The URL can be used to link to this page

18-0116_SIEMENS INDUSTRY, INC_Contract Documents and Specifications61147.91007\30425843.2 CITY OF SAN JUAN CAPISTRANO SAN JUAN CAPISTRANO, CALIFORNIA CONTRACT DOCUMENTS AND SPECIFICATIONS FOR [LED STREETLIGHT CONVERSION PROJECT] <Month> <Year> 61147.91007\30425843.2 -i- TABLE OF CONTENTS TABLE OF CONTENTS Page 00 52 13 – CONTRACT ................................................................................................................ 4 00 61 13 – BOND FORMS ............................................................................................................ 8 00 72 13 – GENERAL CONDITIONS ......................................................................................... 17 ARTICLE 1. DEFINED TERMS .......................................................................................... 17 ARTICLE 2. CONTRACT DOCUMENTS ........................................................................... 20 ARTICLE 3. PRECONSTRUCTION AND CONSTRUCTION COMMUNICATION ................................................................................................... 21 ARTICLE 4. CONTRACT DOCUMENTS: COPIES & MAINTENANCE ............................ 21 ARTICLE 5. EXAMINATION OF DRAWINGS, SPECIFICATIONS AND SITE OF WORK ................................................................................................................. 22 ARTICLE 6. MOBILIZATION .............................................................................................. 22 ARTICLE 7. EXISTENCE OF UTILITIES AT THE WORK SITE ........................................ 23 ARTICLE 8. SOILS INVESTIGATIONS ............................................................................. 24 ARTICLE 9. CONTRACTOR’S SUPERVISION ................................................................. 25 ARTICLE 10. WORKERS ................................................................................................... 25 ARTICLE 11. INDEPENDENT CONTRACTORS ............................................................... 25 ARTICLE 12. SUBCONTRACTS ........................................................................................ 25 ARTICLE 13. VERIFICATION OF EMPLOYMENT ELIGIBILITY ....................................... 25 ARTICLE 14. REQUESTS FOR SUBSTITUTION .............................................................. 26 ARTICLE 15. SHOP DRAWINGS ...................................................................................... 27 ARTICLE 16. SUBMITTALS ............................................................................................... 27 ARTICLE 17. MATERIALS ................................................................................................. 28 ARTICLE 18. PERMITS AND LICENSES .......................................................................... 29 ARTICLE 19. TRENCHES .................................................................................................. 29 ARTICLE 20. TRAFFIC CONTROL .................................................................................... 30 ARTICLE 21. DIVERSION OF RECYCLABLE WASTE MATERIALS ................................ 31 ARTICLE 22. REMOVAL OF HAZARDOUS MATERIALS ................................................. 31 ARTICLE 23. SANITARY FACILITIES ............................................................................... 31 ARTICLE 24. AIR POLLUTION CONTROL ....................................................................... 31 ARTICLE 25. LAYOUT AND FIELD ENGINEERING ......................................................... 31 ARTICLE 26. TESTS AND INSPECTIONS ........................................................................ 32 ARTICLE 27. PROTECTION OF WORK AND PROPERTY .............................................. 32 ARTICLE 28. CONTRACTOR’S MEANS AND METHODS ............................................... 33 TABLE OF CONTENTS (Continued) Page 61147.91007\30425843.2 -ii- CONTRACT—LED STREETLIGHT CONVERSION PROJECT ARTICLE 29. AUTHORIZED REPRESENTATIVES .......................................................... 33 ARTICLE 30. HOURS OF WORK ...................................................................................... 33 ARTICLE 31. PAYROLL RECORDS .................................................................................. 34 ARTICLE 32. PREVAILING RATES OF WAGES .............................................................. 35 ARTICLE 33. PUBLIC WORKS CONTRACTOR REGISTRATION ................................... 36 ARTICLE 34. EMPLOYMENT OF APPRENTICES ............................................................ 36 ARTICLE 35. NONDISCRIMINATION/EQUAL EMPLOYMENT OPPORTUNITY ............. 36 ARTICLE 36. DEBARMENT OF CONTRACTORS AND SUBCONTRACTORS ............... 37 ARTICLE 37. LABOR/EMPLOYMENT SAFETY ................................................................ 37 ARTICLE 38. INSURANCE ................................................................................................ 38 ARTICLE 39. FORM AND PROOF OF CARRIAGE OF INSURANCE .............................. 40 ARTICLE 40. TIME FOR COMPLETION AND LIQUIDATED DAMAGES ......................... 41 ARTICLE 41. COST BREAKDOWN AND PERIODIC ESTIMATES .................................. 42 ARTICLE 42. PROGRESS ESTIMATES AND PAYMENT ................................................. 43 ARTICLE 43. SECURITIES FOR MONEY WITHHELD ..................................................... 44 ARTICLE 44. CHANGES AND EXTRA WORK. ................................................................. 44 ARTICLE 45. FINAL ACCEPTANCE AND PAYMENT ....................................................... 56 ARTICLE 46. OCCUPANCY .............................................................................................. 57 ARTICLE 47. INDEMNIFICATION ..................................................................................... 57 ARTICLE 48. PROCEDURE FOR RESOLVING DISPUTES ............................................. 58 ARTICLE 49. CITY’S RIGHT TO TERMINATE CONTRACT ............................................. 60 ARTICLE 50. WARRANTY AND GUARANTEE OF WORK ............................................... 62 ARTICLE 51. DOCUMENT RETENTION & EXAMINATION .............................................. 65 ARTICLE 52. SEPARATE CONTRACTS ........................................................................... 65 ARTICLE 53. NOTICE AND SERVICE THEREOF ............................................................ 66 ARTICLE 54. NOTICE OF THIRD PARTY CLAIMS .......................................................... 66 ARTICLE 55. STATE LICENSE BOARD NOTICE ............................................................. 66 ARTICLE 56. INTEGRATION ............................................................................................. 66 ARTICLE 57. ASSIGNMENT OF CONTRACT ................................................................... 66 ARTICLE 58. CHANGE IN NAME AND NATURE OF CONTRACTOR’S LEGAL ENTITY ..................................................................................................................... 67 ARTICLE 59. ASSIGNMENT OF ANTITRUST ACTIONS ................................................. 67 ARTICLE 60. PROHIBITED INTERESTS .......................................................................... 67 ARTICLE 61. CONTROLLING LAW ................................................................................... 67 TABLE OF CONTENTS (Continued) Page 61147.91007\30425843.2 -iii- CONTRACT—LED STREETLIGHT CONVERSION PROJECT ARTICLE 62. JURISDICTION; VENUE .............................................................................. 67 ARTICLE 63. LAWS AND REGULATIONS ........................................................................ 67 ARTICLE 64. PATENTS ..................................................................................................... 68 ARTICLE 65. OWNERSHIP OF CONTRACT DOCUMENTS ............................................ 68 ARTICLE 66. NOTICE OF TAXABLE POSSESSORY INTEREST .................................... 68 ARTICLE 67. SURVIVAL OF OBLIGATIONS .................................................................... 68 00 73 13 – SPECIAL CONDITIONS ........................................................................................... 69 01 00 00 – GENERAL REQUIREMENTS ................................................................................... 72 EXHIBIT “A” CHANGE ORDER FORM ...................................................................................... 87 EXHIBIT “B” TECHNICAL SPECIFICATIONS AND SCOPE OF WORK .................................... 87 61147.91007\30425843.2 -4- CONTRACT—led streetlight conversion project CONTRACT—LED STREETLIGHT CONVERSION PROJECT This CONTRACT is made and entered into this ____ day of January 2018, by and between City of San Juan Capistrano, sometimes hereinafter called “City,” and Siemens Industry Inc., sometimes hereinafter called “Contractor.” WITNESSETH: That the parties hereto have mutually covenanted and agreed, and by these presents do covenant and agree with each other as follows: a. SCOPE OF WORK. The Contractor shall perform all Work within the time stipulated in the Contract, and shall provide all labor, materials, equipment, tools, utility services, and transportation to complete all of the Work required in strict compliance with the Contract Documents as specified in Article 5, below, for the following Project: LED STREETLIGHT CONVERSION PROJECT The Contractor and its surety shall be liable to the City for any damages arising as a result of the Contractor’s failure to comply with this obligation. b. TIME FOR COMPLETION. Time is of the essence in the performance of the Work. The Work shall be commenced on the date stated in the Distric’s Notice to Proceed. The Contractor shall complete all Work required by the Contract Documents within 180 calendar days from the commencement date stated in the Notice to Proceed. By its signature hereunder, Contractor agrees the time for completion set forth above is adequate and reasonable to complete the Work. c. CONTRACT PRICE. The City shall pay to the Contractor as full compensation for the performance of the Contract, subject to any additions or deductions as provided in the Contract Documents, and including all applicable taxes and costs, the sum of Four Hundred Fifty-Two Thousand Three Hundred Eighty-Eight and 15/100 Dollars ($452,388.15). Payment shall be made as set forth in the General Conditions. d. LIQUIDATED DAMAGES. In accordance with Government Code section 53069.85, it is agreed that the Contractor will pay the City the sum set forth in Section 00 73 13, Article 1.11 for each and every calendar day of delay beyond the time prescribed in the Contract Documents for finishing the Work, as Liquidated Damages and not as a penalty or forfeiture. In the event this is not paid, the Contractor agrees the City may deduct that amount from any money due or that may become due the Contractor under the Contract. This Article does not exclude recovery of other damages specified in the Contract Documents. e. COMPONENT PARTS OF THE CONTRACT. The “Contract Documents” include the following: Public Works Contractor Registration Certification Performance Bond Payment (Labor and Materials) Bond General Conditions Special Conditions Technical Specifications and Scope of Work Addenda 61147.91007\30425843.2 -5- CONTRACT—led streetlight conversion project Plans and Drawings Standard Specifications for Public Works Construction “Greenbook”, latest edition, Except Sections 1-9 Applicable Local Agency Standards and Specifications, as last revised Approved and fully executed change orders Any other documents contained in or incorporated into the Contract The Contractor shall complete the Work in strict accordance with all of the Contract Documents. All of the Contract Documents are intended to be complementary. Work required by one of the Contract Documents and not by others shall be done as if required by all. This Contract shall supersede any prior agreement of the parties. f. PROVISIONS REQUIRED BY LAW AND CONTRACTOR COMPLIANCE. Each and every provision of law required to be included in these Contract Documents shall be deemed to be included in these Contract Documents. The Contractor shall comply with all requirements of applicable federal, state and local laws, rules and regulations, including, but not limited to, the provisions of the California Labor Code and California Public Contract Code which are applicable to this Work. g. INDEMNIFICATION. Contractor shall provide indemnification and defense as set forth in the General Conditions. h. PREVAILING WAGES. Contractor shall be required to pay the prevailing rate of wages in accordance with the Labor Code which such rates shall be made available at the City’s Administrative Office or may be obtained online at http://www.dir.ca.gov and which must be posted at the job site. [REMAINDER OF PAGE LEFT INTENTIONALLY BLANK] 61147.91007\30425843.2 -6- CONTRACT—led streetlight conversion project IN WITNESS WHEREOF, this Contract has been duly executed by the above-named parties, on the day and year above written. CITY OF SAN JUAN CAPISTRANO Name of Contractor By _____________________________________ Name and Title: _________________________ License No. ____________________________ Date: __________________________________ By______________________________ Benjamin Siegel City Manager Date: ____________________________ (CONTRACTOR’S SIGNATURE MUST BE NOTARIZED AND CORPORATE SEAL AFFIXED, IF APPLICABLE) Approved as to form this _____________day of 20___. _______________________________ Attorney for City of San Juan Capistrano ATTEST: By: Maria Morris City Clerk San Juan Capistrano END OF CONTRACT 61147.91007\30425843.2 -7- CONTRACT—led streetlight conversion project Notary Acknowledgment A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA COUNTY OF ______________ On , 20___, before me, _______________________________, Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT 61147.91007\30425843.2 -8- 00 61 13 – BOND FORMS 00 61 13 – BOND FORMS 1.1 Performance Bond. KNOW ALL PERSONS BY THESE PRESENTS: THAT WHEREAS, the City of San Juan Capistrano, (hereinafter referred to as “City”) has awarded to _________________________, (hereinafter referred to as the “Contractor”) an agreement for the LED Streetlight Conversion Project Contract, (hereinafter referred to as the “Project”). WHEREAS, the work to be performed by the Contractor is more particularly set forth in the Contract Documents for the Project dated ________________, (hereinafter referred to as “Contract Documents”), the terms and conditions of which are expressly incorporated herein by reference; and WHEREAS, the Contractor is required by said Contract Documents to perform the terms thereof and to furnish a bond for the faithful performance of said Contract Documents. NOW, THEREFORE, we, ______________________, the undersigned Contractor and ________________________________________________ as Surety, a corporation organized and duly authorized to transact business under the laws of the State of California, are held and firmly bound unto the City in the sum of ___________________________ DOLLARS, ($____________), said sum being not less than one hundred percent (100%) of the total amount of the Contract, for which amount well and truly to be made, we bind ourselves, our heirs, executors and administrators, successors and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, that, if the Contractor, his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and agreements in the Contract Documents and any alteration thereof made as therein provided, on its part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their intent and meaning; and shall faithfully fulfill all obligations including the one (1) year guarantee of all materials and workmanship; and shall indemnify and save harmless the City, its officials, officers, employees, and authorized volunteers, as stipulated in said Contract Documents, then this obligation shall become null and void; otherwise it shall be and remain in full force and effect. As a part of the obligation secured hereby and in addition to the face amount specified therefore, there shall be included costs and reasonable expenses and fees including reasonable attorney’s fees, incurred by City in enforcing such obligation. As a condition precedent to the satisfactory completion of the Contract Documents, unless otherwise provided for in the Contract Documents, the above obligation shall hold good for a period of one (1) year after the acceptance of the work by City, during which time if Contractor shall fail to make full, complete, and satisfactory repair and replacements and totally protect the City from loss or damage resulting from or caused by defective materials or faulty workmanship. The obligations of Surety hereunder shall continue so long as any obligation of Contractor remains. Nothing herein shall limit the City’s rights or the Contractor or Surety’s obligations 61147.91007\30425843.2 -9- 00 61 13 – BOND FORMS under the Contract, law or equity, including, but not limited to, California Code of Civil Procedure Section 337.15. Whenever Contractor shall be, and is declared by the City to be, in default under the Contract Documents, the Surety shall remedy the default pursuant to the Contract Documents, or shall promptly, at the City’s option: i. Take over and complete the Project in accordance with all terms and conditions in the Contract Documents; or ii. Obtain a bid or bids for completing the Project in accordance with all terms and conditions in the Contract Documents and upon determination by Surety of the lowest responsive and responsible bidder, arrange for a Contract between such bidder, the Surety and the City, and make available as work progresses sufficient funds to pay the cost of completion of the Project, less the balance of the contract price, including other costs and damages for which Surety may be liable. The term “balance of the contract price” as used in this paragraph shall mean the total amount payable to Contractor by the City under the Contract and any modification thereto, less any amount previously paid by the City to the Contractor and any other set offs pursuant to the Contract Documents. iii. Permit the City to complete the Project in any manner consistent with California law and make available as work progresses sufficient funds to pay the cost of completion of the Project, less the balance of the contract price, including other costs and damages for which Surety may be liable. The term “balance of the contract price” as used in this paragraph shall mean the total amount payable to Contractor by the City under the Contract and any modification thereto, less any amount previously paid by the City to the Contractor and any other set offs pursuant to the Contract Documents. Surety expressly agrees that the City may reject any contractor or subcontractor which may be proposed by Surety in fulfillment of its obligations in the event of default by the Contractor. Surety shall not utilize Contractor in completing the Project nor shall Surety accept a bid from Contractor for completion of the Project if the City, when declaring the Contractor in default, notifies Surety of the City’s objection to Contractor’s further participation in the completion of the Project. The Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract Documents or to the Project to be performed thereunder shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Contract Documents or to the Project. [REMAINDER OF PAGE LEFT INTENTIONALLY BLANK] 61147.91007\30425843.2 -10- 00 61 13 – BOND FORMS IN WITNESS WHEREOF, we have hereunto set our hands and seals this _______ day of ______________, 20___. (Corporate Seal) Contractor/ Principal By Title (Corporate Seal) Surety By Attorney-in-Fact (Attach Attorney-in-Fact Certificate) Title The rate of premium on this bond is ____________ per thousand. The total amount of premium charges is $_______________________________. (The above must be filled in by corporate attorney.) THIS IS A REQUIRED FORM Any claims under this bond may be addressed to: (Name and Address of Surety) ___________________________________________ ___________________________________________ ___________________________________________ (Name and Address of Agent or ___________________________________________ Representative for service of ___________________________________________ process in California, if different ___________________________________________ from above) (Telephone number of Surety ___________________________________________ and Agent or Representative for service of process in California) 61147.91007\30425843.2 -11- 00 61 13 – BOND FORMS Notary Acknowledgment A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA COUNTY OF ______________ On , 20___, before me, _______________________________, Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT 61147.91007\30425843.2 -12- 00 61 13 – BOND FORMS Notary Acknowledgment A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA COUNTY OF ______________ On , 20___, before me, _______________________________, Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT 61147.91007\30425843.2 -13- 00 61 13 – BOND FORMS 1.2 Payment Bond (Labor and Materials). KNOW ALL MEN BY THESE PRESENTS That WHEREAS, the City of San Juan Capistrano (hereinafter designated as the “City”), by action taken or a resolution passed ___________________ , 20_____, has awarded to Siemens Industry Inc., hereinafter designated as the “Principal,” a contract for the work described as follows: LED STREETLIGHT CONVERSION PROJECT (the “Project”); and WHEREAS, said Principal is required to furnish a bond in connection with said contract; providing that if said Principal or any of its Subcontractors shall fail to pay for any materials, provisions, provender, equipment, or other supplies used in, upon, for or about the performance of the work contracted to be done, or for any work or labor done thereon of any kind, or for amounts due under the Unemployment Insurance Code or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of said Principal and its Subcontractors with respect to such work or labor the Surety on this bond will pay for the same to the extent hereinafter set forth. NOW THEREFORE, we, the Principal and __________________________ as Surety, are held and firmly bound unto the City in the penal sum of Four Hundred Fifty-Two Thousand Three Hundred Eighty-Eight and 15/100 Dollars ($452,388.15) lawful money of the United States of America, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if said Principal, his or its subcontractors, heirs, executors, administrators, successors or assigns, shall fail to pay any of the persons named in Civil Code Section 9100, fail to pay for any materials, provisions or other supplies, used in, upon, for or about the performance of the work contracted to be done, or for any work or labor thereon of any kind, or amounts due under the Unemployment Insurance Code with respect to work or labor performed under the contract, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department or Franchise Tax Board from the wages of employees of the contractor and his subcontractors pursuant to Revenue and Taxation Code Section 18663, with respect to such work and labor the Surety or Sureties will pay for the same, in an amount not exceeding the sum herein above specified, and also, in case suit is brought upon this bond, all litigation expenses incurred by the City in such suit, including reasonable attorneys’ fees, court costs, expert witness fees and investigation expenses. This bond shall inure to the benefit of any of the persons named in Civil Code Section 9100 so as to give a right of action to such persons or their assigns in any suit brought upon this bond. It is further stipulated and agreed that the Surety on this bond shall not be exonerated or released from the obligation of this bond by any change, extension of time for performance, addition, alteration or modification in, to, or of any contract, plans, specifications, or agreement pertaining or relating to any scheme or work of improvement herein above described, or pertaining or relating to the furnishing of labor, materials, or equipment therefore, nor by any change or modification of any terms of payment or extension of the time for any payment pertaining or relating to any scheme or work of improvement herein above described, nor by any rescission or attempted rescission or attempted rescission of the contract, agreement or bond, nor by any conditions precedent or subsequent in the bond attempting to limit the right of 61147.91007\30425843.2 -14- 00 61 13 – BOND FORMS recovery of claimants otherwise entitled to recover under any such contract or agreement or under the bond, nor by any fraud practiced by any person other than the claimant seeking to recover on the bond and that this bond be construed most strongly against the Surety and in favor of all persons for whose benefit such bond is given, and under no circumstances shall Surety be released from liability to those for whose benefit such bond has been given, by reason of any breach of contract between the owner or City and original contractor or on the part of any obligee named in such bond, but the sole conditions of recovery shall be that claimant is a person described in Civil Code Section 9100, and has not been paid the full amount of his claim and that Surety does hereby waive notice of any such change, extension of time, addition, alteration or modification herein mentioned, including but not limited to the provisions of sections 2819 and 2845 of the California Civil Code. IN WITNESS WHEREOF, we have hereunto set our hands and seals this _______ day of ______________, 20__. (Corporate Seal) Contractor/ Principal By Title (Corporate Seal) Surety By Attorney-in-Fact (Attach Attorney-in-Fact Certificate) Title 61147.91007\30425843.2 -15- 00 61 13 – BOND FORMS Notary Acknowledgment A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA COUNTY OF ______________ On , 20___, before me, _______________________________, Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT 61147.91007\30425843.2 -16- 00 61 13 – BOND FORMS Notary Acknowledgment A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA COUNTY OF ______________ On , 20___, before me, _______________________________, Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT 61147.91007\30425843.2 -17- 00 72 13 – GENERAL CONDITIONS 00 72 13 – GENERAL CONDITIONS ARTICLE 1. DEFINED TERMS Whenever used in the Contract Documents and printed with initial capital letters, the terms listed below will have the meanings indicated which are applicable to both the singular and plural thereof. In addition to terms specifically defined below, terms with initial capital letters in the Contract Documents include references to identified articles and paragraphs, and the titles of other documents or forms. A. Act of God – An earthquake of magnitude of 3.5 or higher on the Richter scale or a tidal wave. B. Addenda -- Written or graphic instruments issued prior to the submission of Bids which clarify, correct, or change the Contract Documents. C. Additional Work -- New or unforeseen work will be classified as “Additional Work” when the City’s Representative determines that it is not covered by the Contract. D. Applicable Laws -- The laws, statutes, ordinances, rules, codes, regulations, permits, and licenses of any kind, issued by local, state or federal governmental authorities or private authorities with jurisdiction (including utilities), to the extent they apply to the Work. E. Change Order (“CO”) -- A document that authorizes an addition, deletion, or revision in the Work or an adjustment in the Contract Price or the Contract Times, issued on or after the Effective Date of the Contract, in accordance with the Contract Documents and in the form contained in the Contract Documents. F. Change Order Request (“COR”) -- A request made by the Contractor for an adjustment in the Contract Price and/or Contract Times as the result of a Contractor- claimed change to the Work. This term may also be referred to as a Change Order Proposal (“COP”), or Request for Change (“RFC”). G. City -- The City of San Juan Capistrano. H. City Council, Council -- The City Council of the City. I. City’s Representative -- The individual or entity as identified in the Special Conditions to act as the City’s Representative. J. Claim -- A demand or assertion by the City or Contractor seeking an adjustment of Contract Price or Contract Times, or both, or other relief with respect to the terms of the Contract. A demand for money or services by a third party is not a Claim. K. Contract -- The entire integrated written agreement between the City and Contractor concerning the Work. “Contract” may be used interchangeably with “Agreement” in the Contract Documents. The Contract supersedes prior negotiations, representations, or agreements, whether written or oral, and includes all Contract Documents. 