading Permit. Winter grading will be conducted in strict accordance with the dynamic erosion and silt control plan submitted by the Developer, and approved by the City. This erosion and silt control plan reflects erosion and silt mitigation measures for expected grading conditions as the work progresses through the winter season and shall not be amended except with the permission of the City. In the event Developer does not wish to implement winter grading, or permission for winter grading is rescinded, static erosion and silt control plans reflecting current conditions of grading shall be submitted within ten (10) days of cessation of work. These plans shall: 1 . Identify all pollutant sources including sources of sediment that may affect the quality of storm water discharges associated with the construction activity. 2. Include the erosion and sediment control planting and hydroseeding to insure a uniform vegetative cover or equivalent stabilization measures which include the use of such Best Management Practices as blankets, fiber matrices, catch basin filters or other erosion resistant soil covering or treatments to the satisfaction of the City Engineer. 3. Suspension in excess of twenty (20) working days of work authorized by approved grading plans and grading permit for subject property, including erosion and sediment control measures and landscaping and irrigation, shall constitute default of this agreement. 4. The supervising civil engineer and soils engineer shall file biweekly progress reports of all grading operations with the Building Official. An interim compaction report, for that work completed at the time work is suspended for the rainy season, shall be filed with the Building Official. This interim report shall conform to the grading code requirements for final compaction reports. Grading Surety Agreement, Permit#'s B16-0860 & B18-1041 Page 6 61147.02100\24835741.2 5. Contractor shall control dust to the satisfaction of the Building Official or his deputy. During grading, Contractor shall keep water truck on site and dampen work area, grounds, and loaded trucks. 6. Grading operations suspended during the rainy season shall be resumed no later than 15 days from date of suspension termination. 7. Installation of interim erosion and sediment control devices and systems shall commence within seven (7) days after rough grade certification has been approved by the Building Official and must be completed within fifteen (15)days of rough grad certification. Final erosion and sediment controls devices, planting, landscaping and irrigation systems shall be installed prior to final inspection of the grading permit. 8. All work shall be performed in strict observation of the Hours of Operation in accordance with San Juan Capistrano Municipal Code Section 8-1 .03. 9. Contractor shall adhere to conditions of haul route permit and encroachment permit issued by the City Engineer. 10. Parking for construction crew is to be on-site. 11 . Exoneration of Security: Developer's security shall be reduced to 90% upon signoff of precise grading permit. No security given by Developer shall be released until the expiration of the warranty period and until any claims filed during the warranty period have been settled. Nothing herein shall limit the City's rights or the Developer or surety's obligations under this Agreement. 12. Warranty Period: 1 year from permit signoff by City. Grading Surety Agreement, Permit#'s B16-0860 & B18-1041 Page 7 61147.02100\24835741.2 • • BOND NO. 39BSBHX8536 INITIAL PREMIUM: $7759.00 SUBJECT TO RENEWAL GRADING SURETY AGREEMENT PERFORMANCE BOND KNOW ALL PERSONS BY THESE PRESENTS: WHEREAS, the City of San Juan Capistrano, California ("City") and Toll West Coast LLC ("Principal"), have executed an agreement for work consisting of, but not limited to, the furnishing all labor, materials, tools, equipment, services, and incidentals for all grading and installation of related improvements for Lot 1-82 Tract 16752, B16-0860 Productions & B18- 1041 Models ("the Work"); WHEREAS, the Work to be performed by Principal is more particularly set forth in that certain Grading Surety Agreement dated —, 2019, ("Agreement"), which