61147.91007\30425843.2 -18- 00 72 13 – GENERAL CONDITIONS L. Contract Documents -- The documents listed in Section 00 52 13, Article 5. Some documents provided by the City to Contractor, including but not limited to reports and drawings of subsurface and physical conditions are not Contract Documents. M. Contract Price -- Amount to be paid by the City to the Contractor as full compensation for the performance of the Contract and completion of the Work, subject to any additions or deductions as provided in the Contract Documents, and including all applicable taxes and costs. N. Contract Times -- The number of days or the dates stated in the Contract Documents to: achieve defined Milestones, if any; and to complete the Work so that it is ready for final payment. O. Contractor -- The individual or entity with which the City has contracted for performance of the Work. P. Contractor’s Designated On-Site Representative -- The Contractor’s Designated On- Site Representative will be as identified in Section 00 72 13, Article 3 and shall not be changed without prior written consent of the City. Q. Daily Rate -- The Daily Rate stipulated in the Contract Documents as full compensation to the Contractor due to the City’s unreasonable delay to the Project that was not contemplated by the parties. R. Day -- A calendar day of 24 hours measured from midnight to the next midnight. S. Defective Work -- Work that is unsatisfactory, faulty, or deficient; or that does not conform to the Contract Documents; or that does not meet the requirements of any inspection, reference standard, test, or approval referenced in the Contract Documents. T. Demobilization -- The complete dismantling and removal by the Contractor of all of the Contractor’s temporary facilities, equipment, and personnel at the Site. U. Drawings -- That part of the Contract Documents prepared by of the Engineer of Record which graphically shows the scope, extent, and character of the Work to be performed by Contractor. Shop Drawings and other Contractor submittals are not Drawings as so defined. V. Effective Date of the Contract -- The date indicated in the Contract on which it becomes effective, but if no such date is indicated, it means the date on which the Contract is signed and delivered by the last of the two parties to sign and deliver. W. Engineer, whenever not qualified, shall mean the Director of Public Works and Utilities of the City, acting either directly or through properly authorized agents, such agents acting severally within the scope of the particular duties entrusted to them. On all questions concerning the acceptance of materials, machinery, the classifications of material, the execution of work, conflicting interest of the contractors performing related work and the determination of costs, the decision of the Engineer, duly authorized by the City Council, shall be binding and final upon both parties. 61147.91007\30425843.2 -19- 00 72 13 – GENERAL CONDITIONS X. Green Book -- The current edition of the Standard Specifications for Public Works Construction promulgated by the Joint Cooperative Committee of the Southern California Chapter American Public Works Association and the Southern California Districts of the Associated General Contractors of California. Y. Hazardous Waste -- The term “Hazardous Waste” shall have the meaning provided in Section 104 of the Solid Waste Disposal Act (42 U.S.C. § 6903) as amended from time to time or, as defined in Section 25117 of the Health and Safety Code, that is required to be removed to a class I, class II, or class III disposal site in accordance with provisions of existing law, whichever is more restrictive. Z. Holiday – The Holidays occur on: New Year’s Day - January 1 President’s Day – Third Monday in February Memorial Day - Last Monday in May Independence Day - July 4 Labor Day - First Monday in September Veteran’s Day - November 11 Thanksgiving Day - Fourth Thursday in November Friday after Thanksgiving Christmas Eve – December 24 Christmas Day - December 25 Day After Christmas – December 26 New Year’s Eve – December 31 If any Holiday listed above falls on a Saturday, Saturday and the preceding Friday are both Holidays. If the Holiday should fall on a Sunday, Sunday and the following Monday are both Holidays. AA. Notice of Completion -- The form which may be executed by the City and recorded by the county where the Project is located constituting final acceptance of the Project. BB. Notice to Proceed -- A written notice given by the City to Contractor fixing the date on which the Contractor may proceed with the Work and when Contract Times will commence to run. CC. Project -- The total construction of which the Work to be performed under the Contract Documents may be the whole, or a part. DD. Recyclable Waste Materials -- Materials removed from the Site which are required to be diverted to a recycling center rather than an area landfill. Recyclable Waste Materials include asphalt, concrete, brick, concrete block, and rock. EE. Schedule of Submittals -- A schedule, prepared and maintained by Contractor, of required submittals and the time requirements to facilitate scheduled performance of related construction activities. 61147.91007\30425843.2 -20- 00 72 13 – GENERAL CONDITIONS FF. Shop Drawings -- All drawings, diagrams, illustrations, schedules, and other data or information which are specifically prepared or assembled by or for Contractor and submitted by Contractor to illustrate some portion of the Work. GG. Specifications -- That part of the Contract Documents consisting of written requirements for materials, equipment, systems, standards and workmanship as applied to the Work, and certain administrative requirements and procedural matters applicable thereto. HH. Stop Payment Notice -- A written notice as defined in Civil Code section 8044. II. Subcontractor -- An individual or entity other than a Contractor having a contract with any other entity than the City for performance of any portion of the Work at the Site. JJ. Submittal -- Written and graphic information and physical samples prepared and supplied by the Contractor demonstrating various portions of the Work. KK. Supplier -- A manufacturer, fabricator, supplier, distributor, material man, or vendor having a direct contract with Contractor or with any Subcontractor to furnish materials or equipment used in the performance of the Work or to be incorporated in the Work. LL. Technical Specifications and Scope of Work – Technical information describing the Work to be conducted pursuant to the Contract, attached hereto as Exhibit B. MM. Underground Facilities -- All underground pipelines, conduits, ducts, cables, wires, manholes, vaults, tanks, tunnels, or other such facilities or attachments, and any encasements containing such facilities, including those that convey electricity, gases, steam, liquid petroleum products, telephone or other communications, cable television, water, wastewater, storm water, other liquids or chemicals, or traffic or other control systems. NN. Unit Price Work -- Work to be paid for on the basis of unit prices as provided by the Contractor or as adjusted in accordance with the Contract Documents. OO. Warranty -- A written guarantee provided to the City by the Contractor that the Work will remain free of defects and suitable for its intended use for the period required by the Contract Documents or the longest period permitted by the law of this State, whichever is longer. PP. Work -- The entire construction or the various separately identifiable parts thereof required to be provided under the Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such construction, and furnishing, installing, and incorporating all materials and equipment into such construction, all as required by the Contract Documents. ARTICLE 2. CONTRACT DOCUMENTS A. Contract Documents. The Contract Documents are complementary, and what is called for by one shall be as binding as if called for by all. 61147.91007\30425843.2 -21- 00 72 13 – GENERAL CONDITIONS B. Interpretations. The Contract Documents are intended to be fully cooperative and complementary. If the Contractor observes that any documents are in conflict, the Contractor shall promptly notify the Engineer in writing. In case of conflicts between the Contract Documents, the order of precedence shall be as follows: 1. Change Orders 2. Addenda 3. Special Conditions 4. Technical Specifications and Scope of Work 5. Plans (Contract Drawings) 6. Contract 7. General Conditions 8. Standard Specifications for Public Works Construction (Sections 1-9 Excluded) 9. Applicable Local Agency Standards and Specifications 10. Standard Drawings 11. Reference Documents With reference to the Drawings, the order of precedence shall be as follows: 1. Figures govern over scaled dimensions 2. Detail drawings govern over general drawings 3. Addenda or Change Order drawings govern over Contract Drawings 4. Contract Drawings govern over Standard Drawings 5. Contract Drawings govern over Shop Drawings C. Conflicts in Contract Documents. Notwithstanding the orders of precedence established above, in the event of conflicts, the higher standard, higher quality, and most expensive shall always apply. D. Organization of Contract Documents. Organization of the Contract Documents into divisions, sections, and articles, and arrangement of drawings shall not control the Contractor in dividing Project Work among subcontractors or in establishing the extent of Work to be performed by any trade. ARTICLE 3. PRECONSTRUCTION AND CONSTRUCTION COMMUNICATION Before any Work at the site is started, a conference attended by the City, Contractor, City’s Representative, and others as appropriate will be held to establish a working understanding among the parties as to the Work and to discuss the schedules referred to herein, procedures for handling Shop Drawings and other submittals, processing Applications for Payment, and maintaining required records. At this conference the City and Contractor each shall designate, in writing, a specific individual to act as its authorized representative with respect to the services and responsibilities under the Contract. Such individuals shall have the authority to transmit instructions, receive information, render decisions relative to the Contract, and otherwise act on behalf of each respective party. ARTICLE 4. CONTRACT DOCUMENTS: COPIES & MAINTENANCE Contractor will be furnished, free of charge, five (5) copies of the Contract Documents. Additional copies may be obtained at cost of reproduction. 61147.91007\30425843.2 -22- 00 72 13 – GENERAL CONDITIONS Contractor shall maintain a clean, undamaged set of Contract Documents, including submittals, at the Project site. ARTICLE 5. EXAMINATION OF DRAWINGS, SPECIFICATIONS AND SITE OF WORK A. Examination of Contract Documents. Before commencing any portion of the Work, Contractor shall again carefully examine all applicable Contract Documents, the Project site, and other information given to Contractor as to materials and methods of construction and other Project requirements. Contractor shall immediately notify the Engineer of any potential error, inconsistency, ambiguity, conflict, or lack of detail or explanation. If Contractor performs, permits, or causes the performance of any Work which is in error, inconsistent or ambiguous, or not sufficiently detailed or explained, Contractor shall bear any and all resulting costs, including, without limitation, the cost of correction. In no case shall the Contractor or any subcontractor proceed with Work if uncertain as to the applicable requirements. B. Additional Instructions. After notification of any error, inconsistency, ambiguity, conflict, or lack of detail or explanation, the Engineer will provide any required additional instructions, by means of drawings or other written direction, necessary for proper execution of Work. C. Quality of Parts, Construction and Finish. All parts of the Work shall be of the best quality of their respective kinds and the Contractor must use all diligence to inform itself fully as to the required construction and finish. D. Contractor’s Variation from Contract Document Requirements. If it is found that the Contractor has varied from the requirements of the Contract Documents including the requirement to comply with all applicable laws, ordinances, rules and regulations, the Engineer may at any time, before or after completion of the Work, order the improper Work removed, remade or replaced by the Contractor at the Contractor’s expense. ARTICLE 6. MOBILIZATION A. When a bid item is included in the Bid Form for mobilization, the costs of Work in advance of construction operations and not directly attributable to any specific bid item will be included in the progress estimate (“Initial Mobilization”). When no bid item is provided for “Initial Mobilization,” payment for such costs will be deemed to be included in the other items of the Work. B. Payment for Initial Mobilization based on the lump sum provided in the Bid Form, which shall constitute full compensation for all such Work. No payment for Initial Mobilization will be made until all of the listed items have been completed to the satisfaction of the Engineer. The scope of the Work included under Initial Mobilization shall include, but shall not be limited to, the following principal items: 1. Obtaining and paying for all bonds, insurance, and permits. 2. Moving on to the Project site of all Contractor’s plant and equipment required for the first month’s operations. 61147.91007\30425843.2 -23- 00 72 13 – GENERAL CONDITIONS 3. Installing temporary construction power, wiring, and lighting facilities, as applicable. 4. Establishing fire protection system, as applicable. 5. Developing and installing a construction water supply, if applicable. 6. Providing and maintaining the field office trailers for the Contractor, if necessary, and the Engineer (if specified), complete, with all specified furnishings and utility services. 7. Providing on-site sanitary facilities and potable water facilities as specified per Cal-OSHA and these Contract Documents. 8. Furnishing, installing, and maintaining all storage buildings or sheds required for temporary storage of products, equipment, or materials that have not yet been installed in the Work. All such storage shall meet manufacturer’s specified storage requirements, and the specific provisions of the specifications, including temperature and humidity control, if recommended by the manufacturer, and for all security. 9. Arranging for and erection of Contractor’s work and storage yard. 10. Posting all OSHA required notices and establishment of safety programs per Cal- OSHA. 11. Full-time presence of Contractor’s superintendent at the job site as required herein. 12. Submittal of Construction Schedule as required by the Contract Documents. ARTICLE 7. EXISTENCE OF UTILITIES AT THE WORK SITE A. The City has endeavored to determine the existence of utilities at the Project site from the records of the owners of known utilities in the vicinity of the Project. The positions of these utilities as derived from such records are shown on the Plans. B. Unless indicated otherwise on the Plans and Specifications, no excavations were made to verify the locations shown for underground utilities. The service connections to these utilities are not shown on the Plans. Water service connections may be shown on the Plans showing general locations of such connections. It shall be the responsibility of the Contractor to determine the exact location of all service connections. The Contractor shall make its own investigations, including exploratory excavations, to determine the locations and type of service connections, prior to commencing Work which could result in damage to such utilities. The Contractor shall immediately notify the City in writing of any utility discovered in a different position than shown on the Plans or which is not shown on the Plans. C. If applicable, all water meters, water valves, fire hydrants, electrical utility vaults, telephone vaults, gas utility valves, and other subsurface structures shall be relocated or adjusted to final grade by the Contractor. Locations of existing utilities 61147.91007\30425843.2 -24- 00 72 13 – GENERAL CONDITIONS shown on the Plans are approximate and may not be complete. The Contractor shall be responsible for coordinating its Work with all utility companies during the construction of the Work. D. Notwithstanding the above, pursuant to section 4215 of the Government Code, the City has the responsibility to identify, with reasonable accuracy, main or trunkline facilities on the plans and specifications. In the event that main or trunkline utility facilities are not identified with reasonable accuracy in the plans and specifications made a part of the invitation for Bids, the City shall assume the responsibility for their timely removal, relocation, or protection. E. Contractor, except in an emergency, shall contact the appropriate regional notification center, Southern California Underground Service Alert at 811 or 1- 800-227-2600 or on-line at www.digalert.org at least two working days prior to commencing any excavation if the excavation will be performed in an area which is known, or reasonably should be known, to contain subsurface installations other than the underground facilities owned or operated by the City, and obtain an inquiry identification number from that notification center. No excavation shall be commenced or carried out by the Contractor unless such an inquiry identification number has been assigned to the Contractor or any subcontractor of the Contractor and the City has been given the identification number by the Contractor. ARTICLE 8. SOILS INVESTIGATIONS A. Reports and Drawings. The Special Conditions identify: 1. those reports known to the City of explorations and tests of subsurface conditions at or contiguous to the site; and 2. those drawings known to the City of physical conditions relating to existing surface or subsurface structures at the site (except Underground Facilities). B. Limited Reliance by Contractor on Technical Data Authorized. Contractor may rely upon the accuracy of the “technical data” contained in such reports and drawings, which were expressly not created or obtained to evaluate or assist in the evaluation of constructability, and are not Contract Documents. Contractor shall make its own interpretation of the “technical data” and shall be solely responsible for any such interpretations. Except for reliance on the accuracy of such “technical data,” Contractor may not rely upon or make any claim against the City, City’s Representative, or Engineer of Record, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors, with respect to: 1. the completeness of such reports and drawings for Contractor’s purposes, including without limitation any aspects of the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor, and safety precautions and programs incident thereto; or 2. other data, interpretations, opinions, conclusions and information contained in such reports or shown or indicated in such drawings; or 61147.91007\30425843.2 -25- 00 72 13 – GENERAL CONDITIONS 3. any Contractor interpretation of or conclusion drawn from any “technical data” or any such other data, interpretations, opinions, or information. ARTICLE 9. CONTRACTOR’S SUPERVISION Contractor shall continuously keep at the Project site, a competent and experienced full-time Project superintendent acceptable to the City. Superintendent must be able to proficiently speak, read and write in English and shall have the authority to make decisions on behalf of the Contractor. Contractor shall continuously provide efficient supervision of the Project. ARTICLE 10. WORKERS A. Contractor shall at all times enforce strict discipline and good order among its employees. Contractor shall not employ on the Project any unfit person or any one not skilled in the Work assigned to him or her. B. Any person in the employ of the Contractor whom the City may deem incompetent or unfit shall be dismissed from the Work and shall not be employed on this Project. ARTICLE 11. INDEPENDENT CONTRACTORS Contractor shall be an independent contractor for the City and not an employee. Contractor understands and agrees that it and all of its employees shall not be considered officers, employees, or agents of City and are not entitled to benefits of any kind normally provided employees of City, including but not limited to, state unemployment compensation or workers’ compensation. Contractor assumes full responsibility for the acts and omissions of its employees or agents related to the Work. ARTICLE 12. SUBCONTRACTS A. Contractor agrees to bind every subcontractor to the terms of the Contract Documents as far as such terms are applicable to subcontractor’s portion of the Work. Contractor shall be as fully responsible to the City for the acts and omissions of its subcontractors and of persons either directly or indirectly employed by its subcontractors, as Contractor is for acts and omissions of persons directly employed by Contractor. Nothing contained in these Contract Documents shall create any contractual relationship between any subcontractor and the City. B. The City reserves the right to accept all subcontractors. The City’s acceptance of any subcontractor under this Contract shall not in any way relieve Contractor of its obligations in the Contract Documents. C. Prior to substituting any subcontractor listed in the Bid Forms, Contractor must comply with the requirements of the Subletting and Subcontracting Fair Practices Act pursuant to California Public Contract Code section 4100 et seq. ARTICLE 13. VERIFICATION OF EMPLOYMENT ELIGIBILITY By executing this Contract, Contractor verifies that it fully complies with all requirements and restrictions of state and federal law respecting the employment of undocumented aliens, including, but not limited to, the Immigration Reform and Control Act of 1986, as may be 61147.91007\30425843.2 -26- 00 72 13 – GENERAL CONDITIONS amended from time to time, and shall require all subcontractors, sub-subcontractors and consultants to comply with the same. Each person executing this Contract on behalf of Contractor verifies that he or she is a duly authorized officer of Contractor and that any of the following shall be grounds for the City to terminate the Contract for cause: (1) failure of the Contractor or its subcontractors, sub-subcontractors or consultants to meet any of the requirements provided for in this Article; (2) any misrepresentation or material omission concerning compliance with such requirements; or (3) failure to immediately remove from the Work any person found not to be in compliance with such requirements. ARTICLE 14. REQUESTS FOR SUBSTITUTION A. For the purposes of this provision, the term “substitution” shall mean the substitution of any material, method or service substantially equal to or better in every respect to that indicated in the Standard Specifications or otherwise referenced herein. B. Pursuant to Public Contract Code section 3400(b), the City may make a finding that is described in the Notice Inviting Bids that designates certain products, things, or services by specific brand or trade name. C. Unless specifically designated in the Special Conditions, whenever any material, process, or article is indicated or specified by grade, patent, or proprietary name or by name of manufacturer, such specifications shall be deemed to be used for the purpose of facilitating the description of the material, process, or article desired and shall be deemed to be followed by the words “or equal.” Contractor may, unless otherwise stated, offer for substitution any material, process, or article which may be substantially equal to or better in every respect to that so indicated or specified in the Contract Documents. However, the City has adopted uniform standards for certain materials, processes, and articles. D. The Contractor shall submit substitution requests, together with substantiating data, for substitution of any “or equal” material, process, or article no later than thirty-five (35) calendar days after award of Contract. Provisions regarding submission of substitution requests shall not in any way authorize an extension of time for the performance of this Contract. If a substitution request is rejected by the City, the Contractor shall provide the material, method or service specified herein. The City shall not be responsible for any costs incurred by the Contractor associated with substitution requests. The burden of proof as to the equality of any material, process, or article shall rest with the Contractor. The Engineer has the complete and sole discretion to determine if a material, process, or article is substantially equal to or better than that specified and to approve or reject all substitution requests. E. Substantiating data as described above shall include, at a minimum, the following information: 1. A signed affidavit from the Contractor stating that the material, process, or article proposed as a substitution is substantially equal to or better than that specified in every way except as may be listed on the affidavit. 2. Illustrations, specifications, catalog cut sheets, and any other relevant data required to prove that the material, process, or article is substantially equal to or better than that specified. 61147.91007\30425843.2 -27- 00 72 13 – GENERAL CONDITIONS 3. A statement of the cost implications of the substitution being requested, indicating whether and why the proposed substitution will reduce or increase the amount of the contract. 4. Information detailing the durability and lifecycle costs of the proposed substitution. F. Failure to submit all the required substantiating data detailed above in a timely manner so that the substitution request can be adequately reviewed may result in rejection of the substitution request. The Engineer is not obligated to review multiple submittals related the same substitution request resulting from the Contractor’s failure to initially submit a complete package. G. Time limitations within this Article shall be strictly complied with and in no case will an extension of time for completion of the contract be granted because of Contractor’s failure to provide substitution requests at the time and in the manner described herein. H. The Contractor shall bear the costs of all City work associated with the review of substitution requests. I. If substitution requests approved by the Engineer require that Contractor furnish materials, methods or services more expensive than that specified, the increased costs shall be borne by Contractor. ARTICLE 15. SHOP DRAWINGS A. Contractor shall check and verify all field measurements and shall submit with such promptness as to provide adequate time for review and cause no delay in its own Work or in that of any other contractor, subcontractor, or worker on the Project, six (6) copies of all shop drawings, calculations, schedules, and materials list, and all other provisions required by the Contract Documents. Contractor shall sign all submittals affirming that submittals have been reviewed and approved by Contractor prior to submission to Engineer. Each signed submittal shall affirm that the submittal meets all the requirements of the Contract Documents except as specifically and clearly noted and listed on the transmittal letter of the submittal. B. Contractor shall make any corrections required by the Engineer, and file with the Engineer six (6) corrected copies each, and furnish such other copies as may be needed for completion of the Work. Engineer’s acceptance of shop drawings shall not relieve Contractor from responsibility for deviations from the Contract Documents unless Contractor has, in writing, called Engineer’s attention to such deviations at time of submission and has secured the Engineer’s written acceptance. Engineer’s acceptance of shop drawings shall not relieve Contractor from responsibility for errors in shop drawings. ARTICLE 16. SUBMITTALS A. Contractor shall furnish to the Engineer for approval, prior to purchasing or commencing any Work, a log of all samples, material lists and certifications, mix designs, schedules, and other submittals, as required in the Contract Documents. 61147.91007\30425843.2 -28- 00 72 13 – GENERAL CONDITIONS The log shall indicate whether samples will be provided in accordance with other provisions of this Contract. B. Contractor will provide samples and submittals, together with catalogs and supporting data required by the Engineer, to the Engineer within a reasonable time period to provide for adequate review and avoid delays in the Work. C. These requirements shall not authorize any extension of time for performance of this Contract. Engineer will check and approve such samples, but only for conformance with design concept of work and for compliance with information given in the Contract Documents. Work shall be in accordance with approved samples and submittals. ARTICLE 17. MATERIALS A. Except as otherwise specifically stated in the Contract Documents, Contractor shall provide and pay for all materials, labor, tools, equipment, lights, power, transportation, superintendence, temporary constructions of every nature, and all other services and facilities of every nature whatsoever necessary to execute and complete this Contract within specified time. B. Unless otherwise specified, all materials shall be new and the best of their respective kinds and grades as noted and/or specified, and workmanship shall be of good quality. C. Materials shall be furnished in ample quantities and at such times as to ensure uninterrupted progress of the Work and shall be stored properly and protected as required by the Contract Documents. Contractor shall be entirely responsible for damage or loss by weather or other causes to materials or Work. D. No materials, supplies, or equipment for Work under this Contract shall be purchased subject to any chattel mortgage or under a conditional sale or other agreement by which an interest therein or in any part thereof is retained by the seller or supplier. Contractor warrants good title to all material, supplies, and equipment installed or incorporated in the Work and agrees upon completion of all work to deliver the Project, to the City free from any claims, liens, or charges. E. Materials shall be stored on the Project site in such manner so as not to interfere with any operations of the City or any independent contractor. F. Contractor shall verify all measurements, dimensions, elevations, and quantities before ordering any materials or performing any Work, and the City shall not be liable for Contractor’s failure to so. No additional compensation, over and above payment for the actual quantities at the prices set out in the Contract, will be allowed because of differences between actual measurements, dimension, elevations and quantities and those indicated on the Plans and in the Specifications. Any difference therein shall be submitted to the Engineer for consideration before proceeding with the Work. 61147.91007\30425843.2 -29- 00 72 13 – GENERAL CONDITIONS ARTICLE 18. PERMITS AND LICENSES A. City will apply and pay for the review of necessary encroachment permits for Work within the public rights-of-way. Contractor shall obtain all other necessary permits and licenses for the construction of the Project, including encroachment permits, and shall pay all fees required by law and shall comply with all laws, ordinances, rules and regulations relating to the Work and to the preservation of public health and safety. Before acceptance of the Project, the Contractor shall submit all licenses, permits, certificates of inspection and required approvals to the City. B. The Bid Form contains an allowance for the Contractor’s cost of acquiring traffic control permits and for construction inspection fees that may be charged to the Contractor by the Agency of Jurisdiction. The allowance is included within the Bid Form to eliminate the need by bidders to research or estimate the costs of traffic control permits and construction inspection fees prior to submitting a bid. The allowance is specifically intended to account for the costs of traffic control permits and construction inspection fees charged by the local Agency of Jurisdiction only. No other costs payable by Contractor to the Agency of Jurisdiction are included within the allowance. Payment by City to Contractor under the Permit and Inspection Allowance Bid Item shall be made based on actual cost receipts only and in accordance with the provisions of these specifications. ARTICLE 19. TRENCHES A. Trenches Five Feet or More in Depth. Contractor shall submit to the Engineer at the preconstruction meeting, a detailed plan showing the design of shoring, bracing, sloping or other provisions to be made for worker protection from hazards of caving ground during the excavation of any trench or trenches five feet or more in depth. If such plan varies from shoring system standards established by the Construction Safety Orders of the California Code of Regulations, Department of Industrial Relations, the plan shall be prepared by a California registered civil or structural engineer. The plan shall not be less effective than the shoring, bracing, sloping, or other provisions of the Construction Safety Orders, as defined in the California Code of Regulations. The Contractor shall designate in writing the “competent person” as defined in Title 8, California Code of Regulations, who shall be present at the Work Site each day that trenching/excavation is in progress. The “competent person” shall prepare and provide daily trenching/excavation inspection reports to the Engineer. Contractor shall also submit a copy of its annual California Occupational Safety and Health Administration (Cal/OSHA) trench/excavation permit. B. Excavations Deeper than Four Feet. If the Work involves excavating trenches or other excavations that extend deeper than four feet below the surface, Contractor shall promptly, and before the excavation is further disturbed, notify the City in writing of any of the following conditions: 1. Material that the Contractor believes may be material that is hazardous waste, as defined in section 25117 of the Health and Safety Code, that is required to be removed to a Class I, Class II, or Class III disposal site in accordance with provisions of existing law. 2. Subsurface or latent physical conditions at the site differing from those indicated. 61147.91007\30425843.2 -30- 00 72 13 – GENERAL CONDITIONS 3. Unknown physical conditions at the site of any unusual nature, different materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract The City shall promptly investigate the conditions, and if it finds that the conditions do so materially differ, or do involve hazardous waste, and cause a decrease or increase in Contractor’s cost of, or the time required for, performance of any part of the Work, shall issue a change order under the procedures described in the Contract Documents. In the event that a dispute arises between the City and the Contractor as to whether the conditions materially differ, or involve hazardous waste, or cause a decrease or increase in the Contractor’s cost of, or time required for, performance of any part of the Work, the Contractor shall not be excused from any scheduled completion date provided for by the Contract, but shall proceed with all Work to be performed under the Contract. Contractor shall retain any and all rights provided either by contract or by law which pertain to the resolution of disputes and protests between the parties. ARTICLE 20. TRAFFIC CONTROL A. Traffic control plan(s) for the Work may be required by the Agency(s) of Jurisdiction. Traffic control plans, if required, shall be prepared at Contractor’s expense, and traffic control shall be performed at Contractor’s expense in accordance with the requirements of the Agency(s) of Jurisdiction. The Permit and Inspection Allowance included within the Bid Form includes the cost of required traffic control permit(s) and construction inspection by the Agency(s) of Jurisdiction only. The Permit and Inspection Allowance does not include costs for preparation of any required traffic control plans, implementation of any traffic control requirements or for any traffic signal services that may be required. Costs for traffic control plans, implementation of traffic control, or traffic signal services required by the Agency(s) of Jurisdiction shall be included in the Contractor’s Bid. B. All warning signs and safety devices used by the Contractor to perform the Work shall conform to the requirements contained in the State of California, Department of Transportation’s current edition of “Manual of Traffic Controls for Construction and Maintenance Work Zones” or to the requirements of the local agency. The Contractor shall also be responsible for all traffic control required by the agency having jurisdiction over the project on the intersecting streets. Contractor must submit a traffic control plan to the agency having jurisdiction over the project for approval prior to starting work. C. The Contractor’s representative on the site responsible for traffic control shall produce evidence that he/she has completed training acceptable to the California Department of Transportation for safety through construction zones. All of the streets in which the Work will occur shall remain open to traffic and one lane of traffic maintained at all times unless otherwise directed by the agency of jurisdiction. Businesses and residences adjacent to the Work shall be notified forty-eight (48) hours in advance of closing of driveways. The Contractor shall make every effort to minimize the amount of public parking temporarily eliminated due to construction in areas fronting businesses. No stockpiles of pipe or other material will be allowed in 61147.91007\30425843.2 -31- 00 72 13 – GENERAL CONDITIONS traveled right-of-ways after working hours unless otherwise approved by the Engineer. ARTICLE 21. DIVERSION OF RECYCLABLE WASTE MATERIALS In compliance with the applicable City’s waste reduction and recycling efforts, Contractor shall divert all Recyclable Waste Materials to appropriate recycling centers as required for compliance with the local jurisdiction’s waste diversion ordinances. Contractor will be required to submit weight tickets and written proof of diversion with its monthly progress payment requests. Contractor shall complete and execute any certification forms required by City or other applicable agencies to document Contractor’s compliance with these diversion requirements. All costs incurred for these waste diversion efforts shall be the responsibility of the Contractor. ARTICLE 22. REMOVAL OF HAZARDOUS MATERIALS Should Contractor encounter material reasonably believed to be polychlorinated biphenyl (PCB) or other toxic wastes and hazardous materials which have not been rendered harmless at the Project site, the Contractor shall immediately stop work at the affected Project site and shall report the condition to the City in writing. The City shall contract for any services required to directly remove and/or abate PCBs and other toxic wastes and hazardous materials, if required by the Project site(s), and shall not require the Contractor to subcontract for such services. The Work in the affected area shall not thereafter be resumed except by written agreement of the City and Contractor. ARTICLE 23. SANITARY FACILITIES Contractor shall provide sanitary temporary toilet buildings and hand washing facilities for the use of all workers. All toilets and hand washing facilities shall comply with local codes and ordinances. Toilets shall be kept supplied with toilet paper and shall have workable door fasteners. Toilets and hand washing facilities shall be serviced no less than once weekly and shall be present in a quantity of not less than 1 per 20 workers as required by Cal/OSHA regulations. The toilets and hand washing facilities shall be maintained in a sanitary condition at all times. Use of toilet and hand washing facilities in the Work under construction shall not be permitted. Any other Sanitary Facilities required by Cal/OSHA shall be the responsibility of the Contractor. ARTICLE 24. AIR POLLUTION CONTROL Contractor shall comply with all air pollution control rules, regulations, ordinances and statutes, including, but not limited to, those required by the South Coast Air Quality Management District. All containers of paint, thinner, curing compound, solvent or liquid asphalt shall be labeled to indicate that the contents fully comply with the applicable material requirements. ARTICLE 25. LAYOUT AND FIELD ENGINEERING All field engineering required for laying out the Work and establishing grades for earthwork operations shall be furnished by the Contractor at its expense. 61147.91007\30425843.2 -32- 00 72 13 – GENERAL CONDITIONS ARTICLE 26. TESTS AND INSPECTIONS A. If the Contract Documents, the Engineer, or any instructions, laws, ordinances, or public authority requires any part of the Work to be tested or Approved, Contractor shall provide the Engineer at least two (2) working days’ notice of its readiness for observation or inspection. If inspection is by a public authority other than the City, Contractor shall promptly inform the City of the date fixed for such inspection. Required certificates of inspection (or similar) shall be secured by Contractor. Costs for City testing and City inspection shall be paid by the City. Costs of tests for Work found not to be in compliance shall be paid by the Contractor. B. If any Work is done or covered up without the required testing or approval, the Contractor shall uncover or deconstruct the Work, and the Work shall be redone after completion of the testing at the Contractor’s cost in compliance with the Contract Documents. C. Where inspection and testing are to be conducted by an independent laboratory or agency, materials or samples of materials to be inspected or tested shall be selected by such laboratory or agency, or by the City, and not by Contractor. All tests or inspections of materials shall be made in accordance with the commonly recognized standards of national organizations. D. In advance of manufacture of materials to be supplied by Contractor which must be tested or inspected, Contractor shall notify the City so that the City may arrange for testing at the source of supply. Any materials which have not satisfactorily passed such testing and inspection shall not be incorporated into the Work. E. If the manufacture of materials to be inspected or tested will occur in a plant or location greater than sixty (60) miles from the City, the Contractor shall pay for any excessive or unusual costs associated with such testing or inspection, including but not limited to excessive travel time, standby time and required lodging. F. Reexamination of Work may be ordered by the City. If so ordered, Work must be uncovered or deconstructed by Contractor. If Work is found to be in accordance with the Contract Documents, the City shall pay the costs of reexamination and reconstruction. If such work is found not to be in accordance with the Contract Documents, Contractor shall pay all costs. ARTICLE 27. PROTECTION OF WORK AND PROPERTY A. The Contractor shall be responsible for all damages to persons or property that occurs as a result of the Work. Contractor shall be responsible for the proper care and protection of all materials delivered and Work performed until completion and final Acceptance by the City. All Work shall be solely at the Contractor’s risk. Contractor shall adequately protect adjacent property from settlement or loss of lateral support as necessary. Contractor shall comply with all applicable safety laws and building codes to prevent accidents or injury to persons on, about, or adjacent to the Project site where Work is being performed. Contractor shall erect and properly maintain at all times, as required by field conditions and progress of work, all necessary safeguards, signs, barriers, lights, and watchmen for protection of workers 61147.91007\30425843.2 -33- 00 72 13 – GENERAL CONDITIONS and the public, and shall post danger signs warning against hazards created in the course of construction. B. In an emergency affecting safety of life or of work or of adjoining property, Contractor, without special instruction or authorization from the Engineer, is hereby permitted to act to prevent such threatened loss or injury; and Contractor shall so act, without appeal, if so authorized or instructed by the Engineer or the City. Any compensation claimed by Contractor on account of emergency work shall be determined by and agreed upon by the City and the Contractor. ARTICLE 28. CONTRACTOR’S MEANS AND METHODS Contractor is solely responsible for the means and methods utilized to perform the Work. In no case shall the Contractor’s means and methods deviate from commonly used industry standards. ARTICLE 29. AUTHORIZED REPRESENTATIVES The City shall designate representatives, who shall have the right to be present at the Project site at all times. The City may designate an inspector who shall have the right to observe all of the Contractor’s Work. The inspector shall not be responsible for the Contractor’s failure to carry out the Work in accordance with the Contract Documents. Contractor shall provide safe and proper facilities for such access. ARTICLE 30. HOURS OF WORK A. As provided in Article 3 (commencing at section 1810), Chapter 1, Part 7, Division 2 of the Labor Code, Contractor stipulates that eight (8) hours of labor shall constitute a legal day’s work. The time of service of any worker employed at any time by the Contractor or by any subcontractor on any subcontract under this Contract upon the Work or upon any part of the Work contemplated by this Contract is limited and restricted to eight (8) hours during any one calendar day and 40 hours during any one calendar week, except as hereinafter provided. Notwithstanding the provisions herein above set forth, work performed by employees of Contractor in excess of eight (8) hours per day, and 40 hours during any one week, shall be permitted upon this public work upon compensation for all hours worked in excess of eight (8) hours per day at not less than one and one-half times the basic rate of pay. B. The Contractor and every subcontractor shall keep an accurate record showing the name of and actual hours worked each calendar day and each calendar week by each worker employed in connection with the Work or any part of the Work contemplated by this Contract. The record shall be kept open at all reasonable hours to the inspection of the City and to the Division of Labor Law Enforcement, Department of Industrial Relations of the State of California. C. The Contractor shall pay to the City a penalty of twenty-five dollars ($25.00) for each worker employed in the execution of this Contract by the Contractor or by any subcontractor for each calendar day during which such worker is required or permitted to work more than eight (8) hours in any calendar day and 40 hours in any one calendar week in violation of the provisions of Article 3 (commencing at section 1810), Chapter 1, Part 7, Division 2 of the Labor Code. 61147.91007\30425843.2 -34- 00 72 13 – GENERAL CONDITIONS D. Any work necessary to be performed after regular working hours, or on Saturdays and Sundays or other holidays, shall be performed without additional expense to the City. E. City will provide inspection during normal working hours from 7:00 a.m. to 3:30 p.m. Monday through Friday. Inspection before or after this time will be charged to the Contractor as reimbursable inspection time. Inspections on weekends requires two days’ notice for review and approval. Upon written request and approval the 8.5 hour working day may be changed to other limits subject to city/county ordinance. F. It shall be unlawful for any person to operate, permit, use, or cause to operate any of the following at the Project site, other than between the hours of 7:00 a.m. to 5:00 p.m., Monday through Friday, with no Work allowed on the City-observed holidays, unless otherwise approved by the City: 1. Powered Vehicles 2. Construction Equipment 3. Loading and Unloading Vehicles 4. Domestic Power Tools ARTICLE 31. PAYROLL RECORDS A. Pursuant to Labor Code section 1776, Contractor and all subcontractors shall maintain weekly certified payroll records, showing the names, addresses, Social Security numbers, work classifications, straight time and overtime hours worked each day and week, and the actual per diem wages paid to each journeyman, apprentice, worker, or other employee employed by them in connection with the Work under this Contract. Contractor shall certify under penalty of perjury that records maintained and submitted by Contractor are true and accurate. Contractor shall also require subcontractor(s) to certify weekly payroll records under penalty of perjury. B. In accordance with Labor Code section 1771.4, the Contractor and each subcontractor shall furnish the certified payroll records directly to the Department of Industrial Relations (“DIR”) on the specified interval and format prescribed by the DIR, which may include electronic submission. Contractor shall comply with all requirements and regulations from the DIR relating to labor compliance monitoring and enforcement. C. The payroll records described herein shall be certified and submitted by the Contractor at a time designated by the City. The Contractor shall also provide the following: 1. A certified copy of the employee’s payroll records shall be made available for inspection or furnished to such employee or his or her authorized representative on request. 61147.91007\30425843.2 -35- 00 72 13 – GENERAL CONDITIONS 2. A certified copy of all payroll records described herein shall be made available for inspection or furnished upon request of the DIR. D. Unless submitted electronically, the certified payroll records shall be on forms provided by the Division of Labor Standards Enforcement (“DLSE”) of the DIR or shall contain the same information as the forms provided by the DLSE. E. Any copy of records made available for inspection as copies and furnished upon request to the public or any public agency, the City, the Division of Apprenticeship Standards or the Division of Labor Standards Enforcement shall be marked or obliterated in such a manner as to prevent disclosure of an individual's name, address and social security number. The name and address of the Contractor awarded the Contract or performing the contract shall not be marked or obliterated. F. In the event of noncompliance with the requirements of this Article, the Contractor shall have ten (10) calendar days in which to comply subsequent to receipt of written notice specifying in what respects the Contractor must comply with this Article. Should noncompliance still be evident after such 10-day period, the Contractor shall pay a penalty of one hundred dollars ($100.00) to the City for each calendar day, or portion thereof, for each worker, until strict compliance is effectuated. Upon the request of the Division of Apprenticeship Standards or the Division of Labor Standards Enforcement, such penalties shall be withheld from progress payment then due. G. The responsibility for compliance with this Article shall rest upon the Contractor. ARTICLE 32. PREVAILING RATES OF WAGES A. The Contractor is aware of the requirements of Labor Code sections 1720 et seq. and 1770 et seq., as well as California Code of Regulations, Title 8, Section 16000 et seq. (“Prevailing Wage Laws”), which require the payment of prevailing wage rates and the performance of other requirements on certain “public works” and “maintenance” projects. Since this Project involves an applicable “public works” or “maintenance” project, as defined by the Prevailing Wage Laws, and since the total compensation is $1,000 or more, Contractor agrees to fully comply with such Prevailing Wage Laws. The Contractor shall obtain a copy of the prevailing rates of per diem wages at the commencement of this Contract from the website of the Division of Labor Statistics and Research of the Department of Industrial Relations located at www.dir.ca.gov. In the alternative, the Contractor may view a copy of the prevailing rate of per diem wages which are on file at the City’s Administration Office and shall be made available to interested parties upon request. Contractor shall make copies of the prevailing rates of per diem wages for each craft, classification, or type of worker needed to perform work on the Project available to interested parties upon request, and shall post copies at the Contractor’s principal place of business and at the Project site. Contractor shall defend, indemnify and hold the City, its officials, officers, employees and authorized volunteers free and harmless from any claims, liabilities, costs, penalties or interest arising out of any failure or allege failure to comply with the Prevailing Wage Laws. B. The Contractor shall forfeit as a penalty to the City not more than Two Hundred Dollars ($200.00), pursuant to Labor Code section 1775, for each calendar day, or 61147.91007\30425843.2 -36- 00 72 13 – GENERAL CONDITIONS portion thereof, for each worker paid less than the prevailing wage rate as determined by the Director of the Department of Industrial Relations for such work or craft in which such worker is employed for any public work done under the Contract by it or by any subcontractor under it. The difference between such prevailing wage rate and the amount paid to each worker for each calendar day or portion thereof, for which each worker was paid less than the prevailing wage rate, shall be paid to each worker by the Contractor. C. Contractor shall post, at appropriate conspicuous points on the Project site, a schedule showing all determined general prevailing wage rates and all authorized deductions, if any, from unpaid wages actually earned. ARTICLE 33. PUBLIC WORKS CONTRACTOR REGISTRATION Pursuant to Labor Code sections 1725.5 and 1771.1, the Contractor and its subcontractors must be registered with the Department of Industrial Relations prior to the execution of a contract to perform public works. By entering into this Contract, Contractor represents that it is aware of the registration requirement and is currently registered with the DIR. Contractor shall maintain a current registration for the duration of the Project. Contractor shall further include the requirements of Labor Code sections 1725.5 and 1771.1 in any subcontract and ensure that all subcontractors are registered at the time this Contract is entered into and maintain registration for the duration of the Project. ARTICLE 34. EMPLOYMENT OF APPRENTICES A. Contractor and all subcontractors shall comply with the requirements of Labor Code sections 1777.5 and 1777.6 in the employment of apprentices. B. Information relative to apprenticeship standards, wage schedules, and other requirements may be obtained from the Director of Industrial Relations, ex officio the Administrator of Apprenticeship, San Francisco, California, or from the Division of Apprenticeship Standards and its branch offices. C. Knowing violations of Labor Code section 1777.5 will result in forfeiture not to exceed one hundred dollars ($100.00) for each calendar day of non-compliance pursuant to Labor Code section 1777.7. D. The responsibility for compliance with this Article shall rest upon the Contractor. ARTICLE 35. NONDISCRIMINATION/EQUAL EMPLOYMENT OPPORTUNITY Pursuant to Labor Code section 1735 and other applicable provisions of law, the Contractor and its subcontractors shall not discriminate against any employee or applicant for employment because of race, religious creed, color, national origin, ancestry, physical disability, mental disability, medical condition, marital status, sex, age, sexual orientation, or any other classifications protected by law on this Project. The Contractor will take affirmative action to insure that employees are treated during employment or training without regard to their race, religious creed, color, national origin, ancestry, physical disability, mental disability, medical condition, marital status, sex, age, sexual orientation, or any other classifications protected by law. 61147.91007\30425843.2 -37- 00 72 13 – GENERAL CONDITIONS Employment Eligibility; Contractor. By executing this Contract, Contractor verifies that it fully complies with all requirements and restrictions of state and federal law respecting the employment of undocumented aliens, including, but not limited to, the Immigration Reform and Control Act of 1986, as may be amended from time to time. Such requirements and restrictions include, but are not limited to, examination and retention of documentation confirming the identity and immigration status of each employee of the Contractor. Contractor also verifies that it has not committed a violation of any such law within the five (5) years immediately preceding the date of execution of this Contract, and shall not violate any such law at any time during the term of the Contract. Contractor shall avoid any violation of any such law during the term of this Contract by participating in an electronic verification of work authorization program operated by the United States Department of Homeland Security, by participating in an equivalent federal work authorization program operated by the United States Department of Homeland Security to verify information of newly hired employees, or by some other legally acceptable method. Contractor shall maintain records of each such verification, and shall make them available to the City or its representatives for inspection and copy at any time during normal business hours. The City shall not be responsible for any costs or expenses related to Contractor’s compliance with the requirements provided for or referred to herein. Employment Eligibility; Subcontractors, Sub-subcontractors and Consultants. To the same extent and under the same conditions as Contractor, Contractor shall require all of its subcontractors, sub-subcontractors and consultants performing any part of the Work or of this Contract to make the same verifications and comply with all requirements and restrictions provided for herein. Employment Eligibility; Failure to Comply. Each person executing this Contract on behalf of Contractor verifies that he or she is a duly authorized officer of Contractor, and understands that any of the following shall be grounds for the City to terminate the Contract for cause: (1) failure of Contractor or its subcontractors, sub-subcontractors or consultants to meet any of the requirements provided for herein; (2) any misrepresentation or material omission concerning compliance with such requirements; or (3) failure to immediately remove from the Work any person found not to be in compliance with such requirements. ARTICLE 36. DEBARMENT OF CONTRACTORS AND SUBCONTRACTORS Contractors or subcontractors may not perform work on a public works project with a subcontractor who is ineligible to perform work on a public project pursuant to Labor Code section 1777.1 or 1777.7. Any contract on a public works project entered into between a contractor and a debarred subcontractor is void as a matter of law. A debarred subcontractor may not receive any public money for performing work as a subcontractor on a public works contract. Any public money that is paid, or may have been paid to a debarred subcontractor by a contractor on the project shall be returned to the City. The Contractor shall be responsible for the payment of wages to workers of a debarred subcontractor who has been allowed to work on the project. ARTICLE 37. LABOR/EMPLOYMENT SAFETY The Contractor shall comply with all applicable laws and regulations of the federal, state, and local government, including Cal/OSHA requirements and requirements for verification of employees’ legal right to work in the United States. The Contractor shall maintain emergency first aid treatment for his employees which complies 61147.91007\30425843.2 -38- 00 72 13 – GENERAL CONDITIONS with the Federal Occupational Safety and Health Act of 1970 (29 U.S.C. § 651 et seq.), and California Code of Regulations, Title 8, Industrial Relations Division 1, Department of Industrial Relations, Chapter 4. The Contractor shall ensure the availability of emergency medical services for its employees in accordance with California Code of Regulations, Title 8, Section 1512. The Contractor shall submit the Illness and Injury Prevention Program and a Project site specific safety program to the City prior to beginning Work at the Project site. Contractor shall maintain a confined space program that meets or exceeds the City Standards. Contractor shall adhere to the City’s lock out tag out program. ARTICLE 38. INSURANCE The Contractor shall obtain, and at all times during performance of the Work of Contract, maintain all of the insurance described in this Article. Contractor shall not commence Work under this Contract until it has provided evidence satisfactory to the City that it has secured all insurance required hereunder. Contractor shall not allow any subcontractor to commence work on any subcontract until it has provided evidence satisfactory to the City that the subcontractor has secured all insurance required under this Article. Failure to provide and maintain all required insurance shall be grounds for the City to terminate this Contract for cause. Contractor shall furnish City with original certificates of insurance and endorsements effective coverage required by this Contract on forms satisfactory to the City. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf, and shall be on forms acceptable to the City. All certificates and endorsements must be received and approved by the City before Work commences. A. Additional Insureds; Waiver of Subrogation. The City, its officials, officers, employees, agents and authorized volunteers shall be named as Additional Insureds on Contractor’s All Risk policy and on Contractor’s and its subcontractors’ policies of Commercial General Liability and Automobile Liability insurance using, for Contractor’s policy/ies of Commercial General Liability insurance, ISO CG forms 20 10 and 20 37 (or endorsements providing the exact same coverage, including completed operations), and, for subcontractors’ policies of Commercial General Liability insurance, ISO CG form 20 38 (or endorsements providing the exact same coverage). Notwithstanding the minimum limits set forth in this Contract for any type of insurance coverage, all available insurance proceeds in excess of the specified minimum limits of coverage shall be available to the parties required to be named as Additional Insureds hereunder. Contractor and its insurance carriers shall provide a Waiver of Subrogation in favor of those parties. B. Workers’ Compensation Insurance. The Contractor shall provide workers’ compensation insurance for all of the employees engaged in Work under this Contract, on or at the Site, and, in case of any sublet Work, the Contractor shall require the subcontractor similarly to provide workers’ compensation insurance for all the latter’s employees as prescribed by State law. Any class of employee or employees not covered by a subcontractor’s insurance shall be covered by the Contractor’s insurance. In case any class of employees engaged in work under this Contract, on or at the Site, is not protected under the Workers’ Compensation Statutes, the Contractor shall provide or shall cause a subcontractor to provide, adequate insurance coverage for the protection of such employees not otherwise protected. The Contractor is required to secure payment of compensation to his 61147.91007\30425843.2 -39- 00 72 13 – GENERAL CONDITIONS employees in accordance with the provisions of section 3700 of the Labor Code. The Contractor shall file with the City certificates of his insurance protecting workers. Company or companies providing insurance coverage shall be acceptable to the City, if in the form and coverage as set forth in the Contract Documents. C. Employer’s Liability Insurance. Contractor shall provide Employer’s Liability Insurance, including Occupational Disease, in the amount of at least one million dollars ($1,000,000.00) per person per accident. Contractor shall provide City with a certificate of Employer’s Liability Insurance. Such insurance shall comply with the provisions of the Contract Documents. The policy shall be endorsed, if applicable, to provide a Borrowed Servant/Alternate Employer Endorsement and contain a Waiver of Subrogation in favor of the City. D. Commercial General Liability Insurance. Contractor shall provide “occurrence” form Commercial General Liability insurance coverage at least as broad as the most current ISO CGL Form 00 01, including but not limited to, premises liability, contractual liability, products/completed operations, personal and advertising injury which may arise from or out of Contractor’s operations, use, and management of the Site, or the performance of its obligations hereunder. The policy shall not contain any exclusion contrary to this Contract including but not limited to endorsements or provisions limiting coverage for (1) contractual liability (including but not limited to ISO CG 24 26 or 21 39); or (2) cross-liability for claims or suits against one insured against another. Policy limits shall not be less than $1,000,000 per occurrence for bodily injury, personal injury and property damage. If Commercial General Liability Insurance or other form with a general aggregate limit is used, either the general aggregate limit shall apply separately to this project/location or the general aggregate limit shall be twice the required occurrence limit. Defense costs shall be paid in addition to the limits. 1. Such policy shall comply with all the requirements of this Article. The limits set forth herein shall apply separately to each insured against whom claims are made or suits are brought, except with respect to the limits of liability. Further the limits set forth herein shall not be construed to relieve the Contractor from liability in excess of such coverage, nor shall it limit Contractor’s indemnification obligations to the City, and shall not preclude the City from taking such other actions available to the City under other provisions of the Contract Documents or law. 2. All general liability policies provided pursuant to the provisions of this Article shall comply with the provisions of the Contract Documents. 3. All general liability policies shall be written to apply to all bodily injury, including death, property damage, personal injury, owned and non-owned equipment, blanket contractual liability, completed operations liability, explosion, collapse, under-ground excavation, removal of lateral support, and other covered loss, however occasioned, occurring during the policy term, and shall specifically insure the performance by Contractor of that part of the indemnification contained in these General Conditions relating to liability for injury to or death of persons and damage to property. 61147.91007\30425843.2 -40- 00 72 13 – GENERAL CONDITIONS 4. If the coverage contains one or more aggregate limits, a minimum of 50% of any such aggregate limit must remain available at all times; if over 50% of any aggregate limit has been paid or reserved, the City may require additional coverage to be purchased by Contractor to restore the required limits. Contractor may combine primary, umbrella, and as broad as possible excess liability coverage to achieve the total limits indicated above. Any umbrella or excess liability policy shall include the additional insured endorsement described in the Contract Documents. 5. All policies of general liability insurance shall permit and Contractor does hereby waive any right of subrogation which any insurer of Contractor may acquire from Contractor by virtue of the payment of any loss. E. Automobile Liability Insurance. Contractor shall provide “occurrence” form Automobile Liability Insurance at least as broad as ISO CA 00 01 (Any Auto) in the amount of, at least, one million dollars ($1,000,000) per accident for bodily injury and property damage. Such insurance shall provide coverage with respect to the ownership, operation, maintenance, use, loading or unloading of any auto owned, leased, hired or borrowed by Contractor or for which Contractor is responsible, in a form and with insurance companies acceptable to the City. All policies of automobile insurance shall permit and Contractor does hereby waive any right of subrogation which any insurer of Contractor may acquire from Contractor by virtue of the payment of any loss. F. Contractor’s Pollution Liability Coverage. Contractor shall provide pollution liability insurance in an amount not less than $1,000,000 per occurrence and $2,000,000 aggregate. G. Contractor shall require all tiers of sub-contractors working under this Contract to provide the insurance required under this Article unless otherwise agreed to in writing by City. Contractor shall make certain that any and all subcontractors hired by Contractor are insured in accordance with this Contract. If any subcontractor’s coverage does not comply with the foregoing provisions, Contractor shall indemnify and hold the City harmless from any damage, loss, cost, or expense, including attorneys’ fees, incurred by the City as a result thereof. ARTICLE 39. FORM AND PROOF OF CARRIAGE OF INSURANCE A. Any insurance carrier providing insurance coverage required by the Contract Documents shall be admitted to and authorized to do business in the State of California unless waived, in writing, by the City’s Risk Manager. Carrier(s) shall have an A.M. Best rating of not less than an A:VII. Insurance deductibles or self-insured retentions must be declared by the Contractor. At the election of the City the Contractor shall either 1) reduce or eliminate such deductibles or self-insured retentions, or 2) procure a bond which guarantees payment of losses and related investigations, claims administration, and defense costs and expenses. If umbrella or excess liability coverage is used to meet any required limit(s) specified herein, the Contractor shall provide a “follow form” endorsement satisfactory to the City indicating that such coverage is subject to the same terms and conditions as the underlying liability policy. 61147.91007\30425843.2 -41- 00 72 13 – GENERAL CONDITIONS B. Each insurance policy required by this Contract shall be endorsed to state that: (1) coverage shall not be suspended, voided, reduced or cancelled except after thirty (30) days prior written notice by certified mail, return receipt requested, has been given to the City; and (2) any failure to comply with reporting or other provisions of the policies, including breaches of warranties, shall not affect coverage provided to the City, its officials, officers, agents, employees, and volunteers. C. The Certificates(s) and policies of insurance shall contain or shall be endorsed to contain the covenant of the insurance carrier(s) that it shall provide no less than thirty (30) days written notice be given to the City prior to any material modification or cancellation of such insurance. In the event of a material modification or cancellation of coverage, the City may terminate the Contract or stop the Work in accordance with the Contract Documents, unless the City receives, prior to such effective date, another properly executed original Certificate of Insurance and original copies of endorsements or certified original policies, including all endorsements and attachments thereto evidencing coverage’s set forth herein and the insurance required herein is in full force and effect. Contractor shall not take possession, or use the Site, or commence operations under this Contract until the City has been furnished original Certificate(s) of Insurance and certified original copies of endorsements or policies of insurance including all endorsements and any and all other attachments as required in this Article. The original endorsements for each policy and the Certificate of Insurance shall be signed by an individual authorized by the insurance carrier to do so on its behalf. D. The Certificate(s) of Insurance, policies and endorsements shall so covenant and shall be construed as primary, and the City’s insurance and/or deductibles and/or self-insured retentions or self-insured programs shall not be construed as contributory. E. City reserves the right to adjust the monetary limits of insurance coverages during the term of this Contract including any extension thereof if, in the City’s reasonable judgment, the amount or type of insurance carried by the Contractor becomes inadequate. F. Contractor shall report to the City, in addition to the Contractor’s insurer, any and all insurance claims submitted by the Contractor in connection with the Work under this Contract. ARTICLE 40. TIME FOR COMPLETION AND LIQUIDATED DAMAGES A. Time for Completion/Liquidated Damages. Time is of the essence in the completion of the Work. Work shall be commenced within ten (10) Days of the date stated in the City’s Notice to Proceed and shall be completed by Contractor in the time specified in the Contract Documents. The City is under no obligation to consider early completion of the Project; and the Contract completion date shall not be amended by the City’s receipt or acceptance of the Contractor’s proposed earlier completion date. Furthermore, Contractor shall not, under any circumstances, receive additional compensation from the City (including but not limited to indirect, general, administrative or other forms of overhead costs) for the period between the time of earlier completion proposed by the Contractor and the Contract completion date. If the Work is not completed as stated in the Contract Documents, it is 61147.91007\30425843.2 -42- 00 72 13 – GENERAL CONDITIONS understood that the City will suffer damage. In accordance with Government Code section 53069.85, being impractical and infeasible to determine the amount of actual damage, it is agreed that Contractor shall pay to the City as fixed and liquidated damages, and not as a penalty, the sum stipulated in the Contract for each calendar day of delay until the Work is fully completed. Contractor and its surety shall be liable for any liquidated damages. Any money due or to become due the Contractor may be retained to cover liquidated damages. B. Inclement Weather. Contractor shall abide by the Engineer’s determination of what constitutes inclement weather. Time extensions for inclement weather shall only be granted when the Work stopped during inclement weather is on the critical path of the Project schedule. C. Extension of Time. Contractor shall not be charged liquidated damages because of any delays in completion of the Work due to unforeseeable causes beyond the control and without the fault or negligence of Contractor (or its subcontractors or suppliers). Contractor shall within five (5) Days of identifying any such delay notify the City in writing of causes of delay. The City shall ascertain the facts and extent of delay and grant extension of time for completing the Work when, in its judgment, the facts justify such an extension. Time extensions to the Project shall be requested by the Contractor as they occur and without delay. No delay claims shall be permitted unless the event or occurrence delays the completion of the Project beyond the Contract completion date. D. No Damages for Reasonable Delay. The City’s liability to Contractor for delays for which the City is responsible shall be limited to only an extension of time unless such delays were unreasonable under the circumstances. In no case shall the City be liable for any costs which are borne by the Contractor in the regular course of business, including, but not limited to, home office overhead and other ongoing costs. Damages caused by unreasonable City delay, including delays caused by items that are the responsibility of the City pursuant to Government Code section 4215, shall be based on actual costs only, no proportions or formulas shall be used to calculate any delay damages. ARTICLE 41. COST BREAKDOWN AND PERIODIC ESTIMATES Contractor shall furnish on forms Approved by the City: A. Within ten (10) Days of Notice to Proceed with the Contract, a detailed estimate giving a complete breakdown of the Contract price, if the Contract amount is a lump sum. B. A monthly itemized estimate of Work done for the purpose of making progress payments. In order for the City to consider and evaluate each progress payment application, the Contractor shall submit a detailed measurement of Work performed and a progress estimate of the value thereof before the tenth (10th) Day of the following month. C. Contractor shall submit, with each of its payment requests, an adjusted list of actual quantities, verified by the Engineer, for unit price items listed, if any, in the Bid Form. 61147.91007\30425843.2 -43- 00 72 13 – GENERAL CONDITIONS D. Following the City’s Acceptance of the Work, the Contractor shall submit to the City a written statement of the final quantities of unit price items for inclusion in the final payment request. E. The City shall have the right to adjust any estimate of quantity and to subsequently correct any error made in any estimate for payment. Contractor shall certify under penalty of perjury, that all cost breakdowns and periodic estimates accurately reflect the Work on the Project. ARTICLE 42. PROGRESS ESTIMATES AND PAYMENT A. By the tenth (10th) Day of the following calendar month, Contractor shall submit to Engineer a payment request which shall set forth in detail the value of the Work done for the period beginning with the date work was first commenced and ending on the end of the calendar month for which the payment request is prepared. Contractor shall include any amount earned for authorized extra work. From the total thus computed, a deduction shall be made in the amount of five percent (5%) for retention, except where the City has adopted a finding that the Work done under the Contract is substantially complex, and then the amount withheld as retention shall be the percentage specified in the Notice Inviting Bids. From the remainder a further deduction may be made in accordance with Section B below. The amount computed, less the amount withheld for retention and any amounts withheld as set forth below, shall be the amount of the Contractor’s payment request. B. The City may withhold a sufficient amount or amounts of any payment or payments otherwise due to Contractor, as in his judgment may be necessary to cover: 1. Payments which may be past due and payable for just claims against Contractor or any subcontractors for labor or materials furnished in and about the performance of work on the Project under this Contract. 2. Defective work not remedied. 3. Failure of Contractor to make proper payments to his subcontractor or for material or labor. 4. Completion of the Contract if there is a reasonable doubt that the Work can be completed for balance then unpaid. 5. Damage to another contractor or a third party. 6. Amounts which may be due the City for claims against Contractor. 7. Failure of Contractor to keep the record (“as-built”) drawings up to date. 8. Failure to provide update on construction schedule as required herein. 9. Site cleanup. 10. Failure to comply with Contract Documents. 61147.91007\30425843.2 -44- 00 72 13 – GENERAL CONDITIONS 11. Liquidated damages. 12. Legally permitted penalties. C. The City may apply such withheld amount or amounts to payment of such claims or obligations at its discretion with the exception of subsections (B)(1), (3), and (5) of this Article, which must be retained or applied in accordance with applicable law. In so doing, the City shall be deemed the agent of Contractor and any payment so made by the City shall be considered as a payment made under contract by the City to Contractor and the City shall not be liable to Contractor for such payments made in good faith. Such payments may be made without prior judicial determination of claim or obligations. The City will render Contractor a proper accounting of such funds disbursed on behalf of Contractor. D. Upon receipt, the Engineer shall review the payment request to determine whether it is undisputed and suitable for payment. If the payment request is determined to be unsuitable for payment, it shall be returned to Contractor as soon as practicable but not later than seven (7) Days after receipt, accompanied by a document setting forth in writing the reasons why the payment request is not proper. The City shall make the progress payment within 30 calendar days after the receipt of an undisputed and properly submitted payment request from Contractor, provided that a release of liens and claims has been received from the Contractor pursuant to Civil Code section 8132. The number of days available to the City to make a payment without incurring interest pursuant to this paragraph shall be reduced by the number of days by which the Engineer exceeds the seven (7) Day requirement. E. A payment request shall be considered properly executed if funds are available for payment of the payment request and payment is not delayed due to an audit inquiry by the financial officer of the City. ARTICLE 43. SECURITIES FOR MONEY WITHHELD Pursuant to section 22300 of the Public Contract Code of the State of California, Contractor may request the City to make retention payments directly to an escrow agent or may substitute securities for any money withheld by the City to ensure performance under the contract. At the request and expense of Contractor, securities equivalent to the amount withheld shall be deposited with the City or with a state or federally chartered bank as the escrow agent who shall return such securities to Contractor upon satisfactory completion of the contract. Deposit of securities with an escrow agent shall be subject to a written agreement substantially in the form provided in section 22300 of the Public Contract Code. ARTICLE 44. CHANGES AND EXTRA WORK. A. Contract Change Orders. 1. The City, without invalidating the Contract, may order changes in the Work consisting of additions, deletions or other revisions, and the Contract Price and Contract Time shall be adjusted accordingly. Except as otherwise provided herein, all such changes in the Work shall be authorized by Change Order, and shall be performed under the applicable conditions of the Contract Documents. A Change Order signed by the Contractor indicates the Contractor's agreement 61147.91007\30425843.2 -45- 00 72 13 – GENERAL CONDITIONS therewith, including any adjustment in the Contract Price or the Contract Time, and the full and final settlement of all costs (direct, indirect and overhead) related to the Work authorized by the Change Order. 2. Contractor shall promptly execute changes in the Work as directed in writing by the City even when the parties have not reached agreement on whether the change increases the scope of Work or affects the Contract Price or Contract Time. All claims for additional compensation to the Contractor shall be presented in writing. No claim will be considered after the Work in question has been done unless a written Change Order has been issued or a timely written notice of claim has been made by Contractor. 3. Whenever any change is made as provided for herein, such change shall be considered and treated as though originally included in the Contract, and shall be subject to all terms, conditions, and provisions of the original Contract. 4. Contractor shall not be entitled to claim or bring suit for damages, whether for loss of profits or otherwise, on account of any decrease or omission of any item or portion of Work to be done. 5. No dispute, disagreement, or failure of the parties to reach agreement on the terms of the Change Order shall relieve the Contractor from the obligation to proceed with performance of the work, including Additional Work, promptly and expeditiously. 6. Contractor shall make available to the City any of the Contractor’s documents related to the Project immediately upon request of the City, as set forth in Article 52. 7. Any alterations, extensions of time, Additional Work, or any other changes may be made without securing consent of the Contractor’s surety or sureties. B. Contract Price Change. 1. Process for Determining Adjustments in Contract Price. a. Owner Initiated Change. The Contractor must submit a complete cost proposal, including any change in the Contract Price or Contract Time, within seven (7) Days after receipt of a scope of a proposed change order initiated by the City, unless the City requests that proposals be submitted in less than seven (7) Days. b. Contractor Initiated Change. The Contractor must give written notice of a proposed change order required for compliance with the Contract Documents within seven (7) Days of discovery of the facts giving rise to the proposed change order. c. Whenever possible, any changes to the Contract amount shall be in a lump sum mutually agreed to by the Contractor and the City. 61147.91007\30425843.2 -46- 00 72 13 – GENERAL CONDITIONS d. Price quotations from the Contractor shall be accompanied by sufficiently detailed supporting documentation to permit verification by the City, including but not limited to estimates and quotations from subcontractors or material suppliers, as the City may reasonably request. Contractor shall certify the accuracy of all Change Order Requests under penalty of perjury. e. If the Contractor fails to submit a complete cost proposal within the seven (7) Day period (or as requested), the City has the right to order the Contractor in writing to commence the Work immediately on a time and materials basis and/or issue a lump sum change to the Contract Price and/or Contract Time in accordance with the City’s estimate. If the change is issued based on the City's estimate, the Contractor will waive its right to dispute the action unless within fifteen (15) Days following completion of the added/deleted work, the Contractor presents written proof that the City’s estimate was in error. 