Agreement is incorporated herein by this reference; and; 3/6//9 WHEREAS, the Improvement Agreement is hereby referred to and incorporated herein by reference; and WHEREAS, Principal is required by the Agreement to provide a good and sufficient bond for performance of the Agreement, and to guarantee and warranty the Work performed thereunder. NOW, THEREFORE, Principal and Hartford Fire Insurance Company ("Surety"), a corporation organized and existing under the laws of the State of Connecticut, and duly authorized to transact business under the laws of the State of California, are held and firmly bound unto City in the sum of One Million Thirty Four Thousand Five Hundred Thirty Five and 00/100 Dollars ($1,034,535.00), for which amount well and truly to be made, we bind ourselves, our heirs, executors and administrators, successors and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION is such, that if Principal, his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions, agreements, guarantees, and warranties in the Agreement and any alteration thereof made as therein provided, to be kept and performed at the time and in the manner therein specified and in all respects according to their intent and meaning, and shall indemnify and save harmless City, its officers, employees, and agents, as stipulated in the Agreement, then this obligation shall become null and void; otherwise it shall be and remain in full force and effect. As part of the obligation secured hereby, and in addition to the face amount specified therefor, there shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, incurred by City in successfully enforcing such obligation, all to be taxed as costs and included in any judgment rendered. Grading Surety Agreement, Permit#'s B 16-0860 & B18-1041 61147.02100\24835741.2 • Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration, or addition to the terms of the Agreement, or to any plans, profiles, and specifications related thereto, or to the Work to be performed thereunder, shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration, or addition. IN WITNESS WHEREOF, the seal, if any, and signature of the Principal is hereto affixed, and the corporate seal and the name of the Surety is hereto affixed and attested by its duly authorized Attorney-in-Fact at Paoli, PA this 28 TH day of FEBRUARY, 2019. Toll West Coast LLC, Hartford Fire Insurance Company a Delaware limited liability company Principal Surety /??ZBy: / i By . 11 — '. uni• . A e ey-in-Fact Grading Surety Agreement, Permit#'s B16-0860 & B18-1041 61147.02100\24835741.2 CALIFORNIA ALL-PURPOSE ACKNOWLEDGEMENT Civil Code § 1 189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfullness,accuracy or validity of that document. State of PENNSYLVANIA County of CHESTER On FEBRUARY 28,2019 before me, ARLENE OSTROFF , Notary Public Dale Name and Idle of Notary personally appeared DANIEL P.DUNIGAN Name and or Names of Signer(s) Who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized COMMONWEALTH OF PENNSYLVANIA capacity(ies), and that by his/her/their signature(s)on the instrument the person(s), or the entity upon behalf of NOTARIAL SEAL which the person(s) acted, executed the instrument. ARLENE Tp Notary Publu Toowwnshinship,Chester County My Commission Expires December 3,2020 I certify under PENALTY OF PERJURY under the laws of [_ itUstown ` the State of California that the foregoing paragraph is true and correct. Witness my ha d official se . Signature ,biyC/ Aary Publi re Place Notary Public Seal Above OPTIONAL Though the information below is not required by law,it may prove valuable to the persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document Description of Attached Document Title or Type of Document Document Date Number of Pages: Signer's Name: ❑ Individual ❑ Individual ❑ Corporate Officer—Title(s): 0 Corporate Officer—Title(s): ❑ Partner- 0 Limited 0 General RIGHT THUMBPRINT ❑ Partner- ❑Limited 0 General RIGHTTHUMBPRINT ❑ Guardian or Conservator OFSIGNER L"] Guardian or Conservator OF SIGNER Top of thumb Top of thumb 0 Attorney-in-Fact 0 Attorney-in-Fact ❑ Trustee ❑Trustee ❑ Other: 0 Other Signer is representing Signer is representing- Hartford Fire Insurance Company • ♦.