2. Unit Price Change Orders. a. When the actual quantity of a Unit Price item varies from the Bid Form, compensation for the change in quantity will be calculated by multiplying the actual quantity by the Unit Price. This calculation may result in either an additive or deductive Final Change Order pursuant to the Contract Documents. b. No Mark up for Overhead and Profit. Because the Contract Unit Prices provided in the Bid Form include Overhead and Profit as determined by Contractor at the time of Bid submission, no mark up or deduction for Overhead and Profit will be included in Unit Price Change Orders. c. Bid items included on the Bid Form may be deducted from the Work in their entirety without any negotiated extra costs. d. Contractor acknowledges that unit quantities are estimates and agrees that the estimated unit quantities listed on the Bid Form will be adjusted to reflect the actual unit quantities which may result in an adjustment to the Contract Unit Prices. Such an adjustment will be made by execution of a final additive or deductive Change Order following Contractor’s completion of the Work. Upon notification, Contractor’s failure to respond within seven (7) Days will result in City’s issuance of a unit quantity adjustment to the Contract Unit Prices and/or Contract Time in accordance with the Contract Documents. e. The City or Contractor may make a Claim for an adjustment in the Unit Price in accordance with the Contract Documents if: i. the quantity of any item of Unit Price Work performed by Contractor differs by twenty-five percent (25%) or more from the estimated quantity of such item indicated in the Contract; and ii. there is no corresponding adjustment with respect to any other item of Work; and 61147.91007\30425843.2 -47- 00 72 13 – GENERAL CONDITIONS iii. Contractor believes that Contractor is entitled to an increase in Unit Price as a result of having incurred additional expense or the City believes that the City is entitled to a decrease in Unit Price and the parties are unable to agree as to the amount of any such increase or decrease.. 3. Lump Sum Change Orders. Compensation for Lump Sum Change Orders shall be limited to expenditures necessitated specifically by the Additional Work, and shall be segregated as follows: a. Labor. The costs of labor will be the actual cost for wages prevailing locally for each craft or type of worker at the time the Additional Work is done, plus employer payments of payroll taxes and insurance, health and welfare, pension, vacation, apprenticeship funds, and other direct costs resulting from Federal, State or local laws, as well as assessment or benefits required by lawful collective bargaining agreements. The use of a labor classification which would increase the Additional Work cost will not be permitted unless the Contractor establishes the necessity for such new classifications. Labor costs for equipment operators and helpers shall be reported only when such costs are not included in the invoice for equipment rental. b. Materials. The cost of materials reported shall be at invoice or lowest current price at which such materials are locally available in the quantities involved, plus sales tax, freight, and delivery. Materials costs shall be based upon supplier or manufacturer’s invoice. If invoices or other satisfactory evidence of cost are not furnished within fifteen (15) Days of delivery, then the City shall determine the materials cost, at its sole discretion. c. Tool and Equipment Use. Costs for the use of small tools, which are tools that have a replacement value of $1,000 or less, shall be considered included in the Overhead and Profit mark-ups established below. Regardless of ownership, the rates to be used in determining equipment use costs shall not exceed listed rates prevailing locally at equipment rental agencies, or distributors, at the time the Work is performed. 4. Time and Materials Change Orders. a. General. The term Time and Materials means the sum of all costs reasonably and necessarily incurred and paid by Contractor for labor, materials, and equipment in the proper performance of Additional Work. Except as otherwise may be agreed to in writing by the City, such costs shall be in amounts no higher than those prevailing in the locality of the Project, and shall include only the following items. b. Timely and Final Documentation. i. T&M Daily Sheets. Contractor must submit timesheets, materials invoices, records of equipment hours, and records of rental equipment hours to the City’s Representative for an approval signature each day Additional Work is performed. Failure to get the City’s Representative’s approval signature each Day shall result in a waiver of Contractor’s right to claim these costs. The City’s Representative’s signature on time 61147.91007\30425843.2 -48- 00 72 13 – GENERAL CONDITIONS sheets only serves as verification that the Work was performed and is not indicative of City’s agreement to Contractor’s entitlement to the cost. ii. T&M Daily Summary Sheets. All documentation of incurred costs (“T&M Daily Summary Sheets”) shall be submitted by Contractor within three (3) Days of incurring the cost for labor, material, equipment, and special services as Additional Work is performed. Contractor’s actual costs shall be presented in a summary table in an electronic spreadsheet file by labor, material, equipment, and special services. Each T&M Daily Summary Sheet shall include Contractor’s actual costs incurred for the Additional Work performed that day and a cumulative total of Contractor’s actual costs incurred for the Additional Work. Contractor’s failure to provide a T&M Daily Summary Sheet showing a total cost summary within three (3) Days but within five (5) Days of performance of the Work will result in the Contractor’s otherwise allowable overhead and profit being reduced by 50% for that portion of Additional Work which was not documented in a timely manner. Contractor’s failure to submit the T&M Daily Summary Sheet within five (5) Days of performance of the Work will result in a total waiver of Contractor’s right to claim these costs. iii. T&M Total Cost Summary Sheet. Contractor shall submit a T&M Total Cost Summary Sheet, which shall include total actual costs, within seven (7) Days following completion of City approved Additional Work. Contractor’s total actual cost shall be presented in a summary table in an electronic spreadsheet file by labor, material, equipment, and special services. Contractor’s failure to submit the T&M Total Cost Summary Sheet within seven (7) Days of completion of the Additional Work will result in Contractor’s waiver for any reimbursement of any costs associated with the T&M Summary Sheets or the performance of the Additional Work. c. Labor. The Contractor will be paid the cost of labor for the workers used in the actual and direct performance of the Work. The cost of labor will be the sum of the actual wages paid (which shall include any employer payments to or on behalf of the workers for health and welfare, pension, vacation, and similar purposes) substantiated by timesheets and certified payroll for wages prevailing for each craft or type of workers performing the Additional Work at the time the Additional Work is done, and the labor surcharge set forth in the Department of Transportation publication entitled Labor Surcharge and Equipment Rental Rates, which is in effect on the date upon which the Work is accomplished and which is a part of the Contract. The labor surcharge shall constitute full compensation for all payments imposed by Federal, State, or local laws and for all other payments made to, or on behalf of, the workers, other than actual wages. i. Equipment Operator Exception. Labor costs for equipment operators and helpers shall be paid only when such costs are not included in the invoice for equipment rental. ii. Foreman Exception. The labor costs for foremen shall be proportioned to all of their assigned work and only that applicable to the Additional Work 61147.91007\30425843.2 -49- 00 72 13 – GENERAL CONDITIONS shall be paid. Indirect labor costs, including, without limitation, the superintendent, project manager, and other labor identified in the Contract Documents will be considered Overhead. d. Materials. The cost of materials reported shall be itemized at invoice or lowest current price at which materials are locally available and delivered to the Project site in the quantities involved, plus the cost of sales tax, freight, delivery, and storage. i. Trade discounts available to the purchaser shall be credited to the City notwithstanding the fact that such discounts may not have been taken by Contractor. ii. For materials secured by other than a direct purchase and direct billing to the purchaser, the cost shall be deemed to be the price paid to the actual supplier as determined by the City’s Representative. iii. Payment for materials from sources owned wholly or in part by the purchaser shall not exceed the price paid by the purchaser for similar materials from said sources on Additional Work items or the current wholesale price for such materials delivered to the Project site, whichever price is lower. iv. If, in the opinion of the City’s Representative, the cost of materials is excessive, or Contractor does not furnish satisfactory evidence of the cost of such materials, then the cost shall be deemed to be the lowest current wholesale price for the total quantity concerned delivered to the Project site less trade discounts. v. The City reserves the right to furnish materials for the Additional Work and no Claim shall be allowed by Contractor for costs of such materials or Indirect Costs or profit on City furnished materials. e. Equipment. i. Rental Time. The rental time to be paid for equipment on the Project site shall be the time the equipment is in productive operation on the Additional Work being performed and, in addition, shall include the time required to move the equipment to the location of the Additional Work and return it to the original location or to another location requiring no more time than that required to return it to its original location; except that moving time will not be paid if the equipment is used on other than the Additional Work, even though located at the site of the Additional Work. (a) Rental Time Not Allowed. Rental time will not be allowed while equipment is inoperative due to breakdowns. (b) Computation Method. The following shall be used in computing the rental time of equipment on the Project site. 61147.91007\30425843.2 -50- 00 72 13 – GENERAL CONDITIONS (i) When hourly rates are paid, any part of an hour less than 30 minutes of operation shall be considered to be 1/2-hour of operation, and any part of an hour in excess of 30 minutes will be considered one hour of operation. (ii) When daily rates are paid, any part of a day less than 4 hours operation shall be considered to be 1/2-day of operation, and any part of an hour in excess of 4 hours will be considered one day of operation. ii. Rental Rates. Contractor will be paid for the use of equipment at the lesser of (i) the actual rental rate, or (ii) the rental rate listed for that equipment in the California Department of Transportation publication entitled Labor Surcharge and Equipment Rental Rates, which is in effect on the date upon which the Contract was executed. Such rental rates will be used to compute payments for equipment whether the equipment is under Contractor’s control through direct ownership, leasing, renting, or another method of acquisition. The rental rate to be applied for use of each item of equipment shall be the rate (i.e., daily, monthly) resulting in the least total cost to the City for the total period of use. If it is deemed necessary by Contractor to use equipment not listed in the publication, an equitable rental rate for the equipment will be established by the City’s Representative. Contractor may furnish cost data which might assist the City’s Representative in the establishment of the rental rate. iii. Contractor-Owned Equipment. (a) For Contractor-owned equipment, the allowed equipment rental rate will be limited to the monthly equipment rental rate using a utilization rate of 173 hours per month. (b) For Contractor-owned equipment, the rental time to be paid for equipment on the Site shall be the time the equipment is in productive operation, unless, in the instance of standby time, the equipment could be actively used by Contractor on another project, then City shall pay for the entirety of the time the equipment is on Site. It shall be Contractor’s burden to demonstrate to the City that the equipment could be actively used on another project. iv. All equipment shall, in the opinion of the City’s Representative, be in good working condition and suitable for the purpose for which the equipment is to be used. v. Before construction equipment is used on the Additional Work, Contractor shall plainly stencil or stamp an identifying number thereon at a conspicuous location, and shall furnish to the City’s Representative, in duplicate, a description of the equipment and its identifying number and the scheduled Additional Work activities planned. vi. Unless otherwise specified, manufacturer’s rating and manufacturer approved modifications shall be used to classify equipment for the 61147.91007\30425843.2 -51- 00 72 13 – GENERAL CONDITIONS determination of applicable rental rates. Equipment which has no direct power unit shall be powered by a unit of at least the minimum rating recommended by the manufacturer. f. Special Services. Special work or services are defined as that Additional Work characterized by extraordinary complexity, sophistication, or innovation or a combination of the foregoing attributes which are unique to the construction industry. i. Invoices for Special Services. When the City’s Representative and Contractor determine that a special service is required which cannot be performed by the forces of Contractor or those of any of its Subcontractors, the special service may be performed by an entity especially skilled in the Additional Work. Invoices for special services based upon the current fair market value thereof may be accepted without complete itemization of labor, material, and equipment rental costs, after validation of market values by the City’s Representative. ii. Discount and Allowance. All invoices for special services will be adjusted by deducting all trade discounts offered or available, whether the discounts were taken or not. In lieu of Overhead and Profit specified herein, a total allowance not to exceed fifteen percent (15%) for Overhead and Profit will be added to invoices for Special Services. iii. When the City determines, in its sole discretion, that competitive bidding is necessary for certain special services, Contractor shall solicit competitive bids for those special services. g. Excluded Costs. The term Time and Material shall not include any of the following costs or any other home or field office overhead costs, all of which are to be considered administrative costs covered by Contractor’s allowance for Overhead and Profit. i. Overhead Cost. Payroll costs and other compensation of Contractor’s officers, executives, principals, general managers, engineers, architects, estimators, attorneys, auditors, accountants, purchasing and contracting agents, timekeepers, clerks, and other personnel employed by Contractor whether at the Site or in Contractor’s principal office or any branch office, material yard, or shop for general administration of the Additional Work; ii. Office Expenses. Expenses of Contractor’s principal and branch offices; iii. Capital Expenses. Any part of Contractor’s capital expenses, including interest on Contractor’s capital employed for the Additional Work and charges against Contractor for delinquent payments; iv. Negligence. Costs due to the negligence of Contractor or any Subcontractor or Supplier, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, including without limitation the correction of Defective Work, disposal of materials 61147.91007\30425843.2 -52- 00 72 13 – GENERAL CONDITIONS or equipment wrongly supplied, and making good any damage to property; v. Other. Other overhead or general expense costs of any kind and the cost of any item not specifically and expressly included in the Contract Documents; vi. Small Tools. Cost of small tools valued at less than $1,000 and that remain the property of Contractor; vii. Administrative Costs. Costs associated with the preparation of Change Orders (whether or not ultimately authorized), cost estimates, or the preparation or filing of Claims; viii. Anticipated Lost Profits. Expenses of Contractor associated with anticipated lost profits or lost revenues, lost income or earnings, lost interest on earnings, or unpaid retention; ix. Home Office Overhead. Costs derived from the computation of a “home office overhead” rate by application of the Eichleay, Allegheny, burden fluctuation, or other similar methods; x. Special Consultants and Attorneys. Costs of special consultants or attorneys, whether or not in the direct employ of Contractor, employed for services specifically related to the resolution of a Claim, dispute, or other matter arising out of or relating to the performance of the Additional Work. h. Overhead, Profit and Other Charges. The mark-up for overhead (including supervision) and profit on work added to the Contract shall be according to the following: i. “Net Cost” is defined as consisting of costs of labor, materials, and tools and equipment only excluding overhead and profit. The costs of applicable insurance and bond premium will be reimbursed to the Contractor and subcontractors at cost only, without mark-up. Contractor shall provide City with documentation of the costs, including, but not limited to, payroll records, invoices, and such other information as City may reasonably request. ii. For Work performed by the Contractor’s forces, the added cost for overhead and profit shall not exceed fifteen percent (15%) of the Net Cost of the Work. iii. For Work performed by a subcontractor, the added cost for overhead and profit shall not exceed fifteen percent (15%) of the subcontractor’s Net Cost of the Work to which the Contractor may add five percent (5%) of the subcontractor’s Net Cost. iv. For Work performed by a sub-subcontractor, the added cost for overhead and profit shall not exceed fifteen percent (15%) of the sub- subcontractor’s Net Cost for Work to which the subcontractor and general 61147.91007\30425843.2 -53- 00 72 13 – GENERAL CONDITIONS contractor may each add an additional five percent (5%) of the Net Cost of the lower tier subcontractor. v. No additional mark-up will be allowed for lower tier subcontractors, and in no case shall the added cost for overhead and profit payable by City exceed twenty-five percent (25%) of the Net Cost as defined herein, of the party that performs the Work. 5. All of the following costs are included in the markups for overhead and profit described above, and Contractor shall not receive any additional compensation for: Submittals, drawings, field drawings, Shop Drawings, including submissions of drawings; field inspection; General Superintendence; General administration and preparation of cost proposals, schedule analysis, Change Orders, and other supporting documentation; computer services; reproduction services; Salaries of project engineer, superintendent, timekeeper, storekeeper, and secretaries; Janitorial services; Small tools, incidentals and consumables; Temporary On-Site facilities (Offices, Telephones, High Speed Internet Access, Plumbing, Electrical Power, Lighting; Platforms, Fencing, Water), Jobsite and Home office overhead or other expenses; vehicles and fuel used for work otherwise included in the Contract Documents; Surveying; Estimating; Protection of Work; Handling and disposal fees; Final Cleanup; Other Incidental Work; Related Warranties; insurance and bond premiums. 6. For added or deducted Work by subcontractors, the Contractor shall furnish to the City the subcontractor’s signed detailed record of the cost of labor, material and equipment, including the subcontractor markup for overhead and profit. The same requirement shall apply to sub-subcontractors 7. For added or deducted work furnished by a vendor or supplier, the Contractor shall furnish to the City a detailed record of the cost to the Contractor, signed by such vendor or supplier. 8. Any change in the Work involving both additions and deletions shall indicate a net total cost, including subcontracts and materials. Allowance for overhead and profit, as specified herein, shall be applied if the net total cost is an increase in the Contract Price; overhead and profit allowances shall not be applied if the net total cost is a deduction to the Contract Price. The estimated cost of deductions shall be based on labor and material prices on the date the Contract was executed. 9. Contractor shall not reserve a right to assert impact costs, extended job site costs, extended overhead, constructive acceleration and/or actual acceleration beyond what is stated in the Change Order for Work. No claims shall be allowed for impact, extended overhead costs, constructive acceleration and/or actual acceleration due to a multiplicity of changes and/or clarifications. The Contractor may not change or modify the City’s change order form in an attempt to reserve additional rights. 10. If the City disagrees with the proposal submitted by Contractor, it will notify the Contractor and the City will provide its opinion of the appropriate price and/or time extension. If the Contractor agrees with the City, a Change Order will be 61147.91007\30425843.2 -54- 00 72 13 – GENERAL CONDITIONS issued by the City. If no agreement can be reached, the City shall have the right to issue a unilateral Change Order setting forth its determination of the reasonable additions or savings in costs and time attributable to the extra or deleted work. Such determination shall become final and binding if the Contractor fails to submit a claim in writing to the City within fifteen (15) Days of the issuance of the unilateral Change Order, disputing the terms of the unilateral Change Order, and providing such supporting documentation for its position as the City may require. C. Change of Contract Times. 1. The Contract Times may only be changed by a Change Order. 2. All changes in the Contract Price and/or adjustments to the Contract Times related to each change shall be included in Contractor’s COR pursuant to this Article. No cost or time will be allowed for cumulative effects of multiple changes. All Change Orders must state that the Contract Time is not changed or is either increased or decreased by a specific number of days. Failure to include a change to time shall waive any change to the time unless the parties mutually agree in writing to postpone a determination of the change to time resulting from the Change Order. 3. Notice of the amount of the request for adjustment in the Contract Times with supporting data shall be delivered within seven (7) Days after such start of occurrence, unless City’s Representative allows an additional period of time to ascertain more accurate data in support of the request. No extension of time or additional compensation shall be given for a delay if the Contractor failed to give notice in the manner and within the time prescribed. 4. City may elect, at City’s sole discretion, to grant an extension in Contract Times, without Contractor’s request, because of delays or other factors. 5. Use of Float and Critical Path. a. Float is for the benefit of the Project. Float shall not be considered for the exclusive use or benefit of either the City or the Contractor. b. Contractor shall not be entitled to compensation, and City will not compensate Contractor, for delays which impact early completion. Any difference in time between the Contractor’s early completion and the Contract Time shall be considered a part of the Project float. 6. Contractor’s entitlement to an extension of the Contract Times is limited to a City- caused extension of the critical path, reduced by the Contractor’s concurrent delays, and established by a proper time impact analysis. No time extension shall be allowed unless, and then only to the extent that, the City-caused delay extends the critical path beyond the previously approved Contract Time. If approved, the increase in time required to complete the Work shall be added to the Contract Time. 61147.91007\30425843.2 -55- 00 72 13 – GENERAL CONDITIONS a. Contractor shall not be entitled to an adjustment in the Contract Price or Contract Times for delays within the control of Contractor. Delays attributable to and within the control of a Subcontractor or Supplier shall be deemed to be delays within the control of Contractor. b. If Contractor is delayed in the performance or progress of the Work by fire, flood, epidemic, abnormal weather conditions (as determined by the City), Acts of God, acts or failures to act of utility owners not under the control of City, or other causes not the fault of and beyond control of City and Contractor, then Contractor shall be entitled to an time extension when the Work stopped is on the critical path. Such a non-compensable adjustment shall be Contractor’s sole and exclusive remedy for such delays. Contractor must submit a timely request in accordance with the requirements of this Article. c. Utility-Related Delays. i. Contractor shall immediately notify in writing the utility owner and City’s Representative of its construction schedule and any subsequent changes in the construction schedule which will affect the time available for protection, removal, or relocation of utilities. Requests for extensions of time arising out of utility relocation or repair delays shall be filed in accordance with this Article. ii. Contractor shall not be entitled to damages or additional payment for delays attributable to utility relocations or alterations if correctly located, as noted in the Contract Documents or by the Underground Service Alert survey. 7. Content for Requests for Contract Extension. Contractor’s justification for entitlement shall be clear and complete citing specific Contract Document references and reasons on which Contractor’s entitlement is based. At a minimum, each request for a time extension must include: a. Each request for an extension of Contract Time must identify the impacting event, in narrative form, providing a description of the delay event and sufficient justification as to why the Contractor is entitled to a time extension. Contractor must demonstrate that the delay arises from unforeseeable causes beyond the control and without the fault or negligence of both Contractor and any Subcontractors or Suppliers, or any other persons or organizations employed by any of them or for whose acts any of them may be liable, and that such causes in fact lead to performance or completion of the Work, or specified part in question, beyond the corresponding Contract Times, despite Contractor’s reasonable and diligent actions to guard against those effects. b. Each request for an extension of Contract Time must include a time impact analysis in CPM format, using the Contemporaneous Impacted As-Planned Schedule Analysis to calculate the impact of the delay event. 8. No Damages for Reasonable Delay. 61147.91007\30425843.2 -56- 00 72 13 – GENERAL CONDITIONS a. City’s liability to Contractor for delays for which City is responsible shall be limited to only an extension of time unless such delays were unreasonable under the circumstances. In no case shall City be liable for any costs which are borne by the Contractor in the regular course of business, including, but not limited to, home office overhead and other ongoing costs. b. Damages caused by unreasonable City delay that impact the critical path, including delays caused by items that are the responsibility of the City pursuant to Government Code section 4215, shall be compensated at the Daily Rate established in the Special Conditions. No other calculations, proportions or formulas shall be used to calculate any delay damages. c. City and City’s Representative, and the officers, members, partners, employees, agents, consultants, or subcontractors of each of them, shall not be liable to Contractor for any claims, costs, losses, or damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. 9. Contractor’s failure, neglect, or refusal to comply with the requirements of the Contract Documents, or any portion thereof, shall bar Contractor’s request for extensions of the Contract Times. Such failure, neglect, or refusal prejudices City’s and City’s Representative’s ability to recognize and mitigate delay, and such failure, neglect, or refusal prevent the timely analysis of requests for extensions of Contract Times, and whether such extensions may be warranted. Contractor hereby waives all rights to extensions of Contract Times due to delays or accelerations that result from or occur during periods of time for which Contractor fails, neglects, or refuses to fully comply with the requirements of this Article. ARTICLE 45. FINAL ACCEPTANCE AND PAYMENT A. The acceptance of the Work on behalf of the City will be made by the Engineer. Such acceptance by the City shall not constitute a waiver of defects. When the Work has been accepted there shall be paid to Contractor a sum equal to the contract price less any amounts previously paid Contractor and less any amounts withheld by the City from Contractor under the terms of the contract. The final five percent (5%), or the percentage specified in the notice inviting bids where the City has adopted a finding of substantially complete, shall not become due and payable until five (5) calendar days shall have elapsed after the expiration of the period within which all claims may be filed under the provisions of Civil Code section 9356. If the Contractor has placed securities with the City as described herein, the Contractor shall be paid a sum equal to one hundred percent (100%) of the contract price less any amounts due the City under the terms of the Contract. B. Unless Contractor advises the City in writing prior to acceptance of the final five percent (5%) or the percentage specified in the notice inviting bids where the City has adopted a finding of substantially complete, or the return of securities held as described herein, said acceptance shall operate as a release to the City of all claims and all liability to Contractor for all things done or furnished in connection with this 61147.91007\30425843.2 -57- 00 72 13 – GENERAL CONDITIONS work and for every act of negligence of the City and for all other claims relating to or arising out of this work. If Contractor advises the City in writing prior to acceptance of final payment or return of the securities that there is a dispute regarding the amount due the Contractor, the City may pay the undisputed amount contingent upon the Contractor furnishing a release of all undisputed claims against the City with the disputed claims in stated amounts being specifically excluded by Contractor from the operation of the release. No payments, however, final or otherwise, shall operate to release Contractor or its sureties from the Faithful Performance Bond, Labor and Material Payment Bond, or from any other obligation under this contract. C. In case of suspension of the contract any unpaid balance shall be and become the sole and absolute property of the City to the extent necessary to repay the City any excess in the cost of the Work above the contract price. D. Final payment shall be made no later than 60 days after the date of acceptance of the Work by the City or the date of occupation, beneficial use and enjoyment of the Work by the City including any operation only for testing, start-up or commissioning accompanied by cessation of labor on the Work, provided that a release of liens and claims has been received from the Contractor pursuant to Civil Code section 8136. In the event of a dispute between the City and the Contractor, the City may withhold from the final payment an amount not to exceed 150% of the disputed amount. E. Within ten (10) calendar days from the time that all or any portion of the retention proceeds are received by Contractor, Contractor shall pay each of its subcontractors from whom retention has been withheld each subcontractor’s share of the retention received. However, if a retention payment received by Contractor is specifically designated for a particular subcontractor, payment of the retention shall be made to the designated subcontractor if the payment is consistent with the terms of the subcontract. ARTICLE 46. OCCUPANCY The City reserves the right to occupy or utilize any portion of the Work at any time before completion, and such occupancy or use shall not constitute acceptance of any part of Work covered by this Contract. This use shall not relieve the Contractor of its responsibilities under the Contract. ARTICLE 47. INDEMNIFICATION To the fullest extent permitted by law, Contractor shall immediately defend (with counsel of the City’s choosing), indemnify and hold harmless the City, officials, officers, agents, employees, and representatives, and each of them from and against: A. Any and all claims, demands, causes of action, costs, expenses, injuries, losses or liabilities, in law or in equity, of every kind or nature whatsoever, but not limited to, injury to or death, including wrongful death, of any person, and damages to or destruction of property of any person, arising out of, related to, or in any manner directly or indirectly connected with the Work or this Contract, including claims made by subcontractors for nonpayment, including without limitation the payment of all consequential damages and attorney’s fees and other related costs and expenses, however caused, regardless of whether the allegations are false, fraudulent, or 61147.91007\30425843.2 -58- 00 72 13 – GENERAL CONDITIONS groundless, and regardless of any negligence of the City or its officers, employees, or authorized volunteers (including passive negligence), except the sole negligence or willful misconduct or active negligence of the City or its officials, officers, employees, or authorized volunteers. B. Contractor’s defense and indemnity obligation herein includes, but is not limited to damages, fines, penalties, attorney’s fees and costs arising from claims under the Americans with Disabilities Act (ADA) or other federal or state disability access or discrimination laws arising from Contractor’s Work during the course of construction of the improvements or after the Work is complete, as the result of defects or negligence in Contractor’s construction of the improvements. C. Any and all actions, proceedings, damages, costs, expenses, fines, penalties or liabilities, in law or equity, of every kind or nature whatsoever, arising out of, resulting from, or on account of the violation of any governmental law or regulation, compliance with which is the responsibility of Contractor; D. Any and all losses, expenses, damages (including damages to the Work itself), attorney’s fees, and other costs, including all costs of defense which any of them may incur with respect to the failure, neglect, or refusal of Contractor to faithfully perform the Work and all of Contractor’s obligations under the agreement. Such costs, expenses, and damages shall include all costs, including attorney’s fees, incurred by the indemnified parties in any lawsuit to which they are a party. Contractor shall immediately defend, at Contractor’s own cost, expense and risk, with the City Council’s choosing, any and all such aforesaid suits, actions or other legal proceedings of every kind that may be brought or instituted against the City, its officials, officers, agents, employees and representatives. Contractor shall pay and satisfy any judgment, award or decree that may be rendered against the City, its officials, officers, employees, agents, employees and representatives, in any such suit, action or other legal proceeding. Contractor shall reimburse the City, its officials, officers, agents, employees and representatives for any and all legal expenses and costs incurred by each of them in connection therewith or in enforcing the indemnity herein provided. The only limitations on this provision shall be those imposed by Civil Code section 2782. ARTICLE 48. PROCEDURE FOR RESOLVING DISPUTES In accordance with Public Contract Code sections 20104 et seq. and other applicable law, public works claims of $375,000 or less which arise between the Contractor and the City shall be resolved under the following statutory procedure unless the City has elected to resolve the dispute pursuant to Public Contract Code section 10240 et seq. A. All Claims. All claims shall be submitted in writing and accompanied by substantiating documentation. Claims must be filed on or before the date of final payment unless other notice requirements are provided in the contract. “Claim” means a separate demand by the Contractor for (1) a time extension, (2) payment of money or damages arising from work done by or on behalf of the Contractor and payment of which is not otherwise expressly provided for or the Contractor is not otherwise entitled, or (3) an amount the payment of which is disputed by the City. 61147.91007\30425843.2 -59- 00 72 13 – GENERAL CONDITIONS B. Claims Under $50,000. The City shall respond in writing to the claim within 45 calendar days of receipt of the claim, or, the City may request, in writing, within 30 calendar days of receipt of the claim, any additional documentation supporting the claim or relating to defenses or claims the City may have. If additional information is needed thereafter, it shall be provided upon mutual agreement of the City and the Contractor. The City’s written response shall be submitted 15 calendar days after receiving the additional documentation, or within the same period of time taken by the Contractor to produce the additional information, whichever is greater. C. Claims over $50,000 but less than or equal to $375,000. The City shall respond in writing within 60 calendar days of receipt, or, may request in writing within 30 calendar days of receipt of the claim, any additional documents supporting the claim or relating to defenses or claims the City may have against the City. If additional information is needed thereafter, it shall be provided pursuant to mutual agreement between the City and the Contractor. The City response shall be submitted within 30 calendar days after receipt of the further documents, or within the same period of time taken by the Contractor to produce the additional information or documents, whichever is greater. The Contractor shall make these records and documents available at all reasonable times, without any direct charge. D. All Claims. The Contractor will submit the claim justification in the following format: 1. Summary of claim merit and price, and Contract clause pursuant to which the claim is made. 2. List of documents relating to claim: a. Specifications b. Drawings c. Clarifications (Requests for Information) d. Schedules e. Other (All Related Documents) 3. Chronology of events and correspondence. 4. Analysis of claim merit. 5. Analysis of claim cost. 6. Analysis of time impact analysis in CPM format. 7. Cover letter and certification of validity of the claim. E. All Claims. If the Contractor disputes the City’s response, or if the City fails to respond within the statutory time period(s), the Contractor may so notify the City within 15 calendar days of the receipt of the response or the failure to respond, and demand an informal conference to meet and confer for settlement. Upon such demand, the City shall schedule a meet and confer conference within 30 calendar days. 61147.91007\30425843.2 -60- 00 72 13 – GENERAL CONDITIONS F. The Contractor must comply with the claims filing procedures set forth in Government Code sections 900 et seq. for any claim or any portion thereof that remains in dispute, after the meet and confer conference. For purposes of those provisions, the time within which a claim must be filed shall be tolled from the time the Contractor submits the written claim until the time the claim is denied, including any time utilized for the meet and confer conference. Submission of a claim, properly certified, with all required supporting documentation, and written rejection or denial of all or part of the claim by the City, is a condition precedent to any action, proceeding, litigation, suit, general conditions claim, or demand for arbitration by Contractor. G. Government Code Claim. In addition to any and all contract requirements pertaining to notices of and requests for compensation or payment for extra work, disputed work, construction claims and/or changed conditions, the Contractor must comply with the claim procedures set forth in Government Code sections 900 et seq. prior to filing any lawsuit against the City. Such Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to extra work, disputed work, construction claims, and/or changed conditions have been followed by Contractor. If no such Government Code claim is submitted, or if the prerequisite contractual requirements are not otherwise satisfied as specified herein, Contractor shall be barred from bringing and maintaining a valid lawsuit against the City. ARTICLE 49. CITY’S RIGHT TO TERMINATE CONTRACT A. Termination for Cause by the City: 1. In the sole estimation of the City, if the Contractor refuses or fails to prosecute the Work or any separable part thereof with such diligence as will insure its completion within the time specified by the Contract Documents, or any extension thereof, or fails to complete such Work within such time, or if the Contractor should be adjudged a bankrupt, or if it should make a general assignment for the benefit of its creditors, or if a receiver should be appointed on account of its insolvency, or the Contractor or any of its subcontractors should violate any of the provisions of this Contract, the City may serve written notice upon the Contractor and its Surety of the City's intention to terminate this Contract. This notice of intent to terminate shall contain the reasons for such intention to terminate this Contract, and a statement to the effect that the Contractor's right to perform this Contract shall cease and terminate upon the expiration of ten (10) calendar days unless such violations have ceased and arrangements satisfactory to the City have been made for correction of said violations. 2. In the event that the City serves such written notice of termination upon the Contractor and the Surety, the Surety shall have the right to take over and perform the Contract. If the Surety does not: (1) give the City written notice of Surety's intention to take over and commence performance of the Contract within 15 calendar days of the City's service of said notice of intent to terminate upon Surety; and (2) actually commence performance of the Contract within 30 calendar days of the City's service of said notice upon Surety; then the City may take over the Work and prosecute the same to completion by separate contract 61147.91007\30425843.2 -61- 00 72 13 – GENERAL CONDITIONS or by any other method it may deem advisable for the account and at the expense of the Contractor. 3. In the event that the City elects to obtain an alternative performance of the Contract as specified above: (1) the City may, without liability for so doing, take possession of and utilize in completion of the Work such materials, appliances, plants and other property belonging to the Contractor that are on the site and reasonably necessary for such completion (A special lien to secure the claims of the City in the event of such suspension is hereby created against any property of Contractor taken into the possession of the City under the terms hereof and such lien may be enforced by sale of such property under the direction of the City Council without notice to Contractor. The proceeds of the sale after deducting all expenses thereof and connected therewith shall be credited to Contractor. If the net credits shall be in excess of the claims of the City against Contractor, the balance will be paid to Contractor or Contractor’s legal representatives.); and (2) Surety shall be liable to the City for any cost or other damage to the City necessitated by the City securing an alternate performance pursuant to this Article. B. Termination for Convenience by the City: 1. The City may terminate performance of the Work called for by the Contract Documents in whole or, from time to time, in part, if the City determines that a termination is in the City's interest. 2. The Contractor shall terminate all or any part of the Work upon delivery to the Contractor of a Notice of Termination specifying that the termination is for the convenience of the City, the extent of termination, and the Effective Date of such termination. 3. After receipt of Notice of Termination, and except as directed by the City's Representative, the Contractor shall, regardless of any delay in determining or adjusting any amounts due under this Termination for Convenience clause, immediately proceed with the following obligations: a. Stop Work as specified in the Notice. b. Complete any Work specified in the Notice of Termination in a least cost/shortest time manner while still maintaining the quality called for under the Contract Documents. c. Leave the property upon which the Contractor was working and upon which the facility (or facilities) forming the basis of the Contract Document is situated in a safe and sanitary manner such that it does not pose any threat to the public health or safety. d. Terminate all subcontracts to the extent that they relate to the portions of the Work terminated. e. Place no further subcontracts or orders, except as necessary to complete the continued portion of the Contract. 61147.91007\30425843.2 -62- 00 72 13 – GENERAL CONDITIONS f. Submit to the City's Representative, within ten (10) calendar days from the Effective Date of the Notice of Termination, all of the usual documentation called for by the Contract Documents to substantiate all costs incurred by the Contractor for labor, materials and equipment through the Effective Date of the Notice of Termination. Any documentation substantiating costs incurred by the Contractor solely as a result of the City's exercise of its right to terminate this Contract pursuant to this clause, which costs the contractor is authorized under the Contract documents to incur, shall: (1) be submitted to and received by the Engineer no later than 30 calendar days after the Effective Date of the Notice of Termination; (2) describe the costs incurred with particularity; and (3) be conspicuously identified as “Termination Costs occasioned by the City's Termination for Convenience.” 4. Termination of the Contract shall not relieve Surety of its obligation for any just claims arising out of or relating to the Work performed. 5. In the event that the City exercises its right to terminate this Contract pursuant to this clause, the City shall pay the Contractor, upon the Contractor's submission of the documentation required by this clause and other applicable provisions of the Contract Documents, the following amounts: a. All actual reimbursable costs incurred according to the provisions of this Contract. b. A reasonable allowance for profit on the cost of the Work performed, provided Contractor establishes to the satisfaction of the City's Representative that it is reasonably probable that Contractor would have made a profit had the Contract been completed and provided further, that the profit allowed shall in no event exceed fifteen (15%) percent of the costs. c. A reasonable allowance for Contractor's administrative costs in determining the amount payable due to termination of the Contract under this Article. C. Notwithstanding any other provision of this Article, when immediate action is necessary to protect life and safety or to reduce significant exposure or liability, the City may immediately order Contractor to cease Work on the Project until such safety or liability issues are addressed to the satisfaction of the City or the Contract is terminated. ARTICLE 50. WARRANTY AND GUARANTEE OF WORK A. Contractor hereby warrants that materials and Work shall be completed in conformance with the Contract Documents and that the materials and Work provided will fulfill the requirements of this Warranty. Contractor hereby agrees to repair or replace, at the discretion of the City, any or all Work that may prove to be defective in its workmanship, materials furnished, methods of installation or fail to conform to the Contract Document requirements together with any other Work which may be damaged or displaced by such defect(s) within a period of one (1) year from the date of the Notice of Completion of the Project without any expense whatever to the City, ordinary wear and tear and unusual abuse and neglect excepted. Contractor shall be required to promptly repair or replace defective equipment or materials, at 61147.91007\30425843.2 -63- 00 72 13 – GENERAL CONDITIONS Contractor’s option. All costs associated with such corrective actions and testing, including the removal, replacement, and reinstitution of equipment and materials necessary to gain access, shall be the sole responsibility of the Contractor. B. For any Work so corrected, Contractor’s obligation hereunder to correct defective Work shall be reinstated for an additional one (1) year period, commencing with the date of acceptance of such corrected Work. The reinstatement of the one (1) year warranty shall apply only to that portion of work that was corrected. Contractor shall perform such tests as City may require to verify that any corrective actions, including, without limitation, redesign, repairs, and replacements comply with the requirements of the Contract. In the event of Contractor’s failure to comply with the above- mentioned conditions within ten (10) calendar days after being notified in writing of required repairs, to the reasonable satisfaction of the City, the City shall have the right to correct and replace any defective or non-conforming Work and any work damaged by such work or the replacement or correction thereof at Contractor’s sole expense. Contractor shall be obligated to fully reimburse the City for any expenses incurred hereunder immediately upon demand. C. In addition to the warranty set forth in this Article, Contractor shall obtain for City all warranties that would be given in normal commercial practice and assign to City any and all manufacturer’s or installer’s warranties for equipment or materials not manufactured by Contractor and provided as part of the Work, to the extent that such third-party warranties are assignable and extend beyond the warranty period set forth in this Article. Contractor shall furnish the City with all warranty and guarantee documents prior to final Acceptance of the Project by the City as required. D. When specifically indicated in the Contract Documents or when directed by the Engineer, the City may furnish materials or products to the Contractor for installation. In the event any act or failure to act by Contractor shall cause a warranty applicable to any materials or products purchased by the City for installation by the Contractor to be voided or reduced, Contractor shall indemnify City from and against any cost, expense, or other liability arising therefrom, and shall be responsible to the City for the cost of any repairs, replacement or other costs that would have been covered by the warranty but for such act or failure to act by Contractor. E. The Contractor shall remedy at its expense any damage to City-owned or controlled real or personal property. F. The City shall notify the Contractor, in writing, within a reasonable time after the discovery of any failure, defect, or damage. The Contractor shall within ten (10) calendar days after being notified commence and perform with due diligence all necessary Work. If the Contractor fails to promptly remedy any defect, or damage; the City shall have the right to replace, repair or otherwise remedy the defect, or damage at the Contractor’s expense. G. In the event of any emergency constituting an immediate hazard to health, safety, property, or licensees, when caused by Work of the Contractor not in accordance with the Contract requirements, the City may undertake at Contractor’s expense, and without prior notice, all Work necessary to correct such condition. H. Acceptance of Defective Work. 61147.91007\30425843.2 -64- 00 72 13 – GENERAL CONDITIONS 1. If, instead of requiring correction or removal and replacement of Defective Work, the City prefers to accept it, City may do so. Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) attributable to City’s evaluation of and determination to accept such Defective Work and for the diminished value of the Work. 2. If any acceptance of defective work occurs prior to release of the Project Retention, a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work, and City shall be entitled to an appropriate decrease in the Contract Price, reflecting the diminished value of Work and all costs incurred by City. 3. If the Project Retention is held in an escrow account as permitted by the Contract Documents, Contractor will promptly alert the escrow holder, in writing, of the amount of Retention to be paid to City. 4. If the acceptance of Defective Work occurs after release of the Project Retention, an appropriate amount will be paid by Contractor to City. I. City May Correct Defective Work. 1. If Contractor fails within a reasonable time after written notice from City’s Representative to correct Defective Work, or to remove and replace rejected Work as required by City, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any other provision of the Contract Documents, City may, after seven (7) Days’ written notice to Contractor, correct, or remedy any such deficiency. 2. In connection with such corrective or remedial action, City may exclude Contractor from all or part of the Site, take possession of all or part of the Work and suspend Contractor’s services related thereto, take possession of Contractor’s tools, appliances, construction equipment and machinery at the Site, and incorporate in the Work all materials and equipment stored at the Site or for which City has paid Contractor but which are stored elsewhere. Contractor shall allow City and City’s Representative, and the agents, employees, other contractors, and consultants of each of them, access to the Site to enable City to exercise the rights and remedies to correct the Defective Work. 3. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred or sustained by City correcting the Defective Work will be charged against Contractor, and a Change Order will be issued incorporating the necessary revisions into the Contract Documents with respect to the Work; and City shall be entitled to an appropriate decrease in the Contract Price. 