••♦•••••••••••••♦••••••4♦••♦••••••....••••••.••.,•••.•,••••.•11•♦ Direct Inquiries/Claims to: THE HARTFORD • POWER OF ATTORNEYBOND,T-12 One Hartford Plaza Hartford,Connecticut 06155 Bond.Claims(&thehartford.com calf:888-266-3488 or fax:860-757-5835 KNOW ALL PERSONS BY THESE PRESENTS THAT: Agency Name: THE SIMKISS AGENCY INC Agency Code: 39-320116 X Hartford Fire Insurance Company,a corporation duly organized under the laws of the State of Connecticut X Hartford Casualty Insurance Company,a corporation duly organized under the laws of the State of Indiana X Hartford Accident and Indemnity Company, a corporation duly organized under the laws of the State of Connecticut Hartford Underwriters Insurance Company,a corporation duly organized under the laws of tbe State of Connecticut Twin City Fire Insurance Company,a corporation duly organized under the laws of the State of Indiana Hartford Insurance Company of Illinois, a corporation duly organized under the laws of the State of Illinois Hartford Insurance Company of the Midwest, a corporation duly organized under the laws of the State of Indiana Hartford Insurance Company of the Southeast, a corporation duly organized under the laws of the State of Florida having their home office in Hartford, Connecticut, (hereinafter collectively referred to as the"Companies")do hereby make, constitute and appoint, up to the amount of Unlimited William F. Simkiss, Daniel P. Dunigan, Richard J. Decker, Brian C. Block, Joseph W. Kolok Jr. , James L. Hahn of PAOLI, Pennsylvania their true and lawful Attorney(s)-in-Fact, each in their separate capacity if more than one is named above, to sign its name as surety(ies) only as delineated above by ®, and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof, on behalf of the Companies in their business of guaranteeing the fidelity of persons,guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law, In Witness Whereof, and as authorized by a Resolution of the Board of Directors of the Companies on May 6,2015 the Companies have caused these presents to be signed by its Senior Vice President and its corporate seals to be hereto affixed, duly attested by its Assistant Secretary. Further, pursuant to Resolution of the Board of Directors of the Companies, the Companies hereby unambiguously affirm that they are and will be bound by any mechanically applied signatures applied to this Power of Attorney. ,p�lTr tak,L �ssgr .F- tett��,� t `G04.e.,ri: 7:-s; ° �► f ♦ ZC.y,.`.1--±..�sI�/9i'/. `v'��k{'NJw.+ai��G. ``aI �� J: , r� g J •`,s� dkal`�4s y�2 f rJts BKe 1979I979J 9e,/ \:•••:'• JA Vet sp • /14' e John Gray,Assistant Secretary M.Ross Fisher,Senior Vice President STATE OF CONNECTICUT ss. Hartford COUNTY OF HARTFORD ))) On this 5th day of January, 2018, before me personally came M.Ross Fisher,to me known,who being by me duly sworn,did depose and say: that he resides in the County of Hartford, State of Connecticut; that he is the Senior Vice President of the Companies, the corporations described in and which executed the above instrument; that he knows the seals of the said corporations; that the seals affixed to the said instrument are such corporate seals; that they were so affixed by authority of the Boards of Directors of said corporations and that he signed his name thereto by like authority. 4t�T„k,A� 44. ,4:0R (/ Kathleen T.Maynard Notary Public CERTIFICATE My Commission Expires July 31,2021 I,the undersigned,Assistant Vice President of the Companies, DO HEREBY CERTIFY that the above and foregoing is a true and correct copy of the Power of Attorney executed by said Companies,which is still in full force effective as of FEBRUARY 28, 2019 Signed and sealed at the City of Hartford. w.r • YxF'it r� f. y ;.,... / l” y4. \, �JA" .o �$ iPB Yew "'Pr' g• �r ,Zis4*• • 3 ICY ti i:f• 7 - 2979 �1 Kevin Heckman,Assistant Vice President POA 2018 • HARTFORD FIRE INSURANCE COMPANY Hartford, Connecticut Financial Statement, December 31, 2017 Statutory Basis ASSETS LIABILITIES U.S. Government Bonds $ 577,913,529 Reserve for Claims $ Bonds of Other Governments 136,631,915 and Claim Expense 8,425,803,806 State, County Municipal Reserve for Unearned Premiums 2,110,221,060 Miscellaneous Bonds 5,713,878,455 Reserve for Taxes, License Stocks 5,418,718,399 and Fees 53,958,612 Short Term Investments 299,018,356 Miscellaneous Liabilities 2,349,289,613 $ 12,146,160,654 Total Liabilities $ 12,939,273,091 Real Estate $ 333,492,680 Capital Paid In $ 55,320,000 Cash 109,093,732 Surplus 9,860,704,902 Agents' Balances (Under 90 Day) 2,994,735,438 Other Invested Assets 4,524,749,529 Surplus as regards Policyholders $ 9,916,024,902 Miscellaneous 2,747,065,960 Total Liabilities, Capital Total Admitted Assets $ 22,855,297,993 and Surplus $ 22,855,297,993 STATE OF CONNECTICUT COUNTY OF HARTFORD SS. CITY OF HARTFORD Michael R. Hazel, Vice President and Controller, and Allen R. Craig, Assistant Secretary of the Hartford Fire Insurance Company, being duly sworn, each deposes and say that the foregoing is a true and correct statement of the said company's • financial condition as of December 31, 2017. Subscribed and sworn to before me this 6th day of March, 2018. (VO Vice Presii`d�er>‘a d ontroller 64/1_,je V./4/1,eser‘ Notary Public a LAURIE HANSEN R� NOTARY PUBLIC Assistant Secretary State of Connecticut My Commission Expires December 31, 2018 Form CS-19-37 HF printed in U.S.A. PROJECT OR TRACT NUMBER OWNER/SUBDIVIDER Ocean Hills-TR 16752-Lots 1 thru 65 and 69 thru 82 7t(O - 0? 'O Toll Brothers ENGINEER CALCULATED BY ADAMS-STREETER CIVIL ENGINEERS,INC. BUD (DATE:1/3112019 JOB No.: 17-2192.02 PRELIMINARY CONSTRUCTION COST ESTIMATE No. DESCRIPTION I UNIT PRICE I TOTAL PRODUCTION PRECISE GRADING 1 INSTALL 12"SQUARE NDS 1212 AREA DRAIN INLET WITH ADAPTER&OUTLET 320 EA @ $ 100.00 $ 32,000 2 CONSTRUCT 6"TO 0"CURB TRANSITION 2 EA @ $ 45.00 $ 90 3 CONSTRUCT 6"P.C,C.CURB ONLY 152 LF @ $ 15.00 $ 2.280 4 INSTALL 4"PVC SCH 40 AREA DRAIN PIPE 21,390 LF @ $ 12.00 $ 256.680 5 INSTALL 4"SDR-35 SEWER PIPIE 274 LF @ $ 50.00 $ 13,700 6 CONSTRUCT 18"BROOKS BOX INLET WITH LOCAL DEPRESSION 1 EA @ $ 2,000.00 $ 2,000 7 CONSTRUCT STORM DRAIN CLEANOUT 6 EA @ $ 500,00 $ 3,000 8 CONSTRUCT DRIVEWAY APPROACH 13,390 SF @ $ 10.00 $ 133,900 9 CORE DRILL CATCH BASIN AND AND INSTALL 4"AREA DRAIN PIPE 16 EA @ $ 300.00 $ 4,800 10 CURB CORE WITH 3"PIPE OUTLET 145 EA @ $ 200.00 $ 29,000 11 CONNECT ROOF GUTTER DOWN SPOUT TO YARD DRAIN 869 EA @ 5 40.00 $ 34,760 12 CONSTRUCT CONCRETE DRIVEWAY PER SOILS ENGINEER'S RECOMMENDATIONS 35.670 SF Coil $ 7.00 $ 249,690 14 PROVIDE WALL OPENING FOR SECONDARY DRAINAGE 79 EA (a $ 25.00 $ 1,975 16 CONSTRUCT CONCRETE WALKWAY PER SOILS ENGINEER'S RECOMMENDATIONS 6,075 SF @ $ 5.00 $ 30,375 18 CONSTRUCT 6"CURB&GUTTER PER CITY STD 301 285 LF @ $ 20.00 $ 5,700 19 1"WATER SERVICE 366 LF @ 5 15.00 $ 5,490 20 CONSTRUCT 4"AC WITH SEAL COAT OVER 8"AB 4,235 SF @ $ 4.00 $ 16,940 21 CONSTRUCT 4"ATRIUM GRATE(NDS-75) 81 SF Coil $ 50.00 $ 4,050 22 INSTALL 6"PVC SCH 80 AREA DRAIN PIPE 172 LF @ $ 20.00 $ 3.440 23 SAWCUT&REMOVE 1'WIDE STRIP OF AC/AB PAVEMENT.REPLACE WITH FULL DEPTH AC. 552 LF @ $ 10.00 $ 5,520 24 INSTALL 6"PVC SCH 40 PIPE 36 LF @ $ 20.00 $ 720 25 INSTALL MWS-L-4-13-V BIOFILTRATION STRUCTURE 1 EA @ $ 31,500.00 $ 31,500, 26 INSTALL DVERT DIVERSION WEIR 1 EA @ $ 1,500.00 $ 1,500 27 CONSTRUCT JUNCTION STRUCTURE PIPE TO PIPE CONNECTION 1 EA @ $ 500.00 $ 500 1 28 INSTALL 8"PVC BEND 2 EA @ $ 60.00 $ 120 29 CORE DRILL CATCH BASIN FOR 8"PVC LOW FLOW DRAIN PIPE 1 EA @ $ 500.00 $ 500 30 INSTALL PVC 4"TEE WITH RISER AND 4"NDS-13 GRATE 2 EA @ $ 80.00 $ 160 31 INSTALL 12"SQUARE BROOKS BOX 1212 CB 3 EA @ $ 500.00 $ 1,500 35 INSTALL 6"PVC SCH 40 AREA DRAIN PIPE 445 LF @ $ 16.00 $ 7,120 36 INSTALL 4"PVC SCH 80 AREA DRAIN PIPE 20 LF ® $ 16.00 $ 320 EARTHWORK SPOILS FROM FOUNDATIONS,SIDEWALKS,SWALES,AND SIDEYARD GRADING (50 CY PER LOT X 82 LOTS=4.100 CY TOTAL) 79 LOTS $ 500.00 $ 39,500 EROSION CONTROL 30 DRAIN INLET GRAVEL BAG PROTECTION 564 EA @ $ 4.00 $ 2,256 31 SIGLE ROW OF GRAVEL BAGS 7,650 LF @ $ 2.00 $ 15,300 33 CATCH BASIN PROTECTION 19 EA @ $ 100.00 $ 1,900 37 GRAVEL BAG VELOCITY REDUCER 550 LF @ $ 4.00 $ 2.200 �!6FESS/ SUB-TOTAL IMPROVEMENTS $ 940,486 'S '/.,_ ,:a A. 8,979(40 10%CONTINGENCY $ 94.049 PU n �, � � ytv0�0 A 0 TOTAL IMPROVEMENTS _ $ 1.034,535 A u wfiJ D W = 0 70862 % m I tP )4r�OF o,zN\ F CALF PAGE 1 OF 1 11 - Og(0O