4. Such claims, costs, losses and damages will include, but not be limited to, all costs of repair, or replacement of work of others destroyed or damaged by correction, removal, or replacement of Defective Work. 61147.91007\30425843.2 -65- 00 72 13 – GENERAL CONDITIONS 5. If the Change Order is executed after all payments under the Contract have been paid by City and the Project Retention is held in an escrow account as permitted by the Contract Documents, Contractor will promptly alert the escrow holder, in writing, of the amount of Retention to be paid to City. 6. If the Change Order is executed after release of the Project Retention, an appropriate amount will be paid by Contractor to City. 7. Contractor shall not be allowed an extension of the Contract Times because of any delay in the performance of the Work attributable to City correcting Defective work. J. Nothing in the Warranty or in the Contract Documents shall be construed to limit the rights and remedies available to City at law or in equity, including, but not limited to, Code of Civil Procedure section 337.15. ARTICLE 51. DOCUMENT RETENTION & EXAMINATION A. In accordance with Government Code section 8546.7, records of both the City and the Contractor shall be subject to examination and audit by the State Auditor General for a period of three (3) years after final payment. B. Contractor shall make available to the City any of the Contractor’s other documents related to the Project immediately upon request of the City. C. In addition to the State Auditor rights above, the City shall have the right to examine and audit all books, estimates, records, contracts, documents, bid documents, subcontracts, and other data of the Contractor (including computations and projections) related to negotiating, pricing, or performing the modification in order to evaluate the accuracy and completeness of the cost or pricing data at no additional cost to the City, for a period of four (4) years after final payment. ARTICLE 52. SEPARATE CONTRACTS A. The City reserves the right to let other contracts in connection with this Work or on the Project site. Contractor shall permit other contractors reasonable access and storage of their materials and execution of their work and shall properly connect and coordinate its Work with theirs. B. To ensure proper execution of its subsequent Work, Contractor shall immediately inspect work already in place and shall at once report to the Engineer any problems with the Work in place or discrepancies with the Contract Documents. C. Contractor shall ascertain to its own satisfaction the scope of the Project and nature of any other contracts that have been or may be awarded by the City in prosecution of the Project to the end that Contractor may perform this Contract in the light of such other contracts, if any. Nothing herein contained shall be interpreted as granting to Contractor exclusive occupancy at site of the Project. Contractor shall not cause any unnecessary hindrance or delay to any other contractor working on the Project. If simultaneous execution of any contract for the Project is likely to cause interference with performance of some other contract or contracts, the Engineer shall decide 61147.91007\30425843.2 -66- 00 72 13 – GENERAL CONDITIONS which Contractor shall cease Work temporarily and which contractor shall continue or whether work can be coordinated so that contractors may proceed simultaneously. The City shall not be responsible for any damages suffered or for extra costs incurred by Contractor resulting directly or indirectly from award, performance, or attempted performance of any other contract or contracts on the Project site. ARTICLE 53. NOTICE AND SERVICE THEREOF All notices shall be in writing and either served by personal delivery or mailed to the other party as designated in the Bid Forms. Written notice to the Contractor shall be addressed to Contractor’s principal place of business unless Contractor designates another address in writing for service of notice. Notice to City shall be addressed to the City as designated in the Notice Inviting Bids unless City designates another address in writing for service of notice. Notice shall be effective upon receipt or five (5) calendar days after being sent by first class mail, whichever is earlier. Notice given by facsimile shall not be effective unless acknowledged in writing by the receiving party. ARTICLE 54. NOTICE OF THIRD PARTY CLAIMS Pursuant to Public Contract Code section 9201, the City shall provide the Contractor with timely notification of the receipt of any third-party claims relating to the Contract. The City is entitled to recover reasonable costs incurred in providing such notification. ARTICLE 55. STATE LICENSE BOARD NOTICE Contractors are required by law to be licensed and regulated by the Contractors’ State License Board which has jurisdiction to investigate complaints against contractors if a complaint regarding a patent act or omission is filed within four (4) years of the date of the alleged violation. A complaint regarding a latent act or omission pertaining to structural defects must be filed within ten (10) years of the date of the alleged violation. Any questions concerning a contractor may be referred to the Registrar, Contractors’ State License Board, P.O. Box 26000, Sacramento, California 95826. ARTICLE 56. INTEGRATION A. Oral Modifications Ineffective. No oral order, objection, direction, claim or notice by any party or person shall affect or modify any of the terms or obligations contained in the Contract Documents. B. Contract Documents Represent Entire Contract. The Contract Documents represent the entire agreement of the City and Contractor. ARTICLE 57. ASSIGNMENT OF CONTRACT Contractor shall not assign, transfer, convey, sublet or otherwise dispose of the rights or title of interest of any or all of this contract without the prior written consent of the City. Any assignment or change of Contractor’s name of legal entity without the written consent of the City shall be void. Any assignment of money due or to become due under this Contract shall be subject to a prior lien for services rendered or Material supplied for performance of Work called for under the Contract Documents in favor of all persons, firms, or corporations rendering such services or supplying such Materials to the extent that claims are filed pursuant to the Civil 61147.91007\30425843.2 -67- 00 72 13 – GENERAL CONDITIONS Code, the Code of Civil Procedure or the Government Code. ARTICLE 58. CHANGE IN NAME AND NATURE OF CONTRACTOR’S LEGAL ENTITY Should a change be contemplated in the name or nature of the Contractor’s legal entity, the Contractor shall first notify the City in order that proper steps may be taken to have the change reflected on the Contract and all related documents. No change of Contractor’s name or nature will affect City’s rights under the Contract, including but not limited to the bonds. ARTICLE 59. ASSIGNMENT OF ANTITRUST ACTIONS Pursuant to Public Contract Code section 7103.5, in entering into a public works contract or subcontract to supply goods, services, or materials pursuant to a public works contract, Contractor or subcontractor offers and agrees to assign to the City all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 USC, Section 15) or under the Cartwright Act (Chapter 2 (commencing with Section 16700) of Part 2 of Division 7 of the Business and Professions Code), arising from the purchase of goods, services, or materials pursuant to this contract or any subcontract. This assignment shall be made and become effective at the time the City tenders final payment to the Contractor, without further acknowledgment by the parties. ARTICLE 60. PROHIBITED INTERESTS No City official or representative who is authorized in such capacity and on behalf of the City to negotiate, supervise, make, accept, or approve, or to take part in negotiating, supervising, making, accepting or approving any engineering, inspection, construction or material supply contract or any subcontract in connection with construction of the project, shall be or become directly or indirectly interested financially in the Contract. ARTICLE 61. CONTROLLING LAW Notwithstanding any subcontract or other contract with any subcontractor, supplier, or other person or organization performing any part of the Work, this Contract shall be governed by the law of the State of California excluding any choice of law provisions. ARTICLE 62. JURISDICTION; VENUE Contractor and any subcontractor, supplier, or other person or organization performing any part of the Work agrees that any action or suits at law or in equity arising out of or related to the bidding, award, or performance of the Work shall be maintained in the Superior Court of Orange County, California, and expressly consent to the jurisdiction of said court, regardless of residence or domicile, and agree that said court shall be a proper venue for any such action. ARTICLE 63. LAWS AND REGULATIONS A. Contractor shall give all notices and comply with all laws, ordinances, rules and regulations bearing on conduct of work as indicated and specified. If Contractor observes that drawings and specifications are at variance therewith, it shall promptly notify the Engineer in writing and any necessary changes shall be adjusted as provided for in this Contract for changes in work. If Contractor performs any work 61147.91007\30425843.2 -68- 00 72 13 – GENERAL CONDITIONS knowing it to be contrary to such laws, ordinances, rules and regulations, and without such notice to the Engineer, it shall bear all costs arising therefrom. B. Contractor shall be responsible for familiarity with the Americans with Disabilities Act (“ADA”) (42 U.S.C. § 12101 et seq.). The Work will be performed in compliance with ADA regulations. ARTICLE 64. PATENTS Contractor shall hold and save the City, officials, officers, employees, and authorized volunteers harmless from liability of any nature or kind of claim therefrom including costs and expenses for or on account of any patented or unpatented invention, article or appliance manufactured, furnished or used by Contractor in the performance of this contract. ARTICLE 65. OWNERSHIP OF CONTRACT DOCUMENTS All Contract Documents furnished by the City are City property. They are not to be used by Contractor or any subcontractor on other work nor shall Contractor claim any right to such documents. With exception of one complete set of Contract Documents, all documents shall be returned to the City on request at completion of the Work. ARTICLE 66. NOTICE OF TAXABLE POSSESSORY INTEREST In accordance with Revenue and Taxation Code section 107.6, the Contract Documents may create a possessory interest subject to personal property taxation for which Contractor will be responsible. ARTICLE 67. SURVIVAL OF OBLIGATIONS All reresentations, indemnifications, warranties, and guarantees made in, required by, or given in accordance with the Contract Documents, as well as all continuing obligations indicated in the Contract Documents, will survive final payment, completion, and acceptance of the Work or termination or completion of the Contract or termination of the services of Contractor. 61147.91007\30425843.2 -69- 00 73 13 – SPECIAL CONDITIONS 00 73 13 – SPECIAL CONDITIONS 1.1 Location of the Project. A. The Project is located in public rights of way as described in the Field Audit Data included as Attachment F to the IGA, and shown on the maps that are referenced by link in Attachment F. 1.2 Intentionally Omitted 1.3 Status of the Project Area and Rights-of-Way. A. City, at its expense, will provide all rights-of-way or permits, or both, covering the crossing of private property and public and private rights-of-way necessary for the permanent Work; provided, however, Contractor shall, at its expense, obtain any bonds or insurance policies or pay any fees and enter into any agreements required by a controlling authority, e.g., Caltrans or Southern Pacific Railroad Company, before Contractor enters upon any property or right-of-way under the jurisdiction of any such controlling authority for the purpose of performing Work. B. City has acquired or is negotiating to acquire any rights-of-way, or both, necessary for the permanent Work. C. If such permits are required, all operations of Contractor shall conform to the restrictions, regulations, and requirements set forth in said permits, copies of which will be included in the Contract Documents. D. Contractor may be required, as a condition for receiving final payment, to obtain, and provide City’s Representative with copies of, executed damage releases from the owners of public and private property whose property has been damaged by the Work. The damage releases will be on a form provided by City. E. Contractor shall, also, as a condition for receiving final payment, obtain, and provide City’s Representative with copies of, executed damage releases from the owners of certain public and private property or areas which have been crossed by the Work or otherwise affected by the Work. The damage releases will be on a form provided by City. 1.4 Site Data. A. The data provided herein is for the information of Contractor and is subject to all limitations and conditions set forth in the Contract Documents. Copies of these reports, drawings and other materials may be examined at City’s office during regular business hours. 1.5 Pre-Purchased or Pre-Negotiated Material. [NOT USED.] A. 61147.91007\30425843.2 -70- 00 73 13 – SPECIAL CONDITIONS 1.6 Designation of City’s Representative. A. Unless otherwise modified by City, City’s Representative shall be Thomas Toman, Assistant Public Works Director. 1.7 Modification of Hours of Work. [NOT USED.] 1.8 Project Retention In accordance with Public Contract Code § 7201, City will withhold 5% of each progress payment as retention on the Project. 1.9 Reverse Liquidated Damages Due to Unreasonable City Delay. A. In compliance with the provisions of California Public Contract Code § 7102, the Contractor will be compensated for damages incurred due to delays in completing the Work due solely to the fault of the City, where such delay is unreasonable under the circumstances and not contemplated by the parties and such delay is not the result of Additional Work. The Contractor and City agree that determining actual damages is impracticable and extremely difficult. As such, the Contractor shall be entitled to the appropriate time extension and to payment of liquidated damages in the sum of $1,000 per Day of delay in excess of the time specified for the Completion of the Work. Such amount shall constitute the only payment allowed and shall necessarily include all overhead (direct or indirect), all profit, all administrative costs, all bond costs, all labor, materials, equipment and rental costs, and any other costs, expenses and fees incurred or sustained as a result of such delay. The Contractor expressly agrees to be limited solely to the liquidated damages for all such delays as defined in this subsection. 1.10 Liquidated Damages Due to Contractor Delay. A. Time is of the essence. Should Contractor fail to complete all or any part of the Work within the time specified in the Contract Documents, City will suffer damage, the amount of which is difficult, if not impossible, to ascertain and, pursuant to the authority of Government Code section 53069.85, City shall therefore be entitled to $1,000 per Day as liquidated damages for each Day or part thereof that actual completion extends beyond the time specified. B. Liquidated damages may be deducted from progress payments due Contractor, Project retention or may be collected directly from Contractor, or from Contractor's surety. These provisions for liquidated damages shall not prevent City, in case of Contractor's default, from terminating the Contractor. 1.11 Utility Outages – Notices to Residents. A. Should Contractor’s operations require interruption of any utility service, Contractor shall notify City at least ten (10) Days prior to the scheduled outage. Contractor will notify all impacted residents on a form provided by City at least seven (7) Days prior to the scheduled outage. 61147.91007\30425843.2 -71- 00 73 13 – SPECIAL CONDITIONS B. Contractor shall be responsible for providing, at its cost, any temporary utility or facilities necessitated by the utility outage. 1.12 Schedule Constraints. NOT USED. 1.13 Noise Restrictions NOT USED. 1.14 Safety Programs. [NOT USED. 1.15 Coordination with Other Contractors. NOT USED. END OF SPECIAL CONDITIONS 61147.91007\30425843.2 -72- 01 00 00 – GENERAL REQUIREMENTS 01 00 00 – GENERAL REQUIREMENTS PART 1 -- GENERAL 1.1 DESCRIPTION To be added 1.2 RELATED REQUIREMENTS SPECIFIED ELSEWHERE PART 2 -- PRODUCTS (NOT USED) PART 3 -- EXECUTION Quantity surveys. The Contractor shall perform such surveys and computations as are necessary to determine quantities of Work performed or placed during each progress payment period, and shall perform all surveys necessary for the City Representative to determine final quantities of Work in place. The City Representative will determine final quantities based upon the survey data provided by the Contractor, and the design lines and grades. If requested by the City Representative, the Contractor shall provide an electronic copy of data used for quantity computations. All surveys performed for measurement of final quantities of Work and material shall be subject to approval of City’s Representative. Unless waived by City’s Representative in each specific case, quantity surveys made by the Contractor shall be made in the presence of City’s Representative. Cost. Unless otherwise called for by the Contract Documents, the cost of all material, equipment, and labor required for quantity surveys shall be included in the Schedule of Pay Items for items of work requiring the surveys. No additional compensation shall be made to the Contractor for this Work. 3.2 SCHEDULE Estimated Schedule. Within 14 Days after the issuance of the Notice to Proceed, Contractor shall prepare a Project schedule and shall submit this to the Engineer for Approval. The receipt or Approval of any schedules by the Engineer or the City shall not in any way relieve the Contractor of its obligations under the Contract Documents. The Contractor is fully responsible to determine and provide for any and all staffing and resources at levels which allow for good quality and timely completion of the Project. Contractor’s failure to incorporate all elements of Work required for the performance of the Contract or any inaccuracy in the schedule shall not excuse the Contractor from performing all Work required for a completed Project within the specified Contract time period. If the required schedule is not received by the time the first payment under the Contract is due, Contractor shall not be paid until the schedule is received, reviewed and accepted by the Engineer. 61147.91007\30425843.2 -73- 01 00 00 – GENERAL REQUIREMENTS Schedule Contents. The schedule shall indicate the beginning and completion dates of all phases of construction; critical path for all critical, sequential time related activities; and “float time” for all “slack” or “gaps” in the non-critical activities. The schedule shall clearly identify all staffing and other resources which in the Contractor’s judgment are needed to complete the Project within the time specified for completion. The overall Project Schedule duration shall be within the Contract time. Schedule Updates. Contractor shall continuously update its construction schedule. Contractor shall submit an updated and accurate construction schedule to the Engineer monthly when requested to do so by Engineer. Contractor shall also submit schedules showing a three week detailed look-ahead at bi-weekly meetings conducted with the City. The Engineer may withhold progress payments or other amounts due under the Contract Documents if Contractor fails to submit an updated and accurate construction schedule. 3.3 TEMPORARY FIELD OFFICE NOT USED. 3.4 PROTECTION OF WORK AND PROPERTY All traffic detector loops, fences, walls, culverts, property line monuments, or other obstructions (except property line monuments within five (5) feet of the centerline of the mains) which are removed, damaged, or destroyed in the course of the Work, shall be replaced or repaired to the original condition. If Contractor provides the City with reasonable notice of the need for such repair or replacement, it shall be performed by the City. If the Contractor fails to provide the City with reasonable notice, the repair or replacement shall be performed by and at the expense of the Contractor to the satisfaction of the City, whether or not those obstructions have been shown on the Plans, unless otherwise stated herein. It is then the Contractor’s responsibility to employ at its expense a Licensed Land Surveyor to restore all property line monuments located more than five (5) feet from the centerline of the mains, which are destroyed or obliterated. Property line monuments located within five (5) feet of the centerline of the mains will be replaced by the City at no expense to the Contractor, provided the City is notified at least 48 hours before the property line monuments are damaged. Contractor shall provide such heat, covering, and enclosures as are necessary to protect all Work, materials, equipment, appliances, and tools against damage by weather conditions. Contractor shall take adequate precautions to protect existing sidewalks, curbs, pavements, utilities, and other adjoining property and structures, and to avoid damage thereto, and Contractor shall repair any damage thereto caused by the Work operations. Contractor shall: 1. Enclose the working area with a substantial barricade, and arrange work to cause minimum amount of inconvenience and danger to the public. 61147.91007\30425843.2 -74- 01 00 00 – GENERAL REQUIREMENTS 2. Provide substantial barricades around any shrubs or trees indicated to be preserved. 3. Deliver materials to the Project site over a route designated by the Engineer. 4. Provide any and all dust control required and follow the Applicable air quality regulations as appropriate. If the Contractor does not comply, the City shall have the immediate authority to provide dust control and deduct the cost from payments to the Contractor. 5. Confine Contractor’s apparatus, the storage of materials, and the operations of its workers to limits required by law, ordinances, permits, or directions of the Engineer. Contractor shall not unreasonably encumber the Project site with its materials. 6. Take care to prevent disturbing or covering any survey markers, monuments, or other devices marking property boundaries or corners. If such markers are disturbed by accident, they shall be replaced by a civil engineer or land surveyor acceptable to the City, at no cost to the City. 7. Ensure that existing facilities, fences and other structures are all adequately protected and that, upon completion of all Work, all facilities that may have been damaged are restored to a condition acceptable to the City. 8. Preserve and protect from injury all buildings, pole lines and all direction, warning and mileage signs that have been placed within the right-of-way. 9. At the completion of work each day, leave the Project site in a clean, safe condition. 10. Comply with any stage construction and traffic control plans. Access to residences and businesses shall be maintained at all times, unless otherwise permitted in writing by the City. These precautionary measures will apply continuously and not be limited to normal working hours. Full compensation for the Work involved in the preservation of life, safety and property as above specified shall be considered as included in the prices paid for the various contract items of Work, and no additional allowance will be made therefore. Should damage to persons or property occur as a result of the Work, Contractor shall be responsible for proper investigation, documentation, including video or photography, to adequately memorialize and make a record of what transpired. The City shall be entitled to inspect and copy any such documentation, video, or photographs. 3.5 SUBMITTAL REQUIREMENTS FOR MANUALS AND RECORD DRAWINGS General. The Contractor shall furnish all materials and perform all Work required for furnishing submittals to City in accordance with Contract Documents. 61147.91007\30425843.2 -75- 01 00 00 – GENERAL REQUIREMENTS Technical Manuals. 1. The Contractor shall submit technical operation and maintenance information for each item of mechanical, electrical and instrumentation equipment in an organized manner in the Technical Manual. It shall be written so that it can be used and understood by City’s operation and maintenance staff. 2. The Technical Manual shall be subdivided first by specification section number; second, by equipment item; and last, by "Category." "Categories" shall conform to the following (as applicable): (a) Category 1 - Equipment Summary: (1) Summary: A summary table shall indicate the equipment name, equipment number, and process area in which the equipment is installed. (b) Category 2 - Operational Procedures: (1) Procedures: Manufacturer-recommended procedures on the following shall be included in Part 2: a. Installation b. Adjustment c. Startup d. Location of controls, special tools, equipment required, or related instrumentation needed for operation e. Operation procedures f. Load changes g. Calibration h. Shutdown i. Troubleshooting j. Disassembly k. Reassembly l. Realignment m. Testing to determine performance efficiency n. Tabulation of proper settings for all pressure relief valves, low and high pressure switches, and other protection devices 61147.91007\30425843.2 -76- 01 00 00 – GENERAL REQUIREMENTS o. List of all electrical relay settings including alarm and contact settings (c) Category 3 - Preventive Maintenance Procedures: (1) Procedures: Preventive maintenance procedures shall include all manufacturer-recommended procedures to be performed on a periodic basis, both by removing and replacing the equipment or component, and by leaving the equipment in place. (2) Schedules: Recommended frequency of preventive maintenance procedures shall be included. Lubrication schedules, including lubricant SAE grade, type, and temperature ranges, shall be covered. (d) Category 4 - Parts List: (1) Parts List: A complete parts list shall be furnished, including a generic description and manufacturer's identification number for each part. Addresses and telephone numbers of the nearest supplier and parts warehouse shall be included. (2) Drawings: Cross-sectional or exploded view drawings shall accompany the parts list. (e) Category 5 - Wiring Diagrams: (1) Diagrams: Part 5 shall include complete internal and connection wiring diagrams for electrical equipment items. (f) Category 6 - Shop Drawings: (1) Drawings: This part shall include approved shop or fabrication drawings, complete with dimensions. (g) Category 7 - Safety: (1) Procedures: This part describes the safety precautions to be taken when operating and maintaining the equipment or working near it. (h) Category 8 - Documentation: (1) All equipment warranties, affidavits, and certifications required by the Technical Specifications and Scope of Work shall be placed in this part. 3. The Contractor shall furnish to City six (6) identical Technical Manuals. Each set shall consist of one or more volumes, each of which shall be bound in a standard binder. Spare Parts List - The Contractor shall furnish to City six (6) identical sets of spare parts information for all mechanical, electrical, and instrumentation equipment. The spare parts list shall include the current list price of each spare part. The spare parts list shall include those spare parts which each manufacturer recommends be maintained by City in inventory. Each manufacturer or supplier shall indicate the 61147.91007\30425843.2 -77- 01 00 00 – GENERAL REQUIREMENTS name, address, and telephone number of its nearest outlet of spare parts to assist City in ordering. The Contractor shall cross-reference all spare parts lists to the equipment numbers designated in the Contract Documents. The spare parts lists shall be bound in standard size, 3-ring binder. Cost. Unless otherwise called for by the Contract Documents, the cost of all material, equipment, and labor required to complete the Manuals shall be included in Contractor’s bid and distributed in the Schedule of Pay. No additional compensation shall be made to the Contractor for this Work. 3.6 MATERIALS Materials to be Furnished by the Contractor 1. Inspection of Materials. Materials furnished by the Contractor which will become a part of the Project shall be subject to inspection at any one or more of the following locations, as determined by City’s Representative: at the place of production or manufacture, at the shipping point, or at the site of the Work. To allow sufficient time to provide for inspection, the Contractor shall submit to City’s Representative, at the time of issuance, copies of purchase orders or other written instrument confirming procurement of the materials, including drawings and other pertinent information, covering materials on which inspection will be made. 2. No later than fourteen (14) Days prior to manufacture of material, Contractor shall inform City’s Representative, in writing, the date the material is to be manufactured. 3. Contractors Obligations. The inspection of materials at any of the locations specified above or the waiving of the inspection thereof shall not impact whether the materials and equipment conform to the Contract Documents. Contractor will not be relieved from furnishing materials meeting the requirements of the Contract Documents due to City’s inspection or lack of inspection of the equipment or materials. Acceptance of any materials will be made only after materials are installed in the Project. 4. Cost. Unless otherwise called for by the Contract Documents, the cost of all material, equipment, and labor required to accommodate City’s testing efforts, including any travel required by Contractor’s forces, shall be included in Contractor’s bid and distributed in the Schedule of Pay Items related to the materials requiring testing. No additional compensation shall be made to the Contractor for this Work. 3.7 LOCAL CONDITIONS AND REQUIREMENTS Access to Work and Haul Routes 1. General. All work on the rights-of-way necessary for access to the Site shall be performed by the Contractor. 61147.91007\30425843.2 -78- 01 00 00 – GENERAL REQUIREMENTS 2. Access, Damage, Restoration. The Contractor shall make his own investigation of the condition of available public or private roads and of clearances, restrictions, bridge-load limits, permit or bond requirements, and other limitations that affect or may affect transportation and ingress or egress at the Site. Claims for changes in Contract Price or Contract Times arising out of the unavailability of transportation facilities or limitations thereon shall not be considered by City. 3. The Contractor shall maintain and repair any damage arising out of Contractor’s operations to all roads used during construction of the Project, and upon completion of all Work, but prior to final acceptance, the roads shall be restored to their original condition. Prior to using any road for access to the Site, the Contractor shall conduct a photograph and/or video survey of the roadway with a copy submitted to City’s Representative. 4. Cost. Unless otherwise called for by the Contract Documents, the cost of all material, equipment, and labor required to complete this Work, shall be included in Contractor’s bid and distributed in the Schedule of Pay Items. No additional compensation shall be made to the Contractor for this Work. Power. Contractor shall provide at its own expense all necessary power required for operations under the contract. The Contractor shall provide and maintain in good order such modern equipment and installations as shall be adequate in the opinion of the Engineer to perform in a safe and satisfactory manner the Work required by the contract. Construction Water. 1. Construction water shall not be used for purposes other than those required to satisfactorily complete the contract. 2. All connections to the City's water system used for the purposes of obtaining construction water shall utilize a temporary construction meter and backflow prevention device supplied by the City. The City-furnished backflow prevention device shall be tested immediately after installation and the construction meter and backflow prevention device shall not be placed into service until the backflow prevention device passes such tests. Backflow prevention device testing shall be performed in accordance with the most recent edition of the Manual of Cross- Connection Control as published by the University of Southern California by a person selected from City of San Juan Capistrano “City-Approved Certified Backflow Assembly Testers” list, and test results shall be provided to the Engineer. If the temporary construction meter and backflow prevention device are moved to alternate location(s) during construction, the backflow prevention device shall again be tested as described above immediately after re-installation. 3. For each temporary construction meter requested by the Contractor for the performance of work under this contract, an amount equivalent to the deposit requirement for temporary construction meters listed in the current approved version of the City’s Policies and Procedures Manual shall be withheld from the final contract payment until the temporary construction meters are returned. Operation of Existing Water Facilities 61147.91007\30425843.2 -79- 01 00 00 – GENERAL REQUIREMENTS 1. The Contractor shall not operate any of the existing water systems, including pumps, motors, and hydrants, but shall contact the City two (2) working days in advance with a list and location of the water system facilities that will require operating, opening, stopping, or closure by the City. 2. At the option of the Engineer, the Contractor may be permitted to operate valves for the purpose of making connections to existing mains. The City will perform all notification to existing customers regarding temporary loss of service. 3. Contractor shall submit a request on City’s standard form for any shut-down of existing water facilities. Construction at Existing Utilities 1. General. Where the Work to be performed crosses or otherwise interferes with water, sewer, gas, or oil pipelines; buried cable; or other public or private utilities, the Contractor shall perform construction in such a manner so that no damage will result to either public or private utilities. It shall be the responsibility of the Contractor to determine the actual locations of, and make accommodates to maintain, all utilities. 2. Permission, Notice and Liability. Before any utility is taken out of service, permission shall be obtained by the Contractor from the owner. The owner, any impacted resident or business owner and the City Representative will be advised of the nature and duration of the utility outage as well as the Contractor’s plan for providing temporary utilities if required by the owner. The Contractor shall be liable for all damage which may result from its failure to maintain utilities during the progress of the Work, and the Contractor shall indemnify City as required by the Contract Documents from all claims arising out of or connected with damage to utilities encountered during construction; damages resulting from disruption of service; and injury to persons or damage to property resulting from the negligent, accidental, or intentional breaching of utilities. 3. Cost. Unless otherwise called for by the Contract Documents, the cost of all material, equipment, and labor required to complete this Work, shall be included in Contractor’s bid and distributed in the Schedule of Pay Items. No additional compensation shall be made to the Contractor for this Work. Traffic Control 1. General. Contractor shall abide by traffic control plans approved by the appropriate jurisdiction. 2. Protections. Roads subject to interference by the Work shall be kept open or suitable temporary passages through the Work shall be provided and maintained by the Contractor. The Contractor shall provide, erect, and maintain all necessary barricades, suitable and sufficient flasher lights, flag persons, danger signals, and signs, and shall take all necessary precautions for the protection of the Work and the safety of the public. No construction work along public or private roads may proceed until the Contractor has proper barricades, flasher lights, flag persons, signals, and signs in place at the construction site. 61147.91007\30425843.2 -80- 01 00 00 – GENERAL REQUIREMENTS 3. Cost. Unless otherwise called for by the Contract Documents, the cost of all material, equipment, and labor required to complete this Work, shall be included in Contractor’s bid and distributed in the Schedule of Pay Items. No additional compensation shall be made to the Contractor for this Work. Cleaning Up 1. Contractor at all times shall keep premises free from debris such as waste, rubbish, and excess materials and equipment. Contractor shall not store debris under, in, or about the premises. Contractor shall also clean all asphalt and concrete areas to the degree necessary to remove oil, grease, fuel, or other stains caused by Contractor operations or equipment. The use of water, resulting in mud on streets, will not be permitted as substitute for sweeping or other methods. Dust control may require having a water truck onsite for the duration of the project, and/or use of temporary hoses and pipelines to convey water. 2. Contractor shall fully clean up the site at the completion of the Work. If the Contractor fails to immediately clean up at the completion of the Work, the City may do so and the cost of such clean up shall be charged back to the Contractor. 3.8 ENVIRONMENTAL QUALITY PROTECTION Environmental Conditions NOT USED. Landscape and Vegetation Preservation 1. General. The Contractor shall exercise care to preserve the natural landscape and vegetation, and shall conduct operations so as to prevent unnecessary destruction, scarring, or defacing of the natural surroundings in the vicinity of the Work. 2. Damage and Restoration. Movement of crews and equipment within the rights-of- way and over routes provided for access to the Work shall be performed in a manner to prevent damage to property. When no longer required, construction roads shall be restored to original contours. 3. Upon completion of the Work, and following removal of construction facilities and required cleanup, land used for construction purposes and not required for the completed installation shall be scarified and regraded, as required, so that all surfaces are left in a condition that will facilitate natural revegetation, provide for proper drainage, and prevent erosion. 4. Cost. Unless otherwise called for by the Contract Documents, the cost of all material, equipment, and labor required to complete this Work, shall be included in Contractor’s bid and distributed in the Schedule of Pay Items. No additional compensation shall be made to the Contractor for this Work. Protected Species 61147.91007\30425843.2 -81- 01 00 00 – GENERAL REQUIREMENTS 1. General. If, in the performance of the Work, evidence of the possible occurrence of any Federally listed threatened or endangered plant or animal is discovered, the Contractor shall notify the City Representative immediately, giving the location and nature of the findings. Written confirmation of the evidence, location and nature of the findings shall be forwarded to City within 2 Days. 2. Procedures. The Contractor shall immediately cease all construction activities in the immediate area of the discovery to the extent necessary to protect the endangered plant or animal. If directed by the City Representative, Contractor will refrain from working in the immediate area, suspend the Work in its entirety, or alter its performance to ensure full compliance with all applicable permits, laws and regulations. Any City directed changes to the Work as a result of a siting will be pursuant to the Contract Documents. 3. False Siting. Any costs or delays incurred by City or the Contractor due to unreasonable or false notification of an endangered plant or animal will be borne by the Contractor. 4. Cost. Unless otherwise called for by the Contract Documents, the cost of all material, equipment, and labor required to comply with this paragraph, shall be included in Contractor’s bid and distributed in the Schedule of Pay Items. No additional compensation shall be made to the Contractor for this Work. Preservation of Historical and Archeological Resources 1. General. If, in the performance of the Work, Contractor should unearth cultural resources (for example, human remains, animal bones, stone tools, artifacts and/or midden deposits) through excavation, grading, watering or other means, the Contractor notify the Construction/Archeological Monitor and/or the City Representative immediately, giving the location and nature of the findings. Written confirmation of the evidence, location and nature of the findings shall be forwarded to the Construction/Archeological Monitor and/or City within 2 Days. 2. Procedures. The Contractor shall immediately cease all construction activities in the immediate area of the discovery to the extent necessary to protect the cultural resource. If directed by the City Representative, Contractor will refrain from working in the immediate area, suspend the Work in its entirety, or re-sequence and/or alter its performance to ensure full compliance with all applicable permits, laws and regulations. Should the presence of cultural resources be confirmed, the Contractor will assist the City Representative and the Construction/Archeological Monitor in the preparation and implementation of a data recovery plan. The Contractor shall provide such cooperation and assistance as may be necessary to preserve the cultural resources for removal or other disposition. Any City directed changes to the Work as a result of the cultural resource will be pursuant to the Contract Documents. 61147.91007\30425843.2 -82- 01 00 00 – GENERAL REQUIREMENTS 3. Contractor’s Liability. Should Contractor, without permission, injure, destroy, excavate, appropriate, or remove any cultural resource on or adjacent to the Site, it will be subject to disciplinary action, arrest and penalty under applicable law. The Contractor shall be principally responsible for all costs of mitigation and/or restoration of cultural resources related to the unauthorized actions identified above. Contractor shall be required to pay for unauthorized damage and mitigation costs to cultural resources (historical and archeological resources) as a result of unauthorized activities that damage cultural resources and shall indemnify City pursuant to the Contract Documents. 4. Cost. Unless otherwise called for by the Contract Documents, the cost of all material, equipment, and labor required to comply with this paragraph, shall be included in Contractor’s bid and distributed in the Schedule of Pay Items. No additional compensation shall be made to the Contractor for this Work. Dust and Pollution Control 1. Contractor shall provide all necessary material, equipment and labor to prevent and control the emission of dust and any other potential pollutant on site. 2. Contractor shall not discharge into the atmosphere from any source smoke, dust or other air contaminants in violation of the law, rules, and regulations of the governing agency. 3. Cost. Unless otherwise called for by the Contract Documents, the cost of all material, equipment, and labor required to comply with this paragraph, shall be included in Contractor’s bid and distributed in the Schedule of Pay Items. No additional compensation shall be made to the Contractor for this Work. Fugitive Dust NOT USED. Management of Storm, Surface and Other Waters 1. Storm water, surface water, groundwater, and nuisance, or other waters may be encountered at various times during construction of the Project. Federal and State laws require the City and its contractors to manage such waters pursuant to the requirements of California State Water Resources Control Board Order Number 2009-0009-DWQ, the Federal Clean Water Act, and the California Porter Cologne Water Quality Control Act. Contractor acknowledges that it has investigated the risk arising from such waters in conjunction with the Project, and assumes any and all risks and liabilities arising therefrom. 2. The Contractor shall perform all construction operations in such a manner as to comply, and ensure all subcontractors to comply, with all applicable Federal, State, and local laws, orders, and regulations concerning the control and abatement of water pollution; and all terms and conditions of any applicable permits issued for the Project. In the event there is a conflict between Federal, State, and local laws, regulations, and requirements, the most stringent shall apply. 61147.91007\30425843.2 -83- 01 00 00 – GENERAL REQUIREMENTS 3. Contractor violations. If noncompliance should occur, the Contractor shall report this to the City Representative immediately, with the specific information submitted in writing within 2 Days. Consistent violations of applicable Federal, State, or local laws, orders, regulations, or Water Quality Standards may result in City stopping all site activity until compliance is ensured. The Contractor shall not be entitled to any change in Contract Price or Contract Times, claim for damage, or additional compensation by reason of such a work stoppage. Corrective measures required to bring activities into compliance shall be at the Contractor's expense. 4. Compliance with Construction General Storm water Permit. Contractor shall be required to comply with all aspects of the State Water Resources Control Board (State Board) Water Quality Order No. 2009-0009-DWQ, National Pollutant Discharge Elimination System General Permit for Storm Water Discharges Associated with Construction Activity (Permit) for all projects that involve construction on or disturbance of one acre or more of land or which are part of a larger common area of development. (a) Contractor shall prepare and implement a Storm Water Pollution Prevention Plan (SWPPP) for the Project site based on the appropriate Risk Level requirements, and draft and coordinate submittal of all Permit related documents with City’s Legally Responsible Person and/or Authorized Signatory as those terms are defined in the Permit. The Contractor shall submit the SWPPP to the City Representative for review not less than fifteen (15) Days prior to the start of on- site construction work. City will file the Notice of Intent and pay the filing fee. (b) The SWPPP shall be developed by a Qualified SWPPP Developer and implemented by a Qualified SWPPP Practitioner as those terms are defined in the Permit and shall include industry standard requirements for water quality control including but not be limited to the following: (1) Sediment and erosion control measures to manage sediment and erosion including vegetative practices, structural control, silt fences, straw dikes, sediment controls or operator controls as appropriate. Storm water management measures shall be instituted as required, including velocity dissipaters, and solid waste controls shall address controls for building materials and offsite tracking of sediment. (2) Wastewater and storm water management controls to divert offsite surface flows around the Project site and to divert surface flows within the Project area away from areas of open earth or stockpiles of building and other materials. Wastewater from general construction activities, such as drain water collection, aggregate processing, concrete batching, drilling, grouting, or other construction operations, shall not enter flowing or dry watercourses without having met the authorized non- storm water discharge requirements listed in State Board Water Quality Order No. 2009-0009-DWQ, Section III.C., including proper notification to the Regional Water Board. (3) Pollution prevention measures including methods of dewatering, unwatering, excavating, or stockpiling earth and rock materials which include prevention measures to control silting and erosion, and which 61147.91007\30425843.2 -84- 01 00 00 – GENERAL REQUIREMENTS will intercept and settle any runoff of sediment-laden waters. (4) Turbidity prevention measures for prevention of excess turbidity including, but are not restricted to, intercepting ditches, settling ponds, gravel filter entrapment dikes, flocculating processes, recirculation, combinations thereof, or other approved methods that are not harmful to aquatic life. All such wastewaters discharged into surface waters, shall contain the least concentration of settleable material possible, and shall meet all conditions of section 402, the National Pollutant Discharge Elimination System (NPDES) permit. (5) Overall construction site management measures to address changes at the Project site as the Project moves through different phases and changes that account for rainy and dry season management practices. (6) Pollution control measures and construction activity methods that will prevent entrance, or accidental spillage, of solid matter, contaminants, debris, or other pollutants or wastes, into streams, flowing or dry watercourses, lakes, wetlands, reservoirs, or underground water sources. Such pollutants and wastes include, but are not restricted to: refuse, garbage, cement, sanitary waste, industrial waste, hazardous materials, radioactive substances, oil and other petroleum products, aggregate processing, tailings, mineral salts, and thermal pollution. (7) Control measures for stockpiled or deposited materials prohibiting the stockpile or deposit of excavated materials, or other construction materials, near or on stream banks, lake shorelines, or other watercourse perimeters where they can be washed away by high water or storm runoff, or can, in any way, encroach upon the watercourse. (8) Develop and implement a Rain Event Action Plan (REAP), if required, that must be designed and implemented to protect all exposed portions of the site 48 hours prior to any likely precipitation event. (9) Monitoring, reporting and record keeping, as necessary to achieve compliance with applicable Permit requirements, including but not limited to annual reports and rain event reports. (c) Before any Permit related documents, including the SWPPP, rain event reports, or annual reports may be submitted to the State Board or implemented on the Project site, they must first be reviewed and approved by City. (d) City retains the right to procure and maintain coverage under the Permit for the Project site if the Contractor fails to draft a SWPPP or other Permit related document, or fails to proceed in a manner that is satisfactory to City. City reserves the right to implement its own SWPPP at the Project site, and hire additional contractors to maintain compliance. Whether Contractor has adequately maintained compliance with the Permit shall be City’s sole determination. In the event that Contractor has failed or is unable to maintain compliance with the Permit, any costs or fines incurred by City in implementing a SWPPP, or otherwise maintaining compliance with the Construction General Permit shall be paid by the Contractor. 61147.91007\30425843.2 -85- 01 00 00 – GENERAL REQUIREMENTS (e) Failure to implement the SWPPP or otherwise comply with the Permit is a violation of federal and state law. Contractor hereby agrees to indemnify City as required by the Contract Documents for any noncompliance or alleged noncompliance with the Permit arising out of or in connection with the Project, except for liability resulting from the sole established negligence, willful misconduct or active negligence of City. City may seek damages from Contractor for delay in completing the Contract in accordance with the Contract Documents, caused by Contractor’s failure to comply with the Permit. 5. In addition to compliance with the Permit, Contractor shall comply with the lawful requirements of any applicable municipality, district, drainage district, flood control district, and other local agencies regarding discharges of storm water, surface water, groundwater or other nuisance waters off of the Project site. 6. Oil storage tanks management. (a) Storage tank placement. All oil or other petroleum product (hereinafter referred to collectively as oil) storage tanks shall be placed at least 20 feet from streams, flowing or dry watercourses, lakes, wetlands, reservoirs, and any other water source. (b) Storage area dikes. Storage areas shall be diked at least 12 inches high or graded and sloped to permit safe containment of leaks and spills equal to the capacity of all tanks and/or containers located within each area, plus a sufficient amount of freeboard to contain the 25-year rainstorm. (c) Diked area barriers. Diked areas shall have an impermeable barrier at least 10 mils thick. Areas used for refueling operations shall have an impermeable liner at least 10 mils thick buried under 2 to 4 inches of soil. (d) Spill Prevention Control and Countermeasure Plan (SPCC). Where the location of a construction site is such that oil from an accidental spillage could reasonably be expected to enter into or upon the navigable waters of the United States or adjoining shorelines, and the aggregate storage of oil at the site is over 1,320 gallons or a single container has a capacity in excess of 660 gallons, the Contractor shall prepare an SPCC Plan. The Contractor shall submit the SPCC Plan to the Engineer at least 30 days prior to delivery or storage of oil at the site. The Plan must have been reviewed and certified by a registered professional engineer in accordance with 40 C.F.R., part 112 7. Underground tank prohibition. The Contractor shall not use underground storage tanks. 8. Construction safety standards. The Contractor shall comply with the sanitation and potable water requirements of Section 7 of United States Bureau of Reclamation's publication “Reclamation Safety And Health Standards.” 9. Other Permits. (a) Other permits applicable to the Project are listed in the Special Conditions. The Contractor shall obtain all other necessary licenses and permits. 61147.91007\30425843.2 -86- 01 00 00 – GENERAL REQUIREMENTS (b) Monitoring. The Contractor is required to conduct monitoring in order to meet the requirements of the permits, which may include sampling, testing and inspections. (c) Recordkeeping. The Contractor shall retain all records and data required by the permits for the time specified in the contract. 10. Cost. Except as specified herein, the cost of complying with this section shall be included in the Schedule of Pay Items for work which necessitate the water pollution prevention measures required by this paragraph. END OF GENERAL REQUIREMENTS 61147.91007\30425843.2 1 EXHIBIT “A” Change Order Form EXHIBIT “A” CHANGE ORDER FORM City of San Juan Capistrano Contract Change Order # Project: Change Order No.: Orig. Contract Amt.: $ Days Contract No.: Contractor: Prev. Appvd. Changes: $ Days Owner: City of San Juan Capistrano This Change: $ Days Revised Contract Amt.: $ Days This Change Order covers changes to the subject contract as described herein. The Contractor shall construct, furnish equipment and materials, and perform all work as necessary or required to complete the Change Order items for a lump sum price agreed upon between the Contractor and City of San Juan Capistrano, otherwise referred to as Owner. Item No. Description of Changes Increase/ (Decrease) in Contract Amount Contract Time Extension, Days 1 2 Totals $ This Contract Change Order consists of 2 pages and any exhibits attached to this Contract Change Order shall not be part of the Contract Change Order unless specifically initialed by or on behalf of both the Contractor and the City of San Juan Capistrano. Contract Change Order # Page 1 of 2 32400 Paseo Adelanto San Juan Capistrano, CA 92675 (949) 493-1171 61147.91007\30425843.2 2 EXHIBIT “A” Change Order Form The amount of the contract will be increased by the sum of $ and the contract time shall be extended by working days. The undersigned Contractor approves the foregoing Change Order # as to the changes, if any, in the contract price specified for each item including any and all supervision costs and other miscellaneous costs relating to the change in work, and as to the extension of time allowed, if any, for completion of the entire work on account of said Change Order #. The Contractor agrees to furnish all labor and materials and perform all other necessary work, inclusive of the directly or indirectly related to the approved time extension, required to complete the Change order items. This document will become a supplement of the contract and all provisions will apply hereto. It is understood that the Change Order shall be effective when approved by the Owner. Contractor accepts the terms and conditions stated above as full and final settlement of any and all claims arising out of or related to the subject of this Change Order and acknowledges that the compensation (time and cost) set forth herein comprises the total compensation due for the work or change defined in the Change Order, including all impact on any unchanged work. By signing this Change Order, the Contractor acknowledges and agrees that the stipulated compensation includes payment for all Work contained in the Change Order, plus all payment for any acceleration or interruption of schedules, extended overhead costs, delay, and all impact or cumulative impact on all Work under this Contract. The signing of this Change Order acknowledges full mutual accord and satisfaction for the change and that the stated time and/or cost constitute the total equitable adjustment owed the Contractor as a result of the change. The Contractor hereby releases and agrees to waive all rights, without exception or reservation of any kind whatsoever, to file any further claim or request for equitable adjustment of any type, for any reasonably foreseeable cause that shall arise out of, or as a result of, this Change Order and/or its impact on the remainder of the Work under the Contract. Accepted: (Signature) Contractor’s Authorized Representative Date Recommended: (Signature) [**INSERT NAME, TITLE**] Date Approved: (Signature) [**INSERT NAME, TITLE**] Date Item No. Justification for Change(s) 1 2 This Contract Change Order consists of 2 pages and any exhibits attached to this Contract Change Order shall not be part of the Contract Change Order unless specifically initialed by or on behalf of both the Contractor and the City of San Juan Capistrano. Contract Change Order # Page 2 of 2 61147.91007\30425843.2 3 EXHIBIT “A” Change Order Form 61147.91007\30425843.2 4 EXHIBIT “A” Change Order Form EXHIBIT “B” Technical Specifications and Scope of Work [Inserted behind this cover page] 61147.91007\30425843.2 5 EXHIBIT “A” Change Order Form I. Consultant will perform the following Services: A. Obtain necessary encroachment permits. B. Prepare and manage waste disposal that will comply with City, State, and Federal requirements. C. Comply with all requirements to ensure luminaires receive the applicable rebates and SDGE’s reduced tariff schedule. D. Provide all necessary equipment, hardware, and any other materials for installation of LED street light retrofit kits per attached proposal. E. Deliver final database of installed fixtures in Microsoft Excel format. F. Prepare all documentation required to receive rebates on behalf of the City. G. Collaborate with SDGE to process the tariff change and amend billing records with SDGE. H. Determine loan repayment amounts for the life of the loan. II. As part of the Services, Consultant will prepare and deliver the following tangible work products to the City: A. Project schedule prior to the commencement of work. B. LED retrofit kits, equipment and labor resources C. Representative samples of spare equipment for future use (in stock) for maintenance and warranty purposes. D. GIS database of installed LED equipment, including attributes as detailed in the Investment Grade Audit E. Traffic Control plan to be reviewed and approved by the City’s Public Works Department 61147.91007\30425843.2 6 EXHIBIT “A” Change Order Form III. Consultant will keep the City appraised of the status of performance by delivering the following status reports: A. Progress reports to the City staff on a weekly basis. B. Final report to the City following acceptance of the installation. IV. All work product is subject to review and acceptance by the City, and must be revised by the Consultant without additional charge to the City until found satisfactory and accepted by the City. V. Consultant will utilize the following personnel to accomplish the Services: A. Bryan Berlin – Project Manager B. Michael Hutchens – Area Operations Manager C. Richard O’Hearn – Senior Energy Engineer D. Kylon – Energy Engineer E. Alex Valenti – Account Manager Street Light Technicians